Loading...
HomeMy WebLinkAbout07 - Agreement with John M. Rabun�EWPORr = CITY OF NEWPORT BEACH City C®uncH Staff Report Agenda Item No. 7 January 28, 2014 TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: Mike Pisani, Municipal Operations Department Co- Director 949 - 644 -3055, mpisani(c�newportbeachca.gov PREPARED BY: Rachell Wilfert, Management Assistant APPROVED: v TITLE: Approve Agreement fo \)eneral Maintenance and Repair Services with John M. Rabun ABSTRACT: The City currently contracts out as- needed general maintenance and repair services to City facilities to supplement the work currently being performed by City employees. RECOMMENDATION: Approve the agreement with John M. Rabun for as- needed general maintenance and repair services for a three year term, and authorize the Mayor and City Clerk to execute the agreement. FUNDING REQUIREMENTS: The current adopted budget includes sufficient funding for this purchase. It will be expensed to the Services — Professional/Technical account in the Municipal Operations Department, Division 3120. DISCUSSION: On November 14, the Municipal Operations Department issued a Request for Proposals (RFP) for building maintenance and repair services. The term of the Agreement for this as- needed service will be for three years with a total amount not to exceed $300,000. Proposals were due on December 3, and the City received three bids in response to the RFP. A committee of evaluators from the Municipal Operations Department reviewed the proposals received and evaluated the firms independent of pricing. The Finance Department's Purchasing Agent calculated the cost score based on the differential in Approve Agreement for Building Maintenance and Repair Services with John M. Rabun January 28, 2014 Page 2 cost between the respondents, with the lowest cost respondent achieving a score of 60 points and the higher cost respondent a lower calculated score. Proposer Technical (out of 40) Cost (out of 60) Total (out of 100) John M. Rabun 132 57.45 189.45 Courage USA 25.33 160 185.33 RT Contractor Corp 26.00 131.76 57.76 John M. Rabun has provided maintenance and repair services for the City of Newport Beach for over 19 years. He provides general maintenance and repairs on an as- needed basis at the Police Station, fire stations, libraries, and other miscellaneous facilities. Although Courage USA had areas of lower cost compared to John M. Rabun, the new company had minimal previous experience with municipalities. Taking into account previous experience with the City and overall pricing, the Municipal Operations Department recommends approval of the Agreement with John M. Rabun for these services. ENVIRONMENTAL REVIEW: Staff recommends the City Council find this action is not subject to the California Environmental Quality Act ( "CEQA ") pursuant to Sections 15060(c)(2) (the activity will not result in a direct or reasonably foreseeable indirect physical change in the environment) and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no potential for resulting in physical change to the environment, directly or indirectly. NOTICING: The agenda item has been noticed according to the Brown Act (72 hours in advance of the meeting at which the City Council considers the item). Submitted by: I' Mike Pisani Co- Director Attachments: A. On -Call Maintenance /Repair Services Agreement with John M. Rabun for As- Needed General Maintenance and Repair Services. Attachment A: On -Call Maintenance /Repair Services Agreement with John M. Rabun for As- Needed General Maintenance and Repair Services ON -CALL MAINTENANCE /REPAIR SERVICES AGREEMENT WITH JOHN M. RABUN FOR AS- NEEDED GENERAL MAINTENANCE AND REPAIR SERVICES THIS ON -CALL MAINTENANCE. /REPAIR SERVICES AGREEMENT ( "Agree- ment') is made and entered into as of this 2nd day of January, 2014 ( "Effective Date'), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ( "City "), and JOHN M. RABUN, a sole proprietor ( "Contractor "), whose address is P.O. Box 422 Corona Del Mar, CA 92625, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Contractor to perform on -call general maintenance and /or repair services for City facilities, piers and public floats (`Project'). C. Contractor possesses the skill, experience, ability, background, certification and knowledge to provide the maintenance and /or repair services described in this Agreement. D. Contractor has examined the location of all proposed work, carefully reviewed and evaluated the specifications set forth by City for the Project, is familiar with all conditions relevant to the performance of services, and has committed to perform all work required for the compensation specified in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on January 31, 2017, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED 2.1 Contractor shall perform the on -call services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ( "Services" or "Work'). Upon written request from the Project Administrator as defined herein, Contractor shall provide a letter proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal'). The Letter Proposal shall include the following: 2.1.1 A detailed description of the Services to be provided; 2.1.2 The position of each person to be assigned to perform the Services, and the name of the individuals to be assigned, if available; 2.13 The estimated number of hours and cost to complete the Services; 2.1.4 The time needed to finish the specific project. 2.2 No Services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Contractor shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Contractor shall perform the Services in accordance with the schedule included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Contractor to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Contractor shall not be responsible for delays due to causes beyond Contractor's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Contractor shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein, not later than two (2) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Contractor's control. 3.4 For all time periods not specifically set forth herein, Contractor shall respond in the most expedient and appropriate manner under the circumstances, by fax, hand - delivery or mail. 4. COMPENSATION TO CONTRACTOR 4.1 City shall pay Contractor for the Services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Except as otherwise provided herein, no rate changes shall be made during the term of this Agreement without the prior written approval of City. Contractor's compensation for all Services performed in accordance with this Agreement, including all reimbursable items, shall not exceed Three Hundred Thousand Dollars and 00/100 ($340,000.04), without prior written amendment to the Agreement. 4.2 Contractor shall submit monthly invoices to City describing the Work performed the preceding month. Contractor's bills shall include the name and /or classification of employee who performed the Work, a brief description of the Services performed and /or the specific task in the Scope of Services to which it relates, the date John M. Rabun Page 2 the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Contractor no later than.thirty (30) calendar days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Contractor only for those costs or expenses specifically identified in Exhibit B to this Agreement and the Letter Proposal, or specifically approved in writing in advance by City. 4.4 Contractor shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with Exhibit B and the Letter Proposal, 51 PROJECT MANAGER 5.1 Contractor shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Contractor has designated John Rabun to be its Project Manager. Contractor shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Contractor, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Contractor warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Municipal Operations Department, City's Municipal Operations Deputy Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. T. CITY'S RESPONSIBILITIES To assist Contractor in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Contractor, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Contractor's Work schedule. 8. TYPE AND INSTALLATION OF MATERIALS /STANDARD OF CARE 8.1 Contractor shall use only the standard materials described in Exhibit A in performing Services under this Agreement. Any deviation from the materials described John M. Rabun Page 3 in Exhibit A shall not be installed or utilized unless approved in advance and in writing by the Project Administrator. 8.2 All of the Services shall be performed by Contractor or under Contractor's supervision. Contractor represents that it possesses the personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with highest industry standards. All Services shat{ be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Contractor certifies that the Work conforms to the requirements of this Agreement and all applicable federal, state and local laws and the industry standard. 8.3 Contractor represents and warrants to City that it has, shall obtain and shall keep in full force and effect during the term hereof, at Its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Contractor to practice its profession. Contractor shall maintain a City of Newport Beach business license during the term of this Agreement. 8.4 Contractor shall not be responsible for delay, nor shall Contractor be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Contractors Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. RESPONSIBILITY FOR DAMAGES OR INJURY 9.1 City and all officers, employees and representatives thereof shall not be responsible in any manner for any loss or damage to any of the materials or other things used or employed in performing the Project or for injury to or death of any person as a result of Contractor's performance of the Services required hereunder; or for damage to property from any cause arising from the performance of the Project by Contractor, or its subcontractors, or its workers, or anyone employed by either of them. 9.2 Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects, obstructions or from any cause arising from Contractor's Work on the Project, or the Work of any subcontractor or supplier selected by Contractor. 9.3 To the fullest extent permitted by law, Contractor shall indemnify, defend and hold harmless City, its City Council, boards and corrimissions, officers, agents, volunteers, and employees (collectively, the "Indemnified Parties ") from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any breach of the terms and conditions of this Agreement, any Work performed or Services provided under this Agreement including, without limitation, defects in workmanship or materials or Contractor's presence or activities conducted on the Project (including the negligent and/or willful acts, errors John M. Rabun Page 4 and /or omissions of Contractor, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). 9A Notwithstanding the foregoing, nothing herein shall be construed to require Contractor to indemnify the Indemnified Parties from any Claim arising from the sole negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by Contractor. 9.5 Contractor shall perform all Work in a manner to minimize public inconvenience and possible hazard, to restore other work areas to their original condition and former usefulness as soon as possible, and to protect public and private property. Contractor shall be liable for any private or public property damaged during the performance of the Work by Contractor or Its agents. 9.6 To the extent authorized by law, as much of the money due Contractor under and by virtue of the Agreement as shall be considered necessary by City may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. 9.7 The rights and obligations set forth in this Section shall survive the termination of this Agreement. 10. INDEPENDENT CONTRACTOR It is understood that City retains Contractor on an independent contractor basis and Contractor is not an agent or employee of City. The manner and means of conducting the Work are under the control of Contractor, .except to the extent they are limited by statute, rule or regulation and the expressed terns of this Agreement. No civil service status or other right of employment shall accrue to Contractor or its employees. Nothing in this Agreement shall be deemed to constitute approval for Contractor or any of Contractor's employees or agents, to be the agents or employees of City, Contractor shall have the responsibility for and control over the means of performing the Work, provided that Contractor is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Contractor as to the details of the performance of the Work or to exercise a measure of control over Contractor shall mean only that Contractor shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Contractor agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with Contractor on the Project. John M. Rabun Page 5 12. CITY POLICY Contractor shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Contractor is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Contractor's indemnification of City, and prior to commencement of Work, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Contractor, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Contractor is a partnership orjoint- venture or syndicate or cotenancy, which shall result in changing the control of Contractor. Control means fifty percent (50 %o) or more of the voting power or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint - venture. 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A and the Letter Proposal. Contractor shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. John M. Rabun Page 6 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Contractor, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Contractor or any other party. Contractor shall, at Contractor's expense, provide such Documents to City upon prior written request. 18. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 19. RECORDS Contractor shall keep records and invoices in connection with the Services to be performed under this Agreement. Contractor shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Contractor under this Agreement. All such records and invoices shall be clearly identifiable. Contractor shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Contractor shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Contractor under this Agreement. 20. WITHHOLDINGS City may withhold payment to Contractor of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Contractor shall not discontinue Work as a result of such withholding. Contractor shall have an immediate right to appeal to the City Manager or his /her designee with respect to such disputed sums. Contractor shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 21. CITY'S RIGHT TO EMPLOY OTHER CONTRACTORS City reserves the right to employ other contractors in connection with the Project. 22. CONFLICTS OF INTEREST 22.1 Contractor or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work John M. Rabun -- _T _ - - -- -- -Page 7 performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 22.2 If subject to the Act, Contractor shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Contractor shall indemnify and hold harmless City for any and all claims for damages resulting from Contractor's violation of this Section. 23. NOTICES 23.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first - class mail, addressed as hereinafter provided. 23.2 All notices, demands, requests or approvals from Contractor to City shall be addressed to City at: Attn: Municipal Operations Deputy Director Municipal Operations Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 233 All notices, demands, requests or approvals from City to Contractor shall be addressed to Contractor at: John M.Rabun 24086 Fawnskin Dr. Corona, CA 92883 24. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Contractor shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Contractor's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Contractor in writing as unsettled at the time of its final request for payment. Contractor and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Contractor shall be required to file any claim Contractor may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). John M. Rabun Page 8 25. TERMINATION 25.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 25.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Contractor. In the event of termination under this Section, City shall pay Contractor for Services satisfactorily performed and costs incurred up to the effective date of termination for which Contractor has not been previously paid. On the effective date of termination, Contractor shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 26. LABOR 26.1 Contractor shall conform with all applicable provisions of state and federal law including, but not limited to, applicable provisions of the federal Fair Labor Standards Act ( "FLSA ") (29 USCA § 201, et seq.). 26.2 Whenever Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Agreement, Contractor shall immediately give written notice to City, and provide all relevant information. 26.3 Contractor represents that all persons working under this Agreement are verified to be U.S. citizens or persons legally authorized to work in the United States. 26.4 To the fullest extent permitted by law, Contractor shall indemnify, defend, and hold harmless City, its City Council, boards.and commissions, officers, agents, volunteers, and employees from loss or damage, including but not limited to attorneys' fees, and other costs of defense by reason of actual or alleged violations of any applicable federal, state and local labor laws or law, rules, and /or regulations. This obligation shall survive the expiration and /or termination of the Agreement. 27. STANDARD PROVISIONS 27.1 Recitals. City and Contractor acknowledge that the above Recitals are true and correct and_ are hereby incorporated by reference. 27.2 Compliance with all Laws. Contractor shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental John M.Rabun Page 9 entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Contractor shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 27.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 27.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 27.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 27.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 27.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Contractor and City and approved as to form by the City Attorney. 27.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 27.9 Controlling Law and Venue. The laws of the State of California shall govem this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 27,10 Equal Opportunity Employment. Contractor represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex, age or any other impermissible basis under law. 27.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 27.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. John M. Rabun Page 10 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: Q, -;Iq - t3 CITY OF NEWPORT BEACH, a California municipal corporation /i By: u 1 t r By: City A to arp V �( P Mayor hN. Hill, II City Attorney ���...111 `_�ttj� ATTEST: CONTRACTOR: John M. Rabun, sole Date: proprietor Date: By: By: L&— Leilani I. brown Jo M. Rabun City Clerk Owner [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements 77 -M. Rabun Page 11 j2tl, EXHIBIT A SCOPE OF SERVICES t vilftl►l;ir o The intent of these specifications is to provide general maintenance and repair services at City facilities, piers and public floats. DESCRIPTION OF PROJECT o Furnish all labor, equipment, materials, and supervision to perform maintenance as described herein including, but not limited to, the following: general carpentry, painting, minor plumbing and electrical repairs, appliance replacement, flooring repairs, assembly of manufactured items, miscellaneous repair Work, and liaison with contractors /vendors. In addition the Contractor will assist with repairs to the City's two piers and ten public floats. WORKING HOURS o Normal working hours shall be between the hours of 7:00 a.m. and 4:00 p.m., Monday through Friday. WORKMANSHIP AND SUPERVISION c Contractor shall maintain a B- contractor's license at all time for the duration of the agreement. MAINTENANCE AND TECHNICAL RESPONSIBILITIES c General Carpentry (removal and installation) • e.g.: Interior and exterior doors, cabinet work c Painting • e.g.: Interior and exterior o Minor Plumbing Repairs • e.g.: Water heater replacement, faucets c Appliance Replacement (removal and installation) e.g.: Dishwasher, refrigerator, icemakers o Minor Electrical Repairs (removal and installation) • e.g.: Light fixtures, ballasts, etc. John M. Rabun Page A -1 o Flooring Repairs (removal and installation) ■ e.g.: Tile replacement, floor sealing o Assembly of Manufactured Items o Miscellaneous Repair Work (removal and installation) ■ e.g.: Window coverings, windows and screens, drywall o Minor Roof Repairs o Liaison with ContractorsNendors o Piers and Public floats ■ Make necessary repairs and upgrades as requested by City staff. ■ In order to ensure quality and long lasting product that will stand up in the marine environment, treated lumber will be used for the under structure and railings, with Trex (composite lumber) being used for the decking and top handrail. o Locations of all City facilities will be provided to the Contractor after the award of the contract. The Contractor will work with the Project Administrator to schedule site meetings and repair requests. John M. Rabun Page A -2 EXHIBIT B SCHEDULE OF BILLING RATES "After hours rate will be any time outside the regular hours of Monday- Friday 7:00 a.m. to 4:00 p.m., this rate also includes weekends and holidays. "Maximum 5% overhead cap for all materials purchased. Project Administrator reserves the right to request that all original receipts of materials be turned in with invoices before Contractor is paid. John M. Rabun Page B -1 EXHIBIT C INSURANCE REQUIREMENTS — MAINTENANCEIREPAIR/ SERVICES 1. Provision of Insurance. Without limiting Contractor's indemnification of City, and prior to commencement of Work, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Contractor agrees to provide insurance in accordance with requirements set forth here. If Contractor uses existing coverage to comply and that coverage does not meet these requirements, Contractor agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Contractor shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Contractor shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. B. General Liability Insurance. Contractor shall maintain commercial general liability Insurance and, if necessary, umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, products - completed operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract) with no endorsement or modification limiting the scope of coverage for liability assumed under a contract. C. Automobile Liability Insurance. Contractor shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Contractor arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented John M. Rabun Page C -1 vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Contractor or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Contractor hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, shall provide or be endorsed to provide that City and its officers, officials, employees, and agents shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self - insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days notice of cancellation (except for nonpayment for which ten (10) calendar days notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: A. Evidence of Insurance. Contractor shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require cornplete, certified copies of all required insurance policies, at anytime. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Contractor sixty (60) calendar days advance written notice of such change. If such change results in substantial additional cost to Contractor, City and Contractor may renegotiate Contractor's compensation. John M.Rabun Page C -2 C. Right to Review Subcontracts. Contractor agrees that upon request, all agreements with subcontractors or others with whom Contractor enters into contracts with on behalf of City will be submitted to City for review. Failure of City to request copies of such agreements will not impose any liability on City, or its employees. D. Enforcement of Agreement Provisions. Contractor acknowledges and agrees that any actual or alleged failure on the part of City to inform Contractor of non - compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. E. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. . F. Self- insured Retentions. Any self- insured retentions must be declared to and approved by City. City reserves the right to require that self- insured retentions be eliminated, lowered, or replaced by a deductible. Self - insurance will not be considered to comply with these requirements unless approved by City. G. City Remedies for Non - Compliance If Contractor or any sub - .consultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Contractor's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City s sole option, be deducted from amounts payable to Contractor or reimbursed by Contractor upon demand. H. Timely Notice of Claims, Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractors performance under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. Contractor's Insurance. Contractor shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. John M. Rabun Page C -3