Loading...
HomeMy WebLinkAboutC-8020-3 - PSA for Lower Sunset View ParkTHIS AMENDMENT NO. ONE TO PROFESSIONAL SERVICES AGREEMENT ("Amendment No. One") is made and entered into as of this 16th day of December, 2019 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and URBAN RESOURCE CORPORATION, a California corporation ("Consultant"), whose address is 23 Mauchly, Suite 110, Irvine, California 92618, and is made with reference to the following: RECITALS A. On July 1, 2018, City and Consultant entered into a Professional Services Agreement ("Agreement") for engineering services relating to the Lower Sunset View Park Project ("Project"). B. The parties desire to enter into this Amendment No. One to reflect additional Services not included in the Agreement, to extend the term of the Agreement to December 31, 2020, to increase the total compensation, and to update the Insurance Requirements as outlined in Exhibit C. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM Section 1 of the Agreement is amended in its entirety and replaced with the following: "The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2020, unless terminated earlier as set forth herein." 2. SERVICES TO BE PERFORMED Exhibit A to the Agreement shall be supplemented to include the Scope of Services, attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Exhibit A to the Agreement and Exhibit A to this Amendment No. One shall collectively be known as "Exhibit A." The City may elect to delete certain Services within the Scope of Services at its sole discretion. 3. COMPENSATION TO CONSULTANT Section 4.1 of the Agreement is amended in its entirety and replaced with the following: "City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Fifty Seven Thousand O N O 00 AMENDMENT NO. ONE TO CJ PROFESSIONAL SERVICES AGREEMENT WITH URBAN RESOURCE CORPORATION FOR LOWER SUNSET VIEW PARK THIS AMENDMENT NO. ONE TO PROFESSIONAL SERVICES AGREEMENT ("Amendment No. One") is made and entered into as of this 16th day of December, 2019 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and URBAN RESOURCE CORPORATION, a California corporation ("Consultant"), whose address is 23 Mauchly, Suite 110, Irvine, California 92618, and is made with reference to the following: RECITALS A. On July 1, 2018, City and Consultant entered into a Professional Services Agreement ("Agreement") for engineering services relating to the Lower Sunset View Park Project ("Project"). B. The parties desire to enter into this Amendment No. One to reflect additional Services not included in the Agreement, to extend the term of the Agreement to December 31, 2020, to increase the total compensation, and to update the Insurance Requirements as outlined in Exhibit C. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM Section 1 of the Agreement is amended in its entirety and replaced with the following: "The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2020, unless terminated earlier as set forth herein." 2. SERVICES TO BE PERFORMED Exhibit A to the Agreement shall be supplemented to include the Scope of Services, attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Exhibit A to the Agreement and Exhibit A to this Amendment No. One shall collectively be known as "Exhibit A." The City may elect to delete certain Services within the Scope of Services at its sole discretion. 3. COMPENSATION TO CONSULTANT Section 4.1 of the Agreement is amended in its entirety and replaced with the following: "City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Fifty Seven Thousand Three Hundred Ninety Dollars and 00/100 ($57,390.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City." The total amended compensation reflects Consultant's additional compensation for additional Services to be performed in accordance with this Amendment No. One, including all reimbursable items and subconsultant fees, in an amount not to exceed One Thousand Eight Hundred Forty Dollars and 00/100 ($1,840.00). 4. INSURANCE Exhibit C to the Agreement, as referenced in Section 14 of the Agreement, is amended in its entirety and replaced with Exhibit C attached to this Amendment No. One. 5. INTEGRATED CONTRACT Except as expressly modified herein, all other provisions, terms, and covenants set forth in the Agreement shall remain unchanged and shall be in full force and effect. [SIGNATURES ON NEXT PAGE] Urban Resource Corporation Page 2 IN WITNESS WHEREOF, the parties have caused this Amendment No. One to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: 12 11 (o /101Q1 By: ly�- F'or . Aaron C. Harp 00(1'r6'i1 City Attorney ATTEST: Date: 1,/Q AU By: 41r Leilani I. Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation Date: 1--10-749lj By"4ZOA XIvidl. Webb Public Works Director CONSULTANT: Urban Resource Corporation, a California corporation Date: By: Signed in Counterpart Jay Ruby President Date: Signed in Counterpart By: Martin Aguerre Secretary [END OF SIGNATURES] Attachments: Exhibit A - Scope of Services Exhibit C - Insurance Requirements Urban Resource Corporation Page 3 IN WITNESS WHEREOF, the parties have caused this Amendment No. One to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date:/ 1 10% CITY OF NEWPORT BEACH, a California municipal corporation By: 06-- 4'ti By: Far .Aaron C. Harp David A. Webb City Attorney Public Works Director ATTEST: CONSULTANT: Urban Resource Date: Corporation, a California corporation Date: 12 117 By: By: Leilani I. Brown Jay R y City Clerk President Date: (2 ( 2:) ( z- t c By: Martin Ague re Secretary [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit C — Insurance Requirements Urban Resource Corporation Page 3 EXHIBIT A SCOPE OF SERVICES Consultant's work shall consist of the following professional engineering services: 1. Additional Engineering Services Complete additional engineering services beyond original scope for the revised staircase, wetland and dog park and knoll design revisions. Includes concept plans, revised CAD design layouts, earthwork, costs, sections and exhibits to City. Urban Resource Corporation Page A-1 EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this Urban Resource Corporation Page C-1 Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self-insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days' notice of cancellation (except for nonpayment for which ten (10) calendar days' notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: Urban Resource Corporation Page C-2 A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. The certificates and endorsements for each insurance policy shall be signed by a person authorized by that insurer to bind coverage on its behalf. At least fifteen (15) days prior to the expiration of any such policy, evidence of insurance showing that such insurance coverage has been renewed or extended shall be filed with the City. If such coverage is cancelled or reduced, Consultant shall, within ten (10) days after receipt of written notice of such cancellation or reduction of coverage, file with the City evidence of insurance showing that the required insurance has been reinstated or has been provided through another insurance company or companies. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days' advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. Urban Resource Corporation Page C-3 F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. G. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. Urban Resource Corporation Page C-4 Nl 0 N a PROFESSIONAL SERVICES AGREEMENT WITH URBAN RESOURCE CORPORATION FOR V LOWER SUNSET VIEW PARK THIS PROFESSIONAL SERVICES AGREEMENT ("Agreement') is made and entered into as of this 1st day of July, 2018 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and URBAN RESOURCE CORPORATION, a California corporation ("Consultant'), whose address is 23 Mauchly, Suite 110, Irvine, California 92618, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide engineering services relating to the Lower Sunset View Park Project ('Project'). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2019, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). City may elect to delete certain Services within the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand -delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Fifty Five Thousand Five Hundred Fifty Dollars and 00/100 ($55,550.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement or specifically approved in writing in advance by City. 4.4 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Urban Resource Corporation Page 2 Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Jay Ruby to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. City's Public Works Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work Urban Resource Corporation Page 3 conforms to the requirements of this Agreement, all applicable federal, state and local laws, and legally recognized professional standards. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this (collectively, the "Indemnified Parties), from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them. 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No Urban Resource Corporation Page 4 civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint -venture or syndicate or co -tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50%) or more of the voting Urban Resource Corporation Page 5 power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint -venture. 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents, including all logins and password information to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 17.3 CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; Urban Resource Corporation Page 6 (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a CD, and should comply with the City's digital submission requirements for improvement plans available from the City's Public Works Department. The City will provide Consultant with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall be transmitted to City in formats compatible with Microsoft Office and/or viewable with Adobe Acrobat. 17.4 All improvement and/or construction plans shall be prepared with indelible waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting ("CADD") and Tagged Image File Format (tiff) files of all final sheets within ninety (90) days after finalization of the Project. For more detailed requirements, a copy of the City of Newport Beach Standard Design Requirements is available from the City's Public Works Department. 18. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents the Consultant's judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to Consultant or contractor bids or actual cost to City. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 21. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, Urban Resource Corporation Page 7 expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 22. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 25. CONFLICTS OF INTEREST 25.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et seq., which (1) require such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibit such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 25.2 If subject to the Act and/or Government Code §§ 1090 et seg., Consultant shall conform to all requirements therein. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. Urban Resource Corporation Page 8 26. NOTICES 26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 26.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Public Works Director Public Works Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 26.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Jay Ruby Urban Resource Corporation 23 Mauchly, Suite 110 Irvine, CA 92618 27. CLAIMS 27.1 Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 27.2 To the extent that Consultant's claim is a "Claim" as defined in Public Contract Code section 9204 or any successor statute thereto, the Parties agree to follow the dispute resolution process set forth therein. Any part of such "Claim" remaining in dispute after completion of the dispute resolution process provided for in Public Contract Code section 9204 or any successor statute thereto shall be subject to the Government Claims Act requirements requiring Consultant to file a claim in strict conformance with the Government Claims Act. To the extent that Contractor/Consultant's claim is not a "Claim" as defined in Public Contract Code section 9204 or any successor statute thereto, Consultant shall be required to file such Urban Resource Corporation Page 9 claim with the City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 28. TERMINATION 28.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. PREVAILING WAGES 29.1 Pursuant to the applicable provisions of the Labor Code of the State of California, not less than the general prevailing rate of per diem wages including legal holidays and overtime Work for each craft or type of workman needed to execute the Work contemplated under the Agreement shall be paid to all workmen employed on the Work to be done according to the Agreement by the Consultant and any subcontractor. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the Work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the Agreement. A copy of said determination is available by calling the prevailing wage hotline number (415) 703-4774, and requesting one from the Department of Industrial Relations. The Consultant is required to obtain the wage determinations from the Department of Industrial Relations and post at the job site the prevailing rate or per diem wages. It shall be the obligation of the Consultant or any subcontractor under him/her to comply with all State of California labor laws, rules and regulations and the parties agree that the City shall not be liable for any violation thereof. 29.2 Unless otherwise exempt by law, Consultant warrants that no contractor or subcontractor was listed on the bid proposal for the Services that it is not currently registered and qualified to perform public work. Consultant further warrants that it is Urban Resource Corporation Page 10 currently registered and qualified to perform "public work' pursuant to California Labor Code section 1725.5 or any successor statute thereto and that no contractor or subcontractor will engage in the performance of the Services unless currently registered and qualified to perform public work. 30. STANDARD PROVISIONS 30.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 30.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 30.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 30.4 Integrated Contract, This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 30.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 30.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 30.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 30.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 30.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to Urban Resource Corporation Page 11 this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 30.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 30.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 30.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] Urban Resource Corporation Page 12 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: By: V.rAkbn C. Harp 1-5 -k% City Attorney ATTEST: Date: 0 (� D Q'I l_ /O By:&i4t--1 Leilani I. Brown City Clerk CITY OF NEWPORT BEACH, a California municip I corporation Date: By: r Davi ebb Public Works Director CONSULTANT: Urban Resource Corporation, a California corporation Signed in Counterpart Jay Ruby President By: Signed in Counterp& Martin Aguerre Secretary [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements Urban Resource Corporation Page 13 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: o� Z6 • t 8 By: _ �.J' A ron . Harp lk%W t•s.c8 City Attorney ATTEST: Date: CITY OF NEWPORT BEACH, a California municipal corporation By: David A. Webb Public Works Director CONSULTANT: Urban Resource Corporation, a California corporation Date: By: By: Leilani I. Brown Jay by City Clerk President Date:}� By: Martin Aq� rre Secretary [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements Urban Resource Corporation Page 13 EXHIBIT A SCOPE OF SERVICES Urban Resource Corporation Page A-1 SCOPE OF SERVICES Consultant's work, subject to City's approval, shall consist of the following professional engineering services as needed to complete the preliminary engineering services for the Project. A. PRELIMINARY ENGINEERING AND BASE MAPPING 1. AERIAL TOPOGRAPHY REQUIRED SURVEY Conduct a field survey to establish project control and to set 12 aerial targets for the aerial topographic flown survey described below. Coordinate with aerial topography company as required to complete the survey. All materials needed are included in the fee. See attached Exhibit B for limits of aerial topography. 2. FLOWN AERIAL TOPOGRAPHY AND MAPPING Conduct an aerial topographic survey of the entire site as shown on the attached exhibit. Prepare a topographic map with an approximate negative scale of 1 "=280', a map compilation scale of 1 "=20', and 1 foot contour intervals. This survey will be based on the 12 aerial survey targets as described above. Provide digital files for use by the aerial mapping consultants, and this information will be used as the existing ground topographic information in conjunction with the site-specific field topographic survey described above. Provide optional orthometric aerial photo for reference if so desired. 3. SITE SPECIFIC DESIGN SURVEY TOPOGRAPHY Conduct a field topographic survey to establish horizontal and vertical control of existing site topographic characteristics around the perimeter of the site as required for the engineering design of the project. This will provide more accurate detailed information that is not included in the original aerial topography that is available for the site. It will include finished grade and finished surface elevations for all improvements, all visible above ground utilities, existing buildings adjacent to the property line, and existing trees. This topography will be based vertically on a nearby County Bench Mark, in conjunction with the previously prepared topographies. The primary scope of the field topo will be to collect data on hardscape and utility improvements to supplement the aerial topography that will provide the contoured slope conditions. 4. MEETINGS AND COORDINATION Attend meetings with City, the architect, the landscape architect, other project consultants, and public agency staff as required to coordinate preliminary constraints and concepts. Provide project consultants with plans, files and information for proper coordination as required. Bill on a time and materials basis not to exceed 40 hours. 5. RECORD DIGITAL BASE MAP AND CONSTRAINTS MAP Research record information with the City of Newport Beach and County of Orange, and prepare a digital base file with the record mapping street and utility improvements information. Prepare a constraints map for the property that describes the site mapping, grading and drainage, utilities and building setbacks as required for the concept design phase. Verify utilities with the as -built information provided by the City as well as with the aerial and field topo survey scopes. This does not include any potholing information. Provide project consultants with digital file for use in their portion of the preliminary project design. This will include plotting the existing easements on the site as noted in the title reports. A preliminary title report will be provided by the owner. Any mapping information will be per record information only and this proposal does not include a boundary survey at this time. 6. CONSTRAINTS ANALYSIS AND CONCEPTUAL DESIGN Review existing site topography, mapping and utility constraints per the information established above and provide conceptual design studies related to the scope to construct parking facilities and the two pedestrian bridge crossings at PCH and Superior, and a connection to the Hoag parking lot. Maintain a digital base file with the latest digital information as provided by the Architect and Landscape Architect as required completing a digital base file for the project. Complete the civil related base information as required for the project and provide project consultants with digital file for use in their portion of the project design. Provide an 160 hour allowance for this initial study process that will be invoiced hourly on a time and materials basis. This scope has been established as an initial allowance for generating conceptual ideas in conjunction with City staff and other consultants. If additional scope is requested or required during the process, then a change order will be process for any additional services. ASSUMPTIONS AND EXCLUSIONS In addition to the information provided under the scope for each item, Consultant has made the following assumptions: 1. The Services are based on the preliminary meeting held on May 16, 2018, and upon Consultant's understanding of the project and Consultant's experience with similar project types. Consultant reserves the right to review and approve any new or revised services and amendments to the Scope of Work and fees accordingly. 2. The City will provide a copy of the latest title report to Consultant. 3. Geotechnical investigations, technical reports, architecture and landscape plans will be provided to Consultant by others. 4. Electric, telephone, gas, and CATV design and coordination will be handled by others. Consultant will work closely with the utility consultant to ensure proper placement of joint trench, and above ground structures. 4 5. AutoCAD digital files will be available for Consultant's use from the architect, the landscape architect, the dry utility consultant and structural consultants if required and / or available. 6. City shall designate a person to act as representative with respect to services to be rendered. Such person shall have complete authority to transmit instructions, receive information, interpret and define City's policies and decisions with respect to all aspects of this Project, request extra work, and authorize payment. 7. Any work not specifically included within this scope may be provided at the direction of the City. Any additional services requested will be processed as an amendment to this Agreement. 8. Record information for existing underground utilities will be utilized for the plan, and no potholing will be included in this proposal. 9. The project boundary will be established as described in the proposal per record information only. This will be the boundary for the property. A boundary survey or ALTA survey is not included in the Services. 10. Upon execution of this Agreement and a notice to proceed, project schedules will be reviewed, evaluated and coordinated with City. H. Land Surveying is investigative in nature. Consultant has no control over the difficulty of locating records, conditions of the terrain, density of the vegetation, severity of the weather, and availability of original monuments. Therefore, any estimates of the project cost provided to the City are made on the basis of experience and similar services provided in the past. Consultant cannot and does not guarantee that the actual costs will not vary from the estimates provided; however, Consultant will notify City as soon as Consultant is aware the fees will exceed the Agreement based on unforeseen conditions. 12. All environmental permitting (i.e. 404, 401, 1600, etc.) will be obtained by others and are not part of the Services. 13. The Services do not include any final lot monumentation, surveys, centerline ties, etc, as may be required during construction. 14. The Services do not include any construction survey or survey certifications. 15. Permission to enter the site will be provided by the City. 16. Traffic signal modifications or plans are not included inthe Services. 17. The Services do not include an ALTA Land Title Survey, but it can be provided as an amendment to the Agreement. 18. The Services do not include a boundary survey, but it can be added as an amendment if requested. EXHIBIT B SCHEDULE OF BILLING RATES Urban Resource Corporation Page B-1 ENGINEERING FEES The engineering fees for each item of work will be as follows: Item of Work A. PRELIMINARY ENGINEERING AND BASE MAPPING AMOUNT 1. AERIAL TOPOGRAPHY REQUIRED SURVEY (TARGETS) 20 HRS @ 5,300.00 $265/HR 2. FLOWN AERIAL TOPOGRAPHY AND MAPPING (LUMP SUM FEE 4,830.00 FROM AERIAL TOPO COMPANY) 3. SITE SPECIFIC FIELD SURVEY TOPOGRAPY 36 FIELD HRS @ 13,220.00 $265/HR AND 32 OFFICE HRS @ $115/HR 4. MEETINGS AND COORDINATION: 40 HRS @ $115/HR 4,600.00 5. RECORD DIGITAL BASE MAP AND CONSTRAINT MAP: 80 HRS @ 9,200.00 $115/HR 6. CONSTRAINTS ANALYSIS AND CONCEPTUAL DESIGN: 160 HRS 18,400.00 @ $115/HR TOTAL FEES A. SUBTOTAL $55,550.40 AMOUNT TOTAL FEES $55,550.0 BILLING Services will be invoiced monthly, based upon the percentage of completion of those project services. The owner will not be billed for any services that were not requited for the project. Additional services, if authorized in writing in advance, will be performed at the following hourly rates: General Office: $115.00/hour One Man Survey Crew: $164.00/hout Two Man Survey Crew: $210.00/hour Three Man Survey Crew: $250.00/hout Two Man Survey Crew at $265.00/hout Prevailing Wage: EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this Urban Resource Corporation Page C-1 Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self- insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days' notice of cancellation (except for nonpayment for which ten (10) calendar days' notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: Urban Resource Corporation Page C-2 A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days' advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. Urban Resource Corporation Page C-3 G. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. Urban Resource Corporation Page C-4 CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach. * Date Received: 7/27/18 Dept./Contact Received From: Raymund Date Completed: 7/27/18 Sent to: Raymund By: Jan Company/Person required to have certificate: Urban Resource Cornoration Type of contract: Other L GENERAL LIABILITY EFFECTIVE/EXPIRATION DATE: 12/1/17— 12/1/18 A. INSURANCE COMPANY: Travelers Property Casualty Company of America B. AM BEST RATING (A-: VII or greater): A++/XV INSURANCE COMPANY: Travelers Property Casualty Company C. ADMITTED Company (Must be California Admitted): B. Is Company admitted in California? N Yes ❑ No D. LIMITS (Must be $1M or greater): What is limit provided? $1M/$2M E. ADDITIONAL INSURED ENDORSEMENT—please attach N Yes ❑ No F. PRODUCTS AND COMPLETED OPERATIONS (Must Is Company admitted in California? include): Is it included? (completed Operations status does ❑ No D. not apply to Waste Haulers or Recreation) ❑ Yes ❑ No G. ADDITIONAL INSURED FOR PRODUCTS AND UM, $2M min for Waste Haulers): What is limits provided? $1,000,000 COMPLETED OPERATIONS ENDORSEMENT (completed E LIMITS Waiver of Auto Insurance / Proof of coverage (if individual) Operations status does not apply to Waste Haulers) ❑ Yes ❑ No H. ADDITIONAL INSURED WORDING TO INCLUDE (The City N/A its officers, officials, employees and volunteers): Is it F. ADDITIONAL INSURED WORDING: included? N Yes ❑ No I. PRIMARY & NON-CONTRIBUTORY WORDING (Must be PRIMARY & NON-CONTRIBUTORY WORDING: N N/A included): Is it included? N Yes ❑ No J. CAUTION! (Confirm that loss or liability of the named insured N N/A ❑ Yes is not limited solely by their negligence) Does endorsement I. NOTICE OF CANCELLATION: include "solely by negligence' wording? ❑ Yes N No K. ELECTED SCMAF COVERAGE (RECREATION ONLY): N N/A ❑ Yes ❑ No L. NOTICE OF CANCELLATION: ❑ N/A N Yes ❑ No 11. AUTOMOBILE LIABILITY EFFECTIVE/EXPIRATION DATE: 12/1/17— 12/1/18 A. INSURANCE COMPANY: Travelers Property Casualty Company of America B. AM BEST RATING (A-: VII or greater) A++/ XV C. ADMITTED COMPANY (Must be California Admitted): Is Company admitted in California? N Yes ❑ No D. LIMITS - If Employees (Must be $1M min. BI & PD and $500,000 UM, $2M min for Waste Haulers): What is limits provided? $1,000,000 E LIMITS Waiver of Auto Insurance / Proof of coverage (if individual) (What is limits provided?) N/A F. ADDITIONAL INSURED WORDING: N N/A ❑ Yes ❑ No G. PRIMARY & NON-CONTRIBUTORY WORDING: N N/A ❑ Yes ❑ No H. HIRED AND NON -OWNED AUTO ONLY: N N/A ❑ Yes ❑ No I. NOTICE OF CANCELLATION: ❑ N/A N Yes ❑ No WORKERS' COMPENSATION EFFECTIVE/EXPIRATION DATE: 12/1/17— 12/1/18 A. INSURANCE COMPANY: Hanover American Insurance Comz B. AM BEST RATING (A-: VII or greater): A / XV C. ADMITTED Company (Must be California Admitted): D. WORKERS' COMPENSATION LIMIT: Statutory E. EMPLOYERS' LIABILITY LIMIT (Must be $1 M or greater) F. WAIVER OF SUBROGATION (To include): Is it included? G. SIGNED WORKERS' COMPENSATION EXEMPTION FORM: H. NOTICE OF CANCELLATION: ® Yes ❑ No ® Yes ❑ No $1,000,000 ® Yes ❑ No ® N/A ❑ Yes ❑ No ❑ N/A ® Yes ❑ No ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED IV. PROFESSIONAL LIABILITY 12/1/17-12/1/18 LIBERTY INSURANCE UNDERWRITERS, INC Rated: A/ XV, Admitted Limits: $2M ® N/A ❑ Yes ❑ No V POLLUTION LIABILITY VI BUILDERS RISK HAVE ALL ABOVE REQUIREMENTS BEEN MET? IF NO, WHICH ITEMS NEED TO BE COMPLETED? ® N/A ❑ Yes ❑ No ® N/A ❑ Yes ❑ No ® Yes ❑ No Agent of Alliant Insurance Services Date Broker of record for the City of Newport Beach RISK MANAGEMENT APPROVAL REQUIRED (Non -admitted carrier rated less than _ Self Insured Retention or Deductible greater than $ ) ❑ N/A ❑ Yes ❑ No Reason for Risk Management approval/exception/waiver: Approved: Risk Management Date * Subject to the terms of the contract.