Loading...
HomeMy WebLinkAbout09 - Award of On -Call Professional Transportation Engineering Services AgreementsTO: FROM CITY OF NEWPORT BEACH City Council Staff Report September 24, 2019 Agenda Item No. 9 HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL David A. Webb, Public Works Director - 949-644-3311, dawebb@newportbeachca.gov PREPARED BY: Brad Sommers, Principal Civil Engineer PHONE: 949-644-3326 TITLE: Approval and Award of On -Call Professional Transportation Engineering Services Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. ABSTRACT: Transportation related design and planning projects often require use of professional consulting services to provide design, planning, studies and review to ensure efficient delivery of transportation -related projects. Upon completion of the selection process for a Request for Proposal (RFP) for On -Call Professional Transportation Engineering Services, staff recommends awarding on-call contracts to Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. for five-year terms and a total not -to -exceed amount of $300,000 per agreement. RECOMMENDATION: a) Determine this action is exempt from the California Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) and 15060(c)(3) of the CEQA Guidelines because this action will not result in a physical change to the environment, directly or indirectly; and b) Approve On -Call Professional Transportation Engineering Services Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. for a five-year term and a total amount not -to -exceed $300,000 per agreement, and authorize the Mayor and City Clerk to execute the agreements. FUNDING REQUIREMENTS: The adopted budget(s) include sufficient funding. Services for individual projects will be expensed to the corresponding Public Works Department Maintenance and Operating Budget and/or Capital Improvement Program (CIP) Budget. 9-1 Approval and Award of On -Call Professional Transportation Engineering Services Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. September 24, 2019 Page 2 DISCUSSION: The City uses private sector consultants to fulfill various engineering and other professional services associated with Public Works projects. Transportation Engineering encompasses planning, design, construction, and maintenance of the City's roadway network with the goal of safe and efficient movement of people and goods. The transportation discipline is multifaceted with items such as preparation of transportation studies, traffic signal design, roadway signage and striping, construction traffic control, and design of pedestrian and bicycle facilities. Each has unique details and requires firms that specialize in a specific branch of transportation engineering. In order to address and to expedite transportation related items, studies and projects, the City currently has ten separate on-call agreements for Transportation Engineering services to facilitate the wide range of transportation and traffic related needs. Eight of these agreements are currently set to expire within the year and are being reviewed for potential time extensions, with the goal of maintaining an adequate number of available supporting contract consultant resources. To ensure staff has adequate resources to continue project delivery, the City issued a Request for Proposals (RFP) in July 2019 for additional On -Call Professional Transportation Engineering Services. The following 13 firms submitted proposals: Firm Name Total Score Rank Willdan Engineering 281 1 Kimley-Horn and Associates, Inc. * 279 2 RK Engineering Group, Inc. 279 3 Ganddini Group, Inc. 265 4 Michael Baker International 261 5 DKS 256 6 JM Diaz, Inc. 253 7 Fehr & Peers 252 8 GHD Inc. 252 8 Quantum Consulting, Inc. 248 10 W.G. Zimmerman Engineering, Inc. 247 11 General Technology & Solutions 239 12 Mark Thomas 235 13 Kimley-Horn and the City were not able to agree on the terms of the agreement. 9-2 Approval and Award of On -Call Professional Transportation Engineering Services Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. September 24, 2019 Page 3 The City's proposal review team consisted of three staff members from the Public Works - Traffic and Transportation Division. Proposals were evaluated by the review team independently. Evaluations were based in accordance to each proposal's demonstration of the firm's abilities and expertise of the project team related to transportation projects, qualifications and experience, a demonstrated understanding of the City's needs, and the ability to deploy appropriate resources. Evaluations also considered each firm's recent experience and project references in conducting work for public agencies of similar scope and complexity. Upon completion of the qualifications -based review of the proposals, the sealed fee schedules were opened and reviewed for the top firms and confirmed to be reasonable and feasible when considering each firm's ability and their available resources. Although Kimley-Horn and Associates was ranked second through the review process, they requested additional revisions to the contract language that are not acceptable by the City. Therefore, Kimley-Horn and Associates has been removed from further consideration. Staff requests approval of three separate On -Call Professional Services Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. for Transportation Engineering Services for a five-year term and a total amount not -to - exceed $300,000 per agreement. ENVIRONMENTAL REVIEW: Staff recommends the City Council find this action is not subject to the California Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) (the activity will not result in a direct or reasonably foreseeable indirect physical change in the environment) and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no potential for resulting in physical change to the environment, directly or indirectly. NOTICING: The agenda item has been noticed according to the Brown Act (72 hours in advance of the meeting at which the City Council considers the item). ATTACHMENTS: Attachment A — Professional Services Agreement with Willdan Engineering Attachment B — Professional Services Agreement with RK Engineering Group, Inc. Attachment C — Professional Services Agreement with Ganddini Group, Inc. 9-3 ATTACHMENT A ON-CALL PROFESSIONAL SERVICES AGREEMENT WITH WILLDAN ENGINEERING FOR TRAFFIC/TRANSPORTATION ENGINEERING THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is made and entered into as of this 24th day of September, 2019 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and WILLDAN ENGINEERING, a California corporation ("Consultant"), whose address is 2401 E. Katella Avenue, Suite 300, Anaheim, CA 92806, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide professional traffic and/or transportation engineering services on an on-call/as-needed basis ("Project"). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: The term of this Agreement shall commence on the Effective Date, and shall terminate on September 23, 2024, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED 2.1 Consultant shall perform the on-call services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Consultant shall provide a letter proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal"). The Letter Proposal shall include the following: 2.1.1 A detailed description of the Services to be provided; 2.1.2 The position of each person to be assigned to perform the Services, and the name of the individuals to be assigned, if available; and 2.1.3 The estimated number of hours and cost to complete the Services; 2.1.4 The time needed to finish the specific project. 2.2 No Services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand -delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written authorization from City. Except as otherwise provided herein, no billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Upon the first anniversary of the Effective Date and upon each anniversary of the Effective Date thereafter, the billing rates set forth in Exhibit B ("Billing Rates") shall WILLDAN ENGINEERING Page 2 MR be adjusted in proportion to changes in the Consumer Price Index, subject to the maximum adjustment set forth below. Such adjustment shall be made by multiplying the Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the Consumer Price Index for the calendar month three (3) months preceding the calendar month for which such adjustment is to be made, and the denominator of which is the value of the Consumer Price Index for the same calendar month immediately prior to Effective Date. The Consumer Price Index to be used in such calculation is the "Consumer Price Index, All Items, 1982-84=100 for All Urban Consumers (CPI -U)", for the Los Angeles - Riverside -Orange County Metropolitan Area, published by the United States Department of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial indices are published, the official index shall be used. If said Consumer Price Index is no longer published at the adjustment date, it shall be constructed by conversion tables included in such new index. In no event, however, shall the amount payable under this Agreement be reduced below the Billing Rates in effect immediately preceding such adjustment. The maximum adjustment increase to the Billing Rates, for any year where an adjustment is made pursuant to this Section, shall not exceed the Consumer Price Index or 2.0% of the Billing Rates in effect immediately preceding such adjustment, whichever is less. 4.3 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.4 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved in writing in advance by City. 4.5 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal. mC91111111►ITTIIZYTITCIA7 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Vanessa Munoz, PE, TE, PTOE to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel WILLDAN ENGINEERING Page 3 on to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. City's Public Works Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws, and legally recognized professional standards. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to WILLDAN ENGINEERING Page 4 9-7 approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this (collectively, the "Indemnified Parties), from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them. 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR 10.1 It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 10.2 Consultant agrees and acknowledges that no individual performing Services or Work pursuant to this Agreement shall: work full-time for more than six (6) WILLDAN ENGINEERING Page 5 9-8 months; work regular part-time service of at least an average of twenty (20) hours per week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or already be a CalPERS member. 10.3 Consultant must submit to and pass a criminal background investigation by providing a complete set of fingerprints to City prior to commencing or performing Services or Work. Consultant is required to submit any fees for the criminal background investigation according to the City's most current administrative fee schedule or successor document. Fingerprints may be required to be updated every five (5) years. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint -venture or syndicate or co -tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint -venture. WILLDAN ENGINEERING Page 6 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents, including all logins and password information to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 17.3 CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability WILLDAN ENGINEERING Page 7 9-10 resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a CD, and should comply with the City's digital submission requirements for improvement plans available from the City's Public Works Department. The City will provide Consultant with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall be transmitted to City in formats compatible with Microsoft Office and/or viewable with Adobe Acrobat. 17.4 All improvement and/or construction plans shall be prepared with indelible waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting ("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90) days after finalization of the Project. For more detailed requirements, a copy of the City of Newport Beach Standard Design Requirements is available from the City's Public Works Department. 18. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents the Consultant's judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to Consultant or contractor bids or actual cost to City. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 21. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow WILLDAN ENGINEERING Page 8 9-11 inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 22. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 25. CONFLICTS OF INTEREST 25.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et seq., which (1) require such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibit such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 25.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant shall conform to all requirements therein. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 26. NOTICES 26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third WILLDAN ENGINEERING Page 9 9-12 business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 26.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Public Works Director Public Works Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 26.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Vanessa Munoz, PE, TE, PTOE WILLDAN ENGINEERING 2401 East Katella Avenue, Suite 300 Anaheim, CA 92806 27. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 28. TERMINATION 28.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by WILLDAN ENGINEERING Page 10 9-13 giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. STANDARD PROVISIONS 29.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 29.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 29.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 29.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 29.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 29.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 29.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 29.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this WILLDAN ENGINEERING Page 11 9-14 Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 29.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 29.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] WILLDAN ENGINEERING Page 12 9-15 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: By: ran C. Harp City Attorney pq1 ATTEST: Date: CITY OF NEWPORT BEACH, a California municipal corporation Date: By: Diane B. Dixon Mayor CONSULTANT:WILLDAN ENGINEERING, a California corporation Date: Bv: Leilani I. Brown Daniel Chow City Clerk Chief Executive Officer Date: By: Stacy McLaughlin Chief Financial Officer [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements WILLDAN ENGINEERING Page 13 9-16 EXHIBIT SCOPE OF SERVICES WILLDAN ENGINEERING Page A-1 9-17 EXHIBIT A SCOPE OF SERVICES ON-CALL PROFESSIONAL ENGINEERING SERVICES —TRAFFIC/ TRANSPORTATION ENGINEERING The following is a list of professional traffic/transportation engineering services that may be required: • Provide full-sized plans, specifications, and estimates for traffic/transportation engineering projects; • Perform general traffic -related studies; • Review/prepare traffic signal timing/coordination plans; • Prepare conceptual design plans/exhibits; • Provide cost estimating and value engineering services; • Prepare/Review transportation impact studies; • Prepare traffic calming (neighborhood) studies; • Review/prepare traffic control plans; • Provide bid support and preparation of record drawings; and • Traffic signal operation observation, review and response (excluding physical traffic signal maintenance and repair); • Review City's traffic control devices and policies for State and Federal Compliance; • Attend meetings as requested; and • Other traffic/transportation engineering -related tasks, as requested by the City. Consultant shall perform the on-call services described in the Scope of Work ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Consultant shall provide a Letter Proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal"). Consultant, its contractors, and subcontractors are prohibited from providing any Work or Services under this Agreement that would require the payment of the prevailing wage rate under any federal, state, or local laws. EXHIBIT B SCHEDULE OF BILLING RATES WILLDAN ENGINEERING Page B-1 9-19 EXHIBIT B FEE SCHEDULE ON-CALL PROFESSIONAL ENGINEERING SERVICES -TRAFFIC /TRANSPORTATION ENGINEERING W"WILLDAN WR.LDAN ENGINEERING Schedule of Hourly Rates Program Manager I Program Manager II Prociram Manaqer III Assistant Engineer I Assistant Engineer II Assistant Engineer III Assistant Engineer IV Associate Encineer I Associate Engineer 11 Associate Engineer III Senior Engineer I Senior Engineer II Senior Engineer III Senior Engineer IV Supervising Engineer Traffic Engineer I Traffic Engineer II Crly Engineer I City Engineer II Deputy Director Director Principal Engineer ' Mr. Reggie Greene to be biked at a r—_ducea rate of S t 55,1',our =or as-needec staff augmentation servioFs $174 $182 $208 $121 $137 $144 $149 $155 $161 $168 $171 $174 $177 $185 $140 $188 $203 $203 $213 $211 $216 $_35 MileageiT eld Vesicle usage wadbe charged at &* rate in accordance with the ctarent FTR m:�eeage re:rtburseinent rate. subject to negotiation. Tre above scee-awe Is ror straight bme. Ove4nrrre Will ce charged at 1.5 times, and Sundays and hDOMys. 2C Mmes tre 5-'Idaid rates. SitsaF4lrcing, repriMictlon. messenger services, and prfMng'e+il 7e t'IvbloM at oosf Fvus rr;een p-rcent i l5%k . A sub-mrsuttant manage�r?rt f?e b'S1f�-er ?ercerr, f 7 S%: 'A91 be added to Te ^JrecZ =5t M at 5w)—co tswarl Wwces to provice lir Vie cost or adtNnls=on, cwsutlatiori, anc ccon:ilmtor. 41081 Technical Aide I S67 Technical Aide II S87 Technical Aisle III $107 CAD Operator 1 $102 CAD Operator II $125 CAD Operator III $139 GIS Analyst 1 $145 GIS Analyst 11 $164 GIS Analyst III $176 Environmental Analyst I $121 Environmental Analyst II $135 Environrrlental Analyst III $144 Environmertal Specialist $155 Desiqner I $145 Designer II $150 Senior Designer 1 $159 Senior Designer 11 $167 Design Manager • 317 C Senior Desicn Manager $176 Project Manager I $15E Project Manager 11 $177 Project Manager III $187 Project Manager IV 5203 Principal Project Manager $207 WR.LDAN ENGINEERING Schedule of Hourly Rates Program Manager I Program Manager II Prociram Manaqer III Assistant Engineer I Assistant Engineer II Assistant Engineer III Assistant Engineer IV Associate Encineer I Associate Engineer 11 Associate Engineer III Senior Engineer I Senior Engineer II Senior Engineer III Senior Engineer IV Supervising Engineer Traffic Engineer I Traffic Engineer II Crly Engineer I City Engineer II Deputy Director Director Principal Engineer ' Mr. Reggie Greene to be biked at a r—_ducea rate of S t 55,1',our =or as-needec staff augmentation servioFs $174 $182 $208 $121 $137 $144 $149 $155 $161 $168 $171 $174 $177 $185 $140 $188 $203 $203 $213 $211 $216 $_35 MileageiT eld Vesicle usage wadbe charged at &* rate in accordance with the ctarent FTR m:�eeage re:rtburseinent rate. subject to negotiation. Tre above scee-awe Is ror straight bme. Ove4nrrre Will ce charged at 1.5 times, and Sundays and hDOMys. 2C Mmes tre 5-'Idaid rates. SitsaF4lrcing, repriMictlon. messenger services, and prfMng'e+il 7e t'IvbloM at oosf Fvus rr;een p-rcent i l5%k . A sub-mrsuttant manage�r?rt f?e b'S1f�-er ?ercerr, f 7 S%: 'A91 be added to Te ^JrecZ =5t M at 5w)—co tswarl Wwces to provice lir Vie cost or adtNnls=on, cwsutlatiori, anc ccon:ilmtor. 41081 EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this WILLDAN ENGINEERING Page C-1 9-21 Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self-insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days' notice of cancellation (except for nonpayment for which ten (10) calendar days' notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Aqreements Between the Parties. The parties hereby agree to the following: WILLDAN ENGINEERING Page C-2 9.22 A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days' advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limitinq. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. WILLDAN ENGINEERING Page C-3 9-23 G. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. WILLDAN ENGINEERING Page C-4 9.24 ATTACHMENT B ON-CALL PROFESSIONAL SERVICES AGREEMENT WITH RK ENGINEERING GROUP, INC. FOR TRAFFIC/TRANSPORTATION ENGINEERING THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is made and entered into as of this 24th day of September, 2019 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and RK ENGINEERING GROUP, INC., a California corporation ("Consultant'), whose address is 4000 Westerly Place, Suite 280, Newport Beach, CA 92660, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide professional traffic and/or transportation engineering services on an on-call/as-needed basis ("Project"). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on September 23, 2024, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED 2.1 Consultant shall perform the on-call services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Consultant shall provide a letter proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal"). The Letter Proposal shall include the following: 2.1.1 A detailed description of the Services to be provided; 2.1.2 The position of each person to be assigned to perform the Services, and the name of the individuals to be assigned, if available; 9-25 and 2.1.3 The estimated number of hours and cost to complete the Services; 2.1.4 The time needed to finish the specific project 2.2 No Services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand -delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written authorization from City. Except as otherwise provided herein, no billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Upon the first anniversary of the Effective Date and upon each anniversary of the Effective Date thereafter, the billing rates set forth in Exhibit B ("Billing Rates") shall RK ENGINEERING GROUP, INC. Page 2 9-26 be adjusted in proportion to changes in the Consumer Price Index, subject to the maximum adjustment set forth below. Such adjustment shall be made by multiplying the Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the Consumer Price Index for the calendar month three (3) months preceding the calendar month for which such adjustment is to be made, and the denominator of which is the value of the Consumer Price Index for the same calendar month immediately prior to Effective Date. The Consumer Price Index to be used in such calculation is the "Consumer Price Index, All Items, 1982-84=100 for All Urban Consumers (CPI -U)", for the Los Angeles - Riverside -Orange County Metropolitan Area, published by the United States Department of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial indices are published, the official index shall be used. If said Consumer Price Index is no longer published at the adjustment date, it shall be constructed by conversion tables included in such new index. In no event, however, shall the amount payable under this Agreement be reduced below the Billing Rates in effect immediately preceding such adjustment. The maximum adjustment increase to the Billing Rates, for any year where an adjustment is made pursuant to this Section, shall not exceed the Consumer Price Index or 2.0% of the Billing Rates in effect immediately preceding such adjustment, whichever is less. 4.3 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.4 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved in writing in advance by City. 4.5 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Robert Khan, P.E., T.E. to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the RK ENGINEERING GROUP, INC. Page 3 9-27 Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. City's Public Works Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws, and legally recognized professional standards. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to RK ENGINEERING GROUP, INC. Page 4 WWI approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this (collectively, the "Indemnified Parties), from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them. 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR 10.1 It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 10.2 Consultant agrees and acknowledges that no individual performing Services or Work pursuant to this Agreement shall: work full-time for more than six (6) RK ENGINEERING GROUP, INC. Page 5 9-29 months, work regular part-time service of at least an average of twenty (20) hours per week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or already be a CalPERS member. 10.3 Consultant must submit to and pass a criminal background investigation by providing a complete set of fingerprints to City prior to commencing or performing Services or Work. Consultant is required to submit any fees for the criminal background investigation according to the City's most current administrative fee schedule or successor document. Fingerprints may be required to be updated every five (5) years. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint -venture or syndicate or co -tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint -venture. RK ENGINEERING GROUP, INC. Page 6 9-30 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents, including all logins and password information to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 17.3 CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability RK ENGINEERING GROUP, INC. Page 7 9-31 resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a CD, and should comply with the City's digital submission requirements for improvement plans available from the City's Public Works Department. The City will provide Consultant with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall be transmitted to City in formats compatible with Microsoft Office and/or viewable with Adobe Acrobat. 17.4 All improvement and/or construction plans shall be prepared with indelible waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting ("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90) days after finalization of the Project. For more detailed requirements, a copy of the City of Newport Beach Standard Design Requirements is available from the City's Public Works Department. 18. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents the Consultant's judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to Consultant or contractor bids or actual cost to City. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 21. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow RK ENGINEERING GROUP, INC. Page 8 9-32 inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 22. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 25. CONFLICTS OF INTEREST 25.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et seq., which (1) require such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibit such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 25.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant shall conform to all requirements therein. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 26. NOTICES 26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third RK ENGINEERING GROUP, INC. Page 9 9-33 business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 26.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Public Works Director Public Works Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 26.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at- Attn: Robert Kahn RK ENGINEERING GROUP, INC. 4000 Westerly Place, Suite 280 Newport Beach 92660 27. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 28. TERMINATION 28.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by RK ENGINEERING GROUP, INC. Page 10 9-34 giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. STANDARD PROVISIONS 29.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 29.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 29.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 29.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 29.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 29.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 29.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 29.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this RK ENGINEERING GROUP, INC. Page 11 9-35 Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 29.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 29.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] RK ENGINEERING GROUP, INC. Page 12 9-36 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: q /[ l M By: aifon C. Harf�u City Attorney ATTEST: Date: Leilani I. Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation Date: By: Diane B. Dixon Mayor CONSULTANT: RK ENGINEERING GROUP, INC., a California corporation Date: By: Robert Khan Chief Executive Officer/ Chief Financial Officer [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements RK ENGINEERING GROUP, INC. Page 13 9-37 EXHIBIT A SCOPE OF SERVICES RK ENGINEERING GROUP, INC. Page A-1 9.38 EXHIBIT A SCOPE OF SERVICES ON-CALL PROFESSIONAL ENGINEERING SERVICES—TRAFFIC/TRANSPORTATION ENGINEERING The following is a list of professional traffic/transportation engineering services that may be required: • Provide full-sized plans, specifications, and estimates for traffic/transportation engineering projects; • Perform general traffic -related studies; • Review/prepare traffic signal timing/coordination plans; • Prepare conceptual design plans/exhibits; • Provide cost estimating and value engineering services; • Prepare/Review transportation impact studies; • Prepare traffic calming (neighborhood) studies; • Review/prepare traffic control plans; • Provide bid support and preparation of record drawings; and • Traffic signal operation observation, review and response (excluding physical traffic signal maintenance and repair); • Review City's traffic control devices and policies for State and Federal Compliance; • Attend meetings as requested; and • Other traffic/transportation engineering -related tasks, as requested by the City. Consultant shall perform the on-call services described in the Scope of Work ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Consultant shall provide a Letter Proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal"). Consultant, its contractors, and subcontractors are prohibited from providing any Work or Services under this Agreement that would require the payment of the prevailing wage rate under any federal, state, or local laws. 9-39 EXHIBIT B SCHEDULE OF BILLING RATES RK ENGINEERING GROUP, INC. Page B-1 9-40 EXHIBIT B FEE SCHEDULE ON-CALL PROFESSIONAL ENGINEERING SERVICES —TRAFFIC/TRANSPORTATION ENGINEERING engineering group, inc. Billing Rates for RK ENGINEERING GROUP, INC. Position Houdy Rate Principal 5180.00 President 5165.00 Associate Principal 5165-00 Senior Associate Engineer/Planner/Designer 5155.00 Principal Engineer/Planner/Designer 5145.00 Associate Er,&.,eer/Planner/Designer 5130.00 Senior Erglreeri'Planner/Designer 5120-00 Engineer/Planner/iDesig.r:er III S1 15.00 Engineer/Planner/Designer II 5105.00 Engineer/Planner/Designer 1 5100.00 Assistant Engineer/Planner/Designer S 90.00 Transportation Analys- 5 70.00 Senior Engineering Technician S 85-00 Engineenrg Technician III S 75.00 Enaireerira Technician II S 65.00 Engineering Technician I S 55.00 E ngineering Aide S 50.00 Office Manager S 70.00 Executive Assistant S 70.00 Administrative Assistant S 55.00 Administrative Aide S 45.00 Clerical Aide S 40.00 Gertera l (t) Reimbursable directtusts, such as reprvductio . supp1 —, Sel+,+ry service, telephone. thavd and trafk Caunt%will be biller dt cast plus ten ? =G) percent. ?2) f -curly r.rtes apply to work tire, travel tame and time spent at public iheamigsarid meeGnys. :as a•,-ertimL1vrark and expert vsitne5s %•nark, the dbove rates may be Creased 50 percent. 9-41 EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this RK ENGINEERING GROUP, INC. Page C-1 9.42 Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self-insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days' notice of cancellation (except for nonpayment for which ten (10) calendar days' notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: RK ENGINEERING GROUP, INC. Page C-2 9-43 A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days' advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. RK ENGINEERING GROUP, INC. Page C-3 9-44 G. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. RK ENGINEERING GROUP, INC. Page C-4 9-45 ATTACHMENT C ON-CALL PROFESSIONAL SERVICES AGREEMENT WITH GANDDINI GROUP, INC. FOR TRAFFIC/TRANSPORTATION ENGINEERING THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is made and entered into as of this 24th day of September, 2019 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and GANDDINI GROUP, INC., a California corporation ("Consultant"), whose address is 550 Parkcenter Drive, Suite 202, Santa Ana, CA 92705, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide professional traffic and/or transportation engineering services on an on-call/as-needed basis ("Project"). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on September 23, 2024, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED 2.1 Consultant shall perform the on-call services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Consultant shall provide a letter proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal"). The Letter Proposal shall include the following: 2.1.1 A detailed description of the Services to be provided; 2.1.2 The position of each person to be assigned to perform the Services, and the name of the individuals to be assigned, if available; Z ,, and 2.1.3 The estimated number of hours and cost to complete the Services; 2.1.4 The time needed to finish the specific project. 2.2 No Services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand -delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written authorization from City. Except as otherwise provided herein, no billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Upon the first anniversary of the Effective Date and upon each anniversary of the Effective Date thereafter, the billing rates set forth in Exhibit B ("Billing Rates") shall GANDDINI GROUP, INC. Page 2 9-47 be adjusted in proportion to changes in the Consumer Price Index, subject to the maximum adjustment set forth below. Such adjustment shall be made by multiplying the Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the Consumer Price Index for the calendar month three (3) months preceding the calendar month for which such adjustment is to be made, and the denominator of which is the value of the Consumer Price Index for the same calendar month immediately prior to Effective Date. The Consumer Price Index to be used in such calculation is the "Consumer Price Index, All Items, 1982-84=100 for All Urban Consumers (CPI -U)", for the Los Angeles - Riverside -Orange County Metropolitan Area, published by the United States Department of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial indices are published, the official index shall be used. If said Consumer Price Index is no longer published at the adjustment date, it shall be constructed by conversion tables included in such new index. In no event, however, shall the amount payable under this Agreement be reduced below the Billing Rates in effect immediately preceding such adjustment. The maximum adjustment increase to the Billing Rates, for any year where an adjustment is made pursuant to this Section, shall not exceed the Consumer Price Index or 2.0% of the Billing Rates in effect immediately preceding such adjustment, whichever is less. 4.3 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.4 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved in writing in advance by City. 4.5 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Giancarlo Jose Ganddini to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the GANDDINI GROUP, INC. Page 3 9-48 Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. City's Public Works Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws, and legally recognized professional standards. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to GANDDINI GROUP, INC. Page 4 9-49 approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this (collectively, the "Indemnified Parties), from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them. 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR 10.1 It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 10.2 Consultant agrees and acknowledges that no individual performing Services or Work pursuant to this Agreement shall: work full-time for more than six (6) GANDDINI GROUP, INC. Page 5 9-50 months; work regular part-time service of at least an average of twenty (20) hours per week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or already be a CalPERS member. 10.3 Consultant must submit to and pass a criminal background investigation by providing a complete set of fingerprints to City prior to commencing or performing Services or Work. Consultant is required to submit any fees for the criminal background investigation according to the City's most current administrative fee schedule or successor document. Fingerprints may be required to be updated every five (5) years. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint -venture or syndicate or co -tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint -venture. GANDDINI GROUP, INC. Page 6 9-51 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents, including all logins and password information to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 17.3 CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability GANDDINI GROUP, INC. Page 7 9-52 resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a CD, and should comply with the City's digital submission requirements for improvement plans available from the City's Public Works Department. The City will provide Consultant with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall be transmitted to City in formats compatible with Microsoft Office and/or viewable with Adobe Acrobat. 17.4 All improvement and/or construction plans shall be prepared with indelible waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting ("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90) days after finalization of the Project. For more detailed requirements, a copy of the City of Newport Beach Standard Design Requirements is available from the City's Public Works Department. 18. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents the Consultant's judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to Consultant or contractor bids or actual cost to City. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 21. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow GANDDINI GROUP, INC. Page 8 9-53 inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 22. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 25. CONFLICTS OF INTEREST 25.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et seq., which (1) require such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibit such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 25.2 If subject to the Act and/or Government Code §§ 1090 et seg., Consultant shall conform to all requirements therein. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 26. NOTICES 26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third GANDDINI GROUP, INC. Page 9 9-54 business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 26.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Public Works Director Public Works Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 26.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Giancarlo Jose Ganddini GANDDINI GROUP, INC. 550 Parkcenter Drive, Suite 202 Santa Ana, CA 92705 27. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 28. TERMINATION 28.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by GANDDINI GROUP, INC. Page 10 9-55 giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination forwhich Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. STANDARD PROVISIONS 29.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 29.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 29.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 29.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 29.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 29.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 29.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 29.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this GANDDINI GROUP, INC. Page 11 Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 29.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 29.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] GANDDINI GROUP, INC. Page 12 9-57 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: By: aron C. Harp City Attorney` ATTEST: Date: Leilani 1. Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation Date: By: Diane B Mayor Dixon CONSULTANT: GANDDINI GROUP, INC., a California corporation Date- ate: By- By: Giancarlo Giancarlo Jose Ganddini Chief Executive Officer/ Chief Financial Officer [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements GANDDINI GROUP, INC. Page 13 U EXHIBIT A SCOPE OF SERVICES GANDDINI GROUP, INC. Page A-1 9.59 EXHIBIT A SCOPE OF SERVICES ON-CALL PROFESSIONAL ENGINEERING SERVICES — TRAFFIC / TRANSPORTATION ENGINEERING The following is a list of professional traffic/transportation engineering services that may be required: • Provide full-sized plans, specifications, and estimates for traffic/transportation engineering projects; • Perform general traffic -related studies; • Review/prepare traffic signal timing/coordination plans; • Prepare conceptual design plans/exhibits; • Provide cost estimating and value engineering services; • Prepare/Review transportation impact studies; • Prepare traffic calming (neighborhood) studies; • Review/prepare traffic control plans; • Provide bid support and preparation of record drawings; and • Traffic signal operation observation, review and response (excluding physical traffic signal maintenance and repair); • Review City's traffic control devices and policies for State and Federal Compliance; • Attend meetings as requested; and • Other traffic/transportation engineering -related tasks, as requested by the City. Consultant shall perform the on-call services described in the Scope of Work ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Consultant shall provide a Letter Proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal"). Consultant, its contractors, and subcontractors are prohibited from providing any Work or Services under this Agreement that would require the payment of the prevailing wage rate under any federal, state, or local laws. •• O EXHIBIT B SCHEDULE OF BILLING RATES GANDDINI GROUP, INC. Page B-1 9.61 FEE SCHEDULE ON-CALL PROFESSIONAL ENGINEERING SERVICES—TRAFFIC/TRANSPORTATION ENGINEERING transportation r noise - air quality I GANDDINI GROUP 2419 STANDARD COMPENSATION SCHEDULE CLASSIFICATION HOURLY RATE Principal $ 150 Environmental Manager S150 Senior Engineer/Planner/Analyst $ 125 Associate Engineer/Planner/Analyst $ 100 Junior Engineer/Planner/Analyst $ 75 technician $ 40 Administrativc Assistant $ 40 9-62 EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this GANDDINI GROUP, INC. Page C-1 9-63 Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self-insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days' notice of cancellation (except for nonpayment for which ten (10) calendar days' notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: GANDDINI GROUP, INC. Page C-2 9-64 A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days' advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. GANDDINI GROUP, INC. Page C-3 9-65 G. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. GANDDINI GROUP, INC. Page C-4 9-66