Loading...
HomeMy WebLinkAboutC-7271-1 - On-Call M/RSA for On-Call Playground Equipment Installation ServicesN r AMENDMENT NO. ONE TO V ON-CALL MAINTENANCE/REPAIR SERVICES AGREEMENT WITH TOT LOT PROS, INC. FOR ON-CALL PLAYGROUND EQUIPMENT INSTALLATION SERVICES THIS AMENDMENT NO. ONE TO ON-CALL MAINTENANCE/REPAIR SERVICES AGREEMENT ("Amendment No. One") is made and entered into as of this 21st day of November, 2019 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and TOT LOT PROS, INC., a California corporation ("Contractor"), whose address is 14688 EI Molino Street, Fontana, CA 92335, and is made with reference to the following: RECITALS A. On January 1, 2018, City and Contractor entered into an On -Call Maintenance/Repair Services Agreement ("Agreement") for Contractor to perform on-call maintenance and/or repair services for City ("Project"). B. The parties desire to enter into this Amendment No. One to extend the term of the Agreement to December 31, 2022, increase the total compensation, update Exhibit B, and amend the Administration, Notices, Prevailing Wage, Conflicts of Interest, and Claims sections. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM Section 1 of the Agreement is amended in its entirety and replaced with the following: "The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2022, unless terminated earlier as set forth herein." 2. COMPENSATION TO CONTRACTOR Exhibit B to the Agreement shall be amended in its entirety and replaced to include the Schedule of Billing Rates, attached hereto as Exhibit B and incorporated herein by reference ("Services" or "Work"). Section 4.1 of the Agreement is amended in its entirety and replaced with the following: "City shall pay Contractor for the Services on a time and expense not -to -exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Except as otherwise provided herein, no rate changes shall be made during the term of this Agreement without the prior written approval of City. Contractor's compensation for all Services performed in accordance with this Agreement, including all reimbursable items, shall not exceed One Hundred Twenty Thousand Dollars and 00/100 ($120,000.00), without prior written amendment to the Agreement." The total amended compensation reflects Contractor's additional compensation for additional Services to be performed in accordance with this Amendment No. One, including all reimbursable items and subconsultant fees, in an amount not to exceed Forty Five Thousand Dollars and 00/100 ($45,000.00). 3. ADMINISTRATION Section 6 of the Agreement is amended in its entirety and replaced with the following: "This Agreement will be administered by the Recreation & Senior Services Department. City's Recreation Manager or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement." 4. PREVAILING WAGE Section 16 of the Agreement is amended in its entirety and replaced with the following: "16.1 Pursuant to the applicable provisions of the Labor Code of the State of California, not less than the general prevailing rate of per diem wages including legal holidays and overtime Work for each craft or type of workman needed to execute the Work contemplated under the Agreement shall be paid to all workmen employed on the Work to be done according to the Agreement by the Contractor and any subcontractor. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the Work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the Agreement. A copy of said determination is available by calling the prevailing wage hotline number (415) 703-4774, and requesting one from the Department of Industrial Relations. The Contractor is required to obtain the wage determinations from the Department of Industrial Relations and post at the job site the prevailing rate or per diem wages. It shall be the obligation of the Contractor or any subcontractor under him/her to comply with all State of California labor laws, rules and regulations and the parties agree that the City shall not be liable for any violation thereof. 16.2 Unless otherwise exempt by law, Contractor warrants that no contractor or subcontractor was listed on the bid proposal for the Services that it is not currently registered and qualified to perform public work. Contractor further warrants that it is currently registered and qualified to perform "public work" pursuant to California Labor Code section 1725.5 or any successor statute thereto and that no contractor or subcontractor will engage in the performance of the Services unless currently registered and qualified to perform public work." TOT LOT PROS, INC. Page 2 CONFLICTS OF INTEREST Section 24 of the Agreement is amended in its entirety and replaced with the following: "24.1 Contractor or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et seq., which (1) require such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibit such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 24.2 If subject to the Act and/or Government Code §§ 1090 et seq., Contractor shall conform to all requirements therein. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Contractor shall indemnify and hold harmless City for any and all claims for damages resulting from Contractor's violation of this Section." 6. NOTICES Section 25.2 is amended in its entirety and replaced with the following: "25.2 All notices, demands, requests or approvals from Contractor to City shall be addressed to City at: Attn: Recreation & Senior Services Director Recreation & Senior Services Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658" 7. CLAIMS Section 26 of the Agreement is amended in its entirety and replaced with the following: "26.1 Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Contractor shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Contractor's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Contractor in writing as unsettled at the time of its final request for payment. Contractor and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Contractor shall be required to file any claim Contractor may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). TOT LOT PROS, INC. Page 3 26.2 To the extent that Contractor's claim is a "Claim" as defined in Public Contract Code section 9204 or any successor statute thereto, the Parties agree to follow the dispute resolution process set forth therein. Any part of such "Claim" remaining in dispute after completion of the dispute resolution process provided for in Public Contract Code section 9204 or any successor statute thereto shall be subject to the Government Claims Act requirements requiring Contractor/Consultant to file a claim in strict conformance with the Government Claims Act. To the extent that Contractor's claim is not a "Claim" as defined in Public Contract Code section 9204 or any successor statute thereto, Contractor shall be required to file such claim with the City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.)." 8. INTEGRATED CONTRACT Except as expressly modified herein, all other provisions, terms, and covenants set forth in the Agreement shall remain unchanged and shall be in full force and effect. [SIGNATURES ON NEXT PAGE] TOT LOT PROS, INC. Page 4 IN WITNESS WHEREOF, the parties have caused this Amendment No. One to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: S p CITY OF NEWPORT BEACH, a California municipal corporation Date: I a -I q - I q By: Q, ' -' P�,.a,,. By: Fo,e'.Aaron C. Harp��q Gr e C Leung City Attorney ��\k Canager ATTEST: Date: !..� !.� r�iruos Leilani 1. Brown City Clerk Attachments: CONTRACTOR: TOT LOT PROS, INC. a California corporation Date: 2-Z/ -/ I By Z z— - Peter E Kleinecke Chief Financial Officer [END OF SIGNATURES] Exhibit B - Schedule of Billing Rates - - --- - - ---------------...- TOT LOT PROS, INC. Page 5 EXHIBIT B SCHEDULE OF BILLING RATES TOT LOT PROS, INC. Page B-1 EXHIBIT B — SCHEDULE OF BILLING RATES PREVAILING WAGE LABOR RATES: Foreman $105 per hour Laborers $95 er hour CONCRETE: Under 2 cubic yards $230 er cubic yard Over 2 cubic yards $165 er cubic yard Concrete pump $1500 DISPOSAL: Dumpsters for dirt $1,400 for 6 tons (Additional $80 per ton up to a total of 12 tons Dumpsters for waste $1,100 for 4 tons (Additional $80 per ton up to a total of 8 tons 2 cubic yard trailer $750 per load EQUIPMENT RENTALS: Reach Forklift $750 per day, plus $225 for delivery and pickup Telescoping Boom Lift $375 per day, plus $225 for delivery and icku Landscape Loader $775 per day, plus $225 for delivery and pickup TEMPORARY SECURITY FENCE: 6' tall, 12' long panels with panel stands $5 per lineal foot RUBBER SURFACE: SBR Cushion Layer $25 per 50lbs ba EPDM Color $90 per 55Ibs ba EPDM Black $25 per 55Ibs bag Cushion Layer Binder $126 per 5 -gallon pail Aromatic Binder for EPDM $131 per 5 -gallon pail Aliphatic Binder for EPDM $270 per 5- allon ail Class II base material for PIP sub -base $2 per square foot 4" thick LOOSE FILL SAFETY SURFACE: Engineered Wood Fiber, Provided and Installed $55 per Cubic Yard ProTour Sand provided and delivered by P.W. Gillibrand $66 per Ton "All other items shall be quoted on a project -specific basis" TOTAL NOT TO EXCEED: $120,000.00 Chong, Matthew From: EXIGIS RiskWorks <notifications@riskworks.com> Sent: Wednesday, December 18, 2019 12:11 PM To: Chong, Matthew, Schmillen, Justin Subject: City of Newport Beach: Notice of Waiver for Tot Lot Pros, Inc. Dear Business Partner, City of Newport Beach has completed its review of the insurance documentation submitted on behalf of Tot Lot Pros, Inc. and has waived its standard insurance requirements. The following comments were provided: Evaluation waived by reviewer No further action is required at this time. You will receive a renewal notice requesting the submission of updated insurance documentation in advance of expiration. If you have any questions, please contact EXIGIS Risk Management Services at support(akxigis.com or 800- 430-1589. Thank you for your cooperation and timely fulfillment of this important request. Sincerely, EXIGIS Risk Management Services On behalf of City of Newport Beach 800-430-1589 supportO,exi ig s.com Organizational Unit: City of Newport Beach -> Recreation & Senior Services Agreement Name: ON-CALL MAINTENANCE/REPAIR SERVICES AGREEMENT FOR ON-CALL PLAYGROUND EQUIPMENT INSTALLATION SERVICES I N r - ON -CALL MAINTENANCE/REPAIR SERVICES AGREEMENT WITH TOT LOT PROS, INC. FOR ON-CALL PLAYGROUND EQUIPMENT INSTALLATION SERVICES THIS ON-CALL MAINTENANCE/REPAIR SERVICES AGREEMENT ("Agreement') is made and entered into as of this 1 st day of January, 2018 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and Tot Lot Pros, Inc., a California corporation ("Contractor"), whose address is 14688 EI Molino Street, Fontana, CA 92335, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Contractor to perform on-call maintenance and/or repair services for City ('Project'). C. Contractor possesses the skill, experience, ability, background, certification and knowledge to provide the maintenance and/or repair services described in this Agreement. D. Contractor has examined the location of all proposed work, carefully reviewed and evaluated the specifications set forth by City for the Project, is familiar with all conditions relevant to the performance of services, and has committed to perform all work required for the compensation specified in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2020, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED 2.1 Contractor shall perform the on-call services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Upon written request from the Project Administrator as defined herein, Contractor shall provide a letter proposal for Services requested by the City (hereinafter referred to as the "Letter Proposal'). The Letter Proposal shall include the following: 2.1.1 A detailed description of the Services to be provided; 2.1.2 The position of each person to be assigned to perform the Services, and the name of the individuals to be assigned, if available; 2.1.3 The estimated number of hours and cost to complete the Services; and 2.1.4 The time needed to finish the specific project. 2.2 No Services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Contractor shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Contractor shall perform the Services in accordance with the schedule included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Contractor to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Contractor shall not be responsible for delays due to causes beyond Contractor's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Contractor shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein, not later than two (2) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Contractor's control. 3.4 For all time periods not specifically set forth herein, Contractor shall respond in the most expedient and appropriate manner under the circumstances, by fax, hand - delivery or mail. 4. COMPENSATION TO CONTRACTOR 4.1 City shall pay Contractor for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Letter Proposal and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Except as otherwise provided herein, no rate changes shall be made during the term of this Agreement without the prior written approval of City. Contractor's compensation for all Services performed in accordance with this Agreement, including all reimbursable items, shall not exceed Seventy Five Thousand Dollars and 001100 ($75,000.00), without prior written amendment to the Agreement. Tot Lot Pros, Inc. Page 2 4.2 Contractor shall submit monthly invoices to City describing the Work performed the preceding month. Contractor's bills shall include the name and/or classification of employee who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Contractor no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Contractor only for those costs or expenses specifically identified in Exhibit B to this Agreement and the Letter Proposal, or specifically approved in writing in advance by City. 4.4 Contractor shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work' means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with Exhibit B and the Letter Proposal. 4.5 Contractor shall provide City with a minimum fourteen (14) days' notice of its dates of installation to enable the City to prepare the installation sites in accordance with the Letter Proposal. The City shall complete site preparation prior to the date of installation, and the site shall thereafter be available for inspection and approval. All costs and expenses related to the site preparation shall be at the sole expense of City. 5. PROJECT MANAGER 5.1 Contractor shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Contractor has designated Jack L. Striegel to be its Project Manager. Contractor shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Contractor, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Contractor warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Recreation & Senior Services Department. City's Recreation & Senior Services Deputy Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. Tot Lot Pros, Inc. Page 3 7. CITY'S RESPONSIBILITIES To assist Contractor in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Contractor, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Contractor's Work schedule. 8. TYPE AND INSTALLATION OF MATERIALS/STANDARD OF CARE 8.1 Contractor shall use only the standard materials described in Exhibit A in performing Services under this Agreement. Any deviation from the materials described in Exhibit A shall not be installed or utilized unless approved in advance and in writing by the Project Administrator. 8.2 All of the Services shall be performed by Contractor or under Contractor's supervision. Contractor represents that it possesses the personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Contractor certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws and legally recognized professional standards. 8.3 Contractor represents and warrants to City that it has, shall obtain and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Contractor to practice its profession. Contractor shall maintain a City of Newport Beach business license during the term of this Agreement. 8.4 Contractor shall not be responsible for delay, nor shall Contractor be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Contractor's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 8.5 Contractor shall perform all Services in a manner to minimize public inconvenience and possible hazard, to restore other work areas to their original condition and former usefulness as soon as possible, and to protect public and private property. Contractor shall perform services as specified in the Letter Proposal to limit impacts to traffic during the system installation period. Contractor shall be liable for any private or public property damaged during the performance of the Services. 8.6 Contractor shall provide traffic control and access in accordance with Section 7-10 of the State Standard Specifications and the latest edition of the Work Area Traffic Control Handbook (WATCH), as published by Building News, Inc. Tot Lot Pros, Inc. Page 4 8.7 Traffic control and detours shall at a minimum meet the following requirements: 8.7.1 Emergency vehicle access shall be maintained at all times. 8.7.2 The locations and wordings of all barricades, signs, delineators, lights, warning devices, parking restrictions, and any other required details shall ensure that all pedestrian and vehicular traffic will be handled in a safe manner with a minimum of inconvenience to the public. 8.7.3 All advanced warning sign installations shall be reflectorized and/or lighted. 8.7.4 Traffic signal system shutdown or planned "red flash" shall be limited to 4 -hour periods between the hours of 9:00 a.m. and 3:00 p.m. on weekdays (Monday through Thursday), except as authorized by the Project Administrator. 8.7.5 "STOP AHEAD" and "STOP" signs shall be furnished by the Contractor and shall conform to the provisions in Section 12-3.06, "Construction Area Signs," of the State Standard Specifications except that the base material for the signs shall not be plywood. Two "STOP AHEAD" signs and two "STOP" signs shall be placed for each direction of traffic. Locations of the signs shall be per the WATCH manual. 9. RESPONSIBILITY FOR DAMAGES OR INJURY 9.1 City and all officers, employees and representatives thereof shall not be responsible in any manner for any loss or damage to any of the materials or other things used or employed in performing the Project or for injury to or death of any person as a result of Contractor's performance of the Services required hereunder; or for damage to property from any cause arising from the performance of the Project by Contractor, or its subcontractors, or its workers, or anyone employed by either of them. 9.2 Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects, obstructions or from any cause arising from Contractor's Work on the Project, or the Work of any subcontractor or supplier selected by Contractor. 9.3 To the fullest extent permitted by law, Contractor shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, and employees (collectively, the "Indemnified Parties") from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims"), which may arise from or in any manner relate (directly or indirectly) to any breach of the terms and conditions of this Agreement, any Work performed or Services provided under this Agreement including, without limitation, defects in workmanship or materials or Contractor's presence or activities conducted on Tot Lot Pros, Inc. Page 5 the Project (including the negligent and/or willful acts, errors and/or omissions of Contractor, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). 9.4 Notwithstanding the foregoing, nothing herein shall be construed to require Contractor to indemnify the Indemnified Parties from any Claim arising from the sole negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by Contractor. 9.5 Contractor shall perform all Work in a manner to minimize public inconvenience and possible hazard, to restore other work areas to their original condition and former usefulness as soon as possible, and to protect public and private property. Contractor shall be liable for any private or public property damaged during the performance of the Work by Contractor or its agents. 9.6 To the extent authorized by law, as much of the money due Contractor under and by virtue of the Agreement as shall be considered necessary by City may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. 9.7 The rights and obligations set forth in this Section shall survive the termination of this Agreement. 10. INDEPENDENT CONTRACTOR It is understood that City retains Contractor on an independent contractor basis and Contractor is not an agent or employee of City. The manner and means of conducting the Work are under the control of Contractor, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Contractor or its employees. Nothing in this Agreement shall be deemed to constitute approval for Contractor or any of Contractor's employees or agents, to be the agents or employees of City. Contractor shall have the responsibility for and control over the means of performing the Work, provided that Contractor is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Contractor as to the details of the performance of the Work or to exercise a measure of control over Contractor shall mean only that Contractor shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Contractor agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with Contractor on the Project. Tot Lot Pros, Inc. Page 6 12. CITY POLICY Contractor shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Contractor is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Contractor's indemnification of City, and prior to commencement of Work, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement orfor other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. BONDING 15.1 For any Letter Proposal accepted by City of over Twenty Five Thousand Dollars and 00/100 ($25,000.00), Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement: (1) a Labor and Materials Payment Bond in the amount of one hundred percent (100%) of the total amount to be paid Contractor as set forth in any Letter Proposal accepted by City of over Twenty Five Thousand Dollars and 00/100 ($25,000.00), and in the form attached hereto as Exhibit D which is incorporated herein by this reference; and (2) a Faithful Performance Bond in the amount of one hundred percent (100%) of the total amount to be paid Contractor as set forth in any Letter Proposal accepted by City of over Twenty Five Thousand Dollars and 00/100 ($25,000.00), and in the form attached hereto as Exhibit E which is incorporated herein by this reference. 15.2 The Labor and Materials Payment Bond and Faithful Performance Bond shall be issued by an insurance organization or surety (1) currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, (2) listed as an acceptable surety in the latest revision of the Federal Register Circular 570, and (3) assigned a Policyholders' Rating A (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide: Property - Casualty. 15.3 Contractor shall deliver, concurrently with City's approval of any Letter Proposal over Twenty Five Thousand Dollars and 00/100 ($25,000.00), the Labor and Materials Payment Bond and Faithful Performance Bond, a certified copy of the "Certificate of Authority" of the Insurer or Surety issued by the Insurance Commissioner, which authorizes the Insurer or Surety to transact surety insurance in the State of California. Tot Lot Pros, Inc. Page 7 16. PREVAILING WAGES Pursuant to the applicable provisions of the Labor Code of the State of California, not less than the general prevailing rate of per diem wages including legal holidays and overtime Work for each craft or type of workman needed to execute the Work contemplated under the Agreement shall be paid to all workmen employed on the Work to be done according to the Agreement by the Contractor and any subcontractor. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the Work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the Agreement. A copy of said determination is available by calling the prevailing wage hotline number (415) 703-4774, and requesting one from the Department of Industrial Relations. The Contractor is required to obtain the wage determinations from the Department of Industrial Relations and post at the job site the prevailing rate or per diem wages. It shall be the obligation of the Contractor or any subcontractor under him/her to comply with all State of California labor laws, rules and regulations and the parties agree that the City shall not be liable for any violation thereof. 17. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Contractor, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Contractor is a partnership or joint -venture or syndicate or cotenancy, which shall result in changing the control of Contractor. Control means fifty percent (50%) or more of the voting power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint -venture. 18. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A and the Letter Proposal. Contractor shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 19. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents"), prepared or caused to be prepared by Contractor, its officers, employees, agents and subcontractors, in the course of implementing this Tot Lot Pros, Inc. Page 8 Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Contractor or any other party. Contractor shall, at Contractor's expense, provide such Documents to City upon prior written request. 20. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 21. RECORDS Contractor shall keep records and invoices in connection with the Services to be performed under this Agreement. Contractor shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Contractor under this Agreement. All such records and invoices shall be clearly identifiable. Contractor shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Contractor shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Contractor under this Agreement. 22. WITHHOLDINGS City may withhold payment to Contractor of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Contractor shall not discontinue Work as a result of such withholding. Contractor shall have an immediate right to appeal to the City Manager or his/her designee with respect to such disputed sums. Contractor shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. CITY'S RIGHT TO EMPLOY OTHER CONTRACTORS City reserves the right to employ other contractors in connection with the Project. 24. CONFLICTS OF INTEREST 24.1 Contractor or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act'), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. Tot Lot Pros, Inc. Page 9 24.2 If subject to the Act, Contractor shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Contractor shall indemnify and hold harmless City for any and all claims for damages resulting from Contractor's violation of this Section. 25. NOTICES 25.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 25.2 All notices, demands, requests or approvals from Contractor to City shall be addressed to City at: Attn: Recreation & Senior Services Deputy Director Recreation & Senior Services Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 25.3 All notices, demands, requests or approvals from City to Contractor shall be addressed to Contractor at: Attn: Jack L. Striegel Tot Lot Pros, Inc. 14688 EI Molino Street Fontana, CA 92335 26. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Contractor shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Contractor's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Contractor in writing as unsettled at the time of its final request for payment. Contractor and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Contractor shall be required to file any claim Contractor may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 27. TERMINATION 27.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in Tot Lot Pros, Inc. Page 10 default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 27.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Contractor. In the event of termination under this Section, City shall pay Contractor for Services satisfactorily performed and costs incurred up to the effective date of termination for which Contractor has not been previously paid. On the effective date of termination, Contractor shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 28. LABOR 28.1 Contractor shall conform with all applicable provisions of state and federal law including, but not limited to, applicable provisions of the federal Fair Labor Standards Act ("FLSK) (29 USCA § 201, et seq.). 28.2 Whenever Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Agreement, Contractor shall immediately give written notice to City, and provide all relevant information. 28.3 Contractor represents that all persons working under this Agreement are verified to be U.S. citizens or persons legally authorized to work in the United States. 28.4 To the fullest extent permitted by law, Contractor shall indemnify, defend, and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, and employees from loss or damage, including but not limited to attorneys' fees, and other costs of defense by reason of actual or alleged violations of any applicable federal, state and local labor laws or law, rules, and/or regulations. This obligation shall survive the expiration and/or termination of the Agreement. 29. STANDARD PROVISIONS 29.1 Recitals. City and Contractor acknowledge that the above Recitals are true and correct and are hereby incorporated by reference. 29.2 Compliance with all Laws. Contractor shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Contractor shall conform to applicable City, Tot Lot Pros, Inc. Page 11 county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 29.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 29.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 29.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 29.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Contractor and City and approved as to form by the City Attorney. 29.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 29.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 29.10 Equal Opportunity Employment. Contractor represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 29.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] Tot Lot Pros, Inc. Page 12 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE 0 Aaron C. H rp ��•aa.�} City Attorney ATTEST: Date: �2•�• 11 By. 414-1, Leilani I. Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation ra Senior Services Director CONTRACTOR: Tot Lot Pros, Inc., a California corporati Date:)- -', - -!% ffck L. St iegel Chief Excutiv fficer Date: /,)-/3 -/'�? By: f -/._ Peter E. Kleinecke Chief Financial Officer [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements Exhibit D — Labor and Materials Payment Bond Exhibit E — Faithful Performance Bond Tot Lot Pros, Inc. Page 13 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Kap ge-,f no f (41?y ) ss. On i 2 11 '3 % t o t 2Q�Z before me, M (✓TI v� Notary Public, personally appeared Y2 (et E• YJtine(W2 $i VIP vl[l-L j who proved to me on the basis of satisfactory evidence to be the person(s whose name(s) isvi' subscribed to the within instrument and acknowledged to me that he/she t e executed the same in his/her/ of authorized capacity(ies), and that by his/her/ti r'I signatures(s) on the instrument the person s), or the entity upon behalf of which the persons acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. 4 J22 J?�- ;e Signature yA� ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of )ss. u►w.+ 0, M. MCTAGUI Notary Public -California '? San Bernardino County Commission X 220895 My Comm. Expires Jun 24.2021 (seal) On , 20 before me, Notary Public, personally appeared proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signatures(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (seal) Tot Lot Pros, Inc. Page D-3 N) EXHIBIT SCOPE OF SERVICES Tot Lot Pros, Inc. Page A-1 EXHIBIT A — SCOPE OF SERVICES 1. Minimum Standards Contractor shall maintain possession of the following certifications by relevant members of the project team assigned to City projects: 1.1 CPS] certified (Certified Playground Safety Inspector) 1.2 LSI certified (Landscape Structures Incorporated) 1.3 Contractors License - at least a "B" with a D34 (prefabricated equipment) and D12 (synthetic products / rubber surfacing) 2. Scope of Services The City may engage Contractor to perform the following services on an as -needed or on-call basis: 2.1 Consulting City staff on matters related to the replacement or installation of playground equipment; 2.2 Advising City staff on new trends and offerings related to playground equipment; 2.3 Providing pricing and project scope related to playground equipment installation at the City's various parks and community centers; 2.4 Receiving or otherwise taking custody of playground equipment procured by the City; 2.5 Performing installation, maintenance and/or repair services related to City playground equipment, while maintaining adherence to Prevailing Wage standards as set forth by the State of California. EXHIBIT B SCHEDULE OF BILLING RATES Tot Lot Pros, Inc. Page B-1 EXHIBIT B — SCHEDULE OF BILLING RATES PREVAILING WAGE LABOR RATES: Foreman $105 per hour Laborers $95 per hour CONCRETE: Under 2 cubic yards $230 per cubic yard Over 2 cubic yards $165 per cubic yard Concrete pump $1500 DISPOSAL: Dumpsters for dirt $1,400 for 6 tons (Additional $80 per ton up to a total of 12 tons Dumpsters for waste $1,100 for 4 tons (Additional $80 per ton up to a total of 8 tons 2 cubic yard trailer $750 per load EQUIPMENT RENTALS: Reach Forklift $750 per day, plus $225 for delivery and pickup Telescoping Boom Lift $375 per day, plus $225 for delivery and pickup Landscape Loader $775 per day, plus $225 for delivery and icku TEMPORARY SECURITY FENCE: 6' tall, 12' long panels with panel stands $5 per lineal foot RUBBER SURFACE: SBR Cushion Layer $25 per 50lbs ba EPDM Color $90 per 55lbs ba EPDM Black $25 per 55lbs ba Cushion Layer Binder $126 per 5 -gallon pail Aromatic Binder for EPDM $131 per 5 -gallon pail Aliphatic Binder for EPDM $270 per 5 -gallon pail Class II base material for PIP sub -base $2 per square foot 4" thick LOOSE FILL SAFETY SURFACE: Engineered Wood Fiber, Provided and Installed $55 per Cubic Yard ProTour Sand provided and delivered by P.W. Gillibrand $66 per Ton **All other items shall be quoted on a project -specific basis* TOTAL NOT TO EXCEED: $75,000.00 EXHIBIT C INSURANCE REQUIREMENTS — MAINTENANCE/REPAIR/JANITORIAL SERVICES 1. Provision of Insurance. Without limiting Contractor's indemnification of City, and prior to commencement of Work, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Contractor agrees to provide insurance in accordance with requirements set forth here. If Contractor uses existing coverage to comply and that coverage does not meet these requirements, Contractor agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Contractor shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Contractor shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers and employees. B. General Liability Insurance. Contractor shall maintain commercial general liability insurance and, if necessary, umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, products -completed operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Contractor shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Contractor arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented Tot Lot Pros, Inc. Page C-1 vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers and employees or shall specifically allow Contractor or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Contractor hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subcontractors. B. Additional Insured Status. All liability policies including general liability, products and completed operations, excess liability, pollution liability, and automobile liability, if required, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers and employees shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self-insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days notice of cancellation (except for nonpayment for which ten (10) calendar days notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: A. Evidence of Insurance. Contractor shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Contractor sixty (60) calendar days advance written notice of such change. If such change results in substantial Tot Lot Pros, Inc. Page C-2 additional cost to Contractor, City and Contractor may renegotiate Contractor's compensation. C. Right to Review Subcontracts. Contractor agrees that upon request, all agreements with subcontractors or others with whom Contractor enters into contracts with on behalf of City will be submitted to City for review. Failure of City to request copies of such agreements will not impose any liability on City, or its employees. Contractor shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Contractor shall ensure that City is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a format at least as broad as CG 20 38 04 13. D. Enforcement of Agreement Provisions. Contractor acknowledges and agrees that any actual or alleged failure on the part of City to inform Contractor of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. E. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Contractor maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. F. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. G. City Remedies for Non -Compliance. If Contractor or any subcontractor fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Contractor's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Contractor or reimbursed by Contractor upon demand. H. Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractor's Tot Lot Pros, Inc. Page C-3 performance under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. Contractor's Insurance. Contractor shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. Tot Lot Pros, Inc. Page C-4 CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach. * Date Received: 4/14/17 Dept./Contact Received From: Teri Date Completed: 4/14/17 Sent to: Teri By: Alicia Company/Person required to have certificate: Tot Lot Pros, Inc. Type of contract: GENERAL LIABILITY EFFECTIVE/EXPIRATION DATE: 4/5/17-4/5/18 All Others A. INSURANCE COMPANY: James River Insurance Company B. AM BEST RATING (A-: VII or greater): A: IX C. ADMITTED Company (Must be California Admitted): Is Company admitted in California? ❑ Yes ®No D. LIMITS (Must be $1 M or greater): What is limit provided? 1,000,000/2,000,000 E. ADDITIONAL INSURED ENDORSEMENT — please attach ® Yes ❑ No F. PRODUCTS AND COMPLETED OPERATIONS (Must include): Is it included? (completed Operations status does not apply to Waste Haulers or Recreation) ® Yes ❑ No G. ADDITIONAL INSURED FOR PRODUCTS AND COMPLETED OPERATIONS ENDORSEMENT (completed Operations status does not apply to Waste Haulers) ® Yes ❑ No H. ADDITIONAL INSURED WORDING TO INCLUDE (The City its officers, officials, employees and volunteers): Is it included? ® Yes ❑ No I. PRIMARY & NON-CONTRIBUTORY WORDING (Must be included): Is it included? ® Yes ❑ No J. CAUTION! (Confirm that loss or liability of the named insured is not limited solely by their negligence) Does endorsement include "solely by negligence" wording? ❑ Yes ® No K. ELECTED SCMAF COVERAGE (RECREATION ONLY): ® N/A ❑ Yes ❑ No L. NOTICE OF CANCELLATION: ❑ N/A ® Yes ❑ No II. AUTOMOBILE LIABILITY EFFECTIVE/EXPIRATION DATE: 4/5/17-4/5/18 A. INSURANCE COMPANY: American Fire and Casualty Company B. AM BEST RATING (A-: VII or greater) A: XV C. ADMITTED COMPANY (Must be California Admitted): Is Company admitted in California? ® Yes ❑ No D. LIMITS - If Employees (Must be $1M min. BI & PD and $500,000 UM, $2M min for Waste Haulers): What is limits provided? 1,000,000 E LIMITS Waiver of Auto Insurance / Proof of coverage (if individual) (What is limits provided?) N/A F. PRIMARY & NON-CONTRIBUTORY WORDING (For Waste Haulers only): ® N/A ❑ Yes ❑ No G. HIRED AND NON -OWNED AUTO ONLY: ❑ N/A ® Yes ❑ No H. NOTICE OF CANCELLATION: ❑ N/A 2 Yes ❑ No III. WORKERS' COMPENSATION EFFECTIVE/EXPIRATION DATE: 4/5/1 A. INSURANCE COMPANY: Everest National Insurance Company B. AM BEST RATING (A-: VII or greater): A+:XV C. ADMITTED Company (Must be California Admitted): ® Yes El No D. WORKERS' COMPENSATION LIMIT: Statutory ®Yes El No E. EMPLOYERS' LIABILITY LIMIT (Must be $1M or reater greater) 1,000,000 F. WAIVER OF SUBROGATION (To include): Is it included? ® Yes El No G. SIGNED WORKERS' COMPENSATION EXEMPTION FORM: ®N/A ❑ Yes EJ No H. NOTICE OF CANCELLATION: ❑ N/A ®Yes ❑ No ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED IV. PROFESSIONAL LIABILITY V POLLUTION LIABILITY V BUILDERS RISK HAVE ALL ABOVE REQUIREMENTS BEEN MET? IF NO WHICH ITEMS NEED TO BE COMPLETED? Approved: Agent of Alliant Insurance Services Broker of record for the City of Newport Beach 4/14/17 ® N/A ❑ Yes ❑ No ® N/A ❑ Yes ❑ No ® N/A ❑ Yes ❑ No ® Yes ❑ No RISK MANAGEMENT APPROVAL REQUIRED (Non -admitted carrier rated less than Self Insured Retention or Deductible greater than $.) ❑ N/A ❑ Yes ❑ No Reason for Risk Management approval/exception/waiver: Risk Management approval needed for non -admitted status of general liability carrier. 4/14/16 Sheri Approved, Approved: Risk Management Subject to the terms of the contract.