HomeMy WebLinkAboutC-10057-1 - On-Call PSA for On-Call Civil Engineering Consulting ServicesON -CALL PROFESSIONAL SERVICES AGREEMENT
WITH STANTEC CONSULTING SERVICES INC. FOR
ON -CALL CIVIL ENGINEERING CONSULTING SERVICES
THIS ON -CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 13th day of January, 2026 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and charter
city ("City"), and STANTEC CONSULTING SERVICES INC., a New York corporation
("Consultant"), whose address is 410 17th Street, Suite 1400, Denver, CO 80202, and is
made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide on -call civil engineering consulting
services ("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on January 12, 2031, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on -call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services,
and the name and contact number of the individuals to be assigned, if available;
2.1.3 The estimated number of hours and any anticipated consumable,
material, or ancillary costs to complete the Services; and
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Five Hundred Thousand Dollars and 00/100 ($500,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
4.2 Upon first anniversary of the Effective Date and upon each anniversary of
the Effective Date thereafter, the billing rates set for in Exhibit B ("Billing Rates") shall be
STANTEC CONSULTING SERVICES INC. Page 2
adjusted by a fixed amount of three percent (3.0%) of the Billing Rates in effect
immediately preceding such adjustment.
4.3 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.4 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.5 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Jeff Wilkerson to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Director of Public Works or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
STANTEC CONSULTING SERVICES INC. Page 3
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers and employees (collectively, the "Indemnified Parties"), from and against any
and all claims (including, without limitation, claims for bodily injury, death or damage to
property), demands, obligations, damages, actions, causes of action, suits, losses,
judgments, fines, penalties, liabilities, costs and expenses (including, without limitation,
attorneys' fees, disbursements and court costs) of every kind and nature whatsoever
(individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the
negligence, recklessness, or willful misconduct of the Consultant or its principals, officers,
agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone
employed directly or indirectly by any of them or for whose acts they may be liable, or any
or all of them.
STANTEC CONSULTING SERVICES INC. Page 4
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable, but only to the extent
permitted by law, and not to exceed the policy limits of Consultant's insurance policy
where applicable.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis
and Consultant is not an agent or employee of City. The manner and means of conducting
the Work are under the control of Consultant, except to the extent they are limited by
statute, rule or regulation and the expressed terms of this Agreement. No civil service
status or other right of employment shall accrue to Consultant or its employees. Nothing
in this Agreement shall be deemed to constitute approval for Consultant or any of
Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
STANTEC CONSULTING SERVICES INC. Page 5
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
STANTEC CONSULTING SERVICES INC. Page 6
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 Computer Aided Design and Drafting ("CADD") data delivered to City shall
include the professional stamp of the engineer or architect in charge of or responsible for
the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses
arising out of, or connected with (a) the modification or misuse by City, or anyone
authorized by City, of CADD data; or (b) any use by City, or anyone authorized by City,
of CADD data for additions to this Project, for the completion of this Project by others, or
for any other Project, excepting only such use as is authorized, in writing, by Consultant.
By acceptance of CADD data, City agrees to indemnify Consultant for damages and
liability resulting from the modification or misuse of such CADD data. All original drawings
shall be submitted to City in the version of AutoCAD used by the City in .dwg file format,
and should comply with the City's digital submission requirements for improvement plans
available from the City's Public Works Department.
17.4 All improvement and/or construction plans shall be plotted on standard
twenty-four inch (24") by thirty-six inch (36") paper size. Consultant shall provide to City
digital 'As -Built' drawings in both AutoCAD and Adobe PDF file format within thirty (30)
days after finalization of the Project.
18. OPINION OF COST
Any opinion of the construction cost prepared by Consultant represents the
Consultant's judgment as a design professional and is supplied for the general guidance
of City. Since Consultant has no control over the cost of labor and material, or over
competitive bidding or market conditions, Consultant does not guarantee the accuracy of
such opinions as compared to Consultant or contractor bids or actual cost to City.
19. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
20. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
STANTEC CONSULTING SERVICES INC. Page 7
21. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
22. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
23. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
25. CONFLICTS OF INTEREST
25.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
STANTEC CONSULTING SERVICES INC. Page 8
25.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
26. NOTICES
26.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
26.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Director of Public Works
Public Works Department
City of Newport Beach
100 Civic Center Drive
Newport Beach, CA 92658
26.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Jeff Wilkerson
Stantec Consulting Services Inc.
38 Technology Drive, Suite 200
Irvine, CA 92618
27. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in writing,
all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set
forth in the Agreement, Consultant shall be required to file any claim Consultant may have
against City in strict conformance with the Government Claims Act (Government Code
sections 900 et seq.).
28. TERMINATION
28.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
STANTEC CONSULTING SERVICES INC. Page 9
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
28.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
STANTEC CONSULTING SERVICES INC. Page 10
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
STANTEC CONSULTING SERVICES INC. Page 11
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: t 9- ZoZsL
0
4�& Fr'
Aaron C. Harp IZ. 11. 25 F-,)
City Attorney
ATTEST:
Date: 1 �Z W 2,6
By:
Lena Shumway
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date: // W a026
By:
Lauren Kleiman
Mayor
CONSULTANT: STANTEC
CONSULTING SERVICES INC., a New
York corporation
Date:
Signed in Counterpart
By:
Jeff Wilkerson
Senior Associate
Date:
Signed in Counterpart
Bv:
David Elwell
Vice President
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
STANTEC CONSULTING SERVICES INC. Page 12
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: ,Z�-I9_ ZoZ,-
v
By: `1
� at'
Aaron C. Harp IZ 25 g
City Attorney
ATTEST:
Date:
Lena Shumway
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Lauren
Mayor
Kleinman
CONSULTANT: STANTEC
CONSULTING SERVICES INC., a New
York corporation
Date:_
By: � al--�
Je ilkerson
Senior Associate
Date: 12.1 r,11-5—
�QBy.
David Elwell
Vice President
[END OF SIGNATURES]
Attachments: Exhibit A - Scope of Services
Exhibit B - Schedule of Billing Rates
Exhibit C - Insurance Requirements
STANTEC CONSULTING SERVICES INC. Page 12
EXHIBIT A
SCOPE OF SERVICES
STANTEC CONSULTING SERVICES INC. Page A-1
SCOPE OF SERVICES
ON -CALL CIVIL — SCOPE OF SERVICES
Consultant shall provide Civil Engineering services for the conceptual and final design of a wide
variety of City capital improvement and maintenance projects. Consultant shall provide in-
house services, or capacity to subconsultant, for the following areas:
■ Provide full plans, specifications, and estimates for a broad range of civil engineering
disciplines;
■ Provide cost estimating and value engineering services;
■ Provide bid support and preparation of record drawings;
■ Provide construction support, administration, and management services;
■ Provide construction traffic control concepts and plans;
■ Provide project -specific professional surveying services;
■ Review public/private development plans and maps;
■ Provide regulatory permitting support;
■ Prepare various studies and supporting documentation for, but not limited to,
hydrology and hydraulic analysis, water and sewer studies and network analysis;
■ Prepare/review NPDES reports, Water Quality Management Plan (WQMP), and
Storm Water Pollution Prevention Plans (SWPPP);
■ Prepare maps and legal descriptions for right-of-way acquisitions and easements; and
■ Other engineering -related tasks as necessary.
EXHIBIT B
SCHEDULE OF BILLING RATES
STANTEC CONSULTING SERVICES INC. Page B-1
® Stantec
October 23,d, 2025
Stantec Consulting Services
Inc.
38 Technology Drive, Suite 200
Irvine, CA 92618
Attention:
City of Newport Beach
Ben Davis, Senior Civil Engineer
949-644-3317
bdavis@newportbeachca.gov
Reference:
RFP #26-13
On -Call Professional Civil
Engineering Services
Sherry Weinmeier, PE
Principal -in -Charge
949-584-7231
sherry.weinmeier@stantec,com
Jeff Wilkerson
Project Manager
949-929-1449
jeff.wilkerson@stantec,com
Dear Ben Davis,
Per your RFP, we are providing our Fee Schedule
showing our proposed billing rates in this separate
document. The rates outlined herein shall remain in
effect for the full duration of the five-year Agreement.
We also assume that they shall escalate annually on
January 1 st by 3%, or as otherwise agreed upon in
writing by both parties, to reflect increases in labor and
overhead costs.
At Stantec, we strongly believe that the measurement
of value is partially referenced from pricing, but also
from credentials and capabilities. Our rates were
created with an understanding of this balance.
Should you have any questions or require additional
information about our fee proposal, please contact Jeff
Wilkerson or Sherry Weinmeier at the contact
information below.
Sincerely,
STANTEC CONSULTING SERVICES INC.
SCHEDULE OF BILLING RATES - 2026 City of Newport Beach Civil On -Call ® Stantec
Billing
Hourly
Description
Level
Rate
Junior Level position
3
$127
❑ Independently carries out assignments of limited scope using standard procedures, methods, and
4
$138
techniques
❑ Assists senior staff in carrying out more advanced procedures
5
$158
❑ Completed work is reviewed for feasibility and soundness of judgment
❑ Graduate from an appropriate post -secondary program or equivalent
❑ Generally, one to three ears' experience
Fully Qualified Professional Position
6
$162
❑ Carries out assignments requiring general familiarity within a broad field of the respective profession
❑ Makes decisions by using a combination of standard methods and techniques
7
$174
❑ Actively participates in planning to ensure the achievement of objectives
8
$184
❑ Works independently to interpret information and resolve difficulties
❑ Graduate from an appropriate post -secondary program, with credentials or equivalent
❑ Generally, three to six years' experience
First Level Supervisor or first complete Level of Specialization
9
$190
❑ Provides applied professional knowledge and initiative in planning and coordinating work programs
10
$198
❑ Adapts established guidelines as necessary to address unusual issues
❑ Decisions accepted as technically accurate, however may on occasion be reviewed for soundness of
11
$214
judgment
❑ Graduate from an appropriate post -secondary program, with credentials or equivalent
❑ Generally, five to nine years' experience
Highly Specialized Technical Professional or Supervisor of groups of professionals
❑ Provides multi -discipline knowledge to deliver innovative solutions in related field of expertise
12
$226
❑ Participates in short- and long-range planning to ensure the achievement of objectives
13
$237
❑ Makes responsible decisions on all matters, including policy recommendations, work methods, and
financial controls associated with large expenditures
14
$250
❑ Reviews and evaluates technical work
❑ Graduate from an appropriate post -secondary program, with credentials or equivalent
❑ Generally, ten to fifteen ears' experience with extensive, broad experience
Senior Level Consultant or Management
❑ Recognized as an authority in a specific field with qualifications of significant value
15
$264
❑ Provides multi -discipline knowledge to deliver innovative solutions in related field of expertise
❑ Independently conceives programs and problems for investigation
16
$291
❑ Participates in discussions to ensure the achievement of program and/or project objectives
❑ Makes responsible decisions on expenditures, including large sums or implementation of major
17
$302
programs and/or projects
❑ Graduate from an appropriate post -secondary program, with credentials or equivalent
❑ Generally, more than twelve years' experience with extensive experience
Senior level Management under review by Vice President or higher
18
$308
❑ Recognized as an authority in a specific field with qualifications of significant value
❑ Responsible for long range planning within a specific area of practice or region
19
$320
❑ Makes decisions which are for reaching and limited only by objectives and policies of the organization
❑ Plans/approves projects requiring significant human resources or capital investment
20
$332
❑ Graduate from an appropriate post -secondary program, with credentials or equivalent
21
$352
❑ Generally, fifteen years' experience with extensive professional and management experience
Crew Size Regular Rate
Survey Crews
1-Person $255
2-Person $385
3-Person $515
Note: The rates outlined herein shall remain in effect for the full duration of the five-year Agreement. We also assume
that they shall escalate annually on January 1st by 37o, or as otherwise agreed upon in writing by both parties, to
reflect increases in labor and overhead costs.
Expert Witness Services carry a 50% premium on labor. Overtime may be charged at 1.5 times the standard billing rate.
All expert fees and overtime fees shall be approved in writing by the City prior to being incurred.
T-2 2026 CA
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL CONSULTING SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City,
and prior to commencement of Work, Consultant shall obtain, provide and
maintain at its own expense during the term of this Contract, policies of
insurance of the type and amounts described below and in a form satisfactory
to City. Consultant agrees to provide insurance in accordance with
requirements set forth here. If Consultant uses existing coverage to comply and
that coverage does not meet these requirements, Consultant agrees to amend,
supplement or endorse the existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance providing statutory benefits and Employer's
Liability Insurance with limits of at least one million dollars ($1,000,000)
each employee for bodily injury by accident and each employee for
bodily injury by disease in accordance with the laws of the State of
California.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council,
boards and commissions, officers, agents, volunteers and employees.
B. General Liability Insurance. Consultant shall maintain commercial
general liability insurance, and if necessary excess/umbrella liability
insurance, with coverage at least as broad as provided by Insurance
Services Office form CG 00 01, in an amount not less than two million
dollars ($2,000,000) per occurrence, four million dollars ($4,000,000)
general aggregate. The policy shall cover liability arising from bodily
injury, property damage, personal and advertising injury, and liability
assumed under an insured contract (including the tort liability of another
assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
STANTEC CONSULTING SERVICES INC. Page C-1
arising out of or in connection with Work to be performed under this
Contract, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit for each accident.
D. Professional (Errors & Omissions) Insurance. Consultant shall maintain
professional liability insurance that covers the Services to be performed
in connection with this Agreement, in the minimum amount of two million
dollars ($2,000,000) per claim and four million dollars ($4,000,000) in
the aggregate. Any policy inception date, continuity date, or retroactive
date must be before the Effective Date of this Agreement and Consultant
agrees to maintain continuous coverage through a period no less than
three years after completion of the Services required by this Agreement.
E. Excess/Umbrella Liability Insurance. If any Excess or Umbrella Liability
policies are used to meet the limits of liability required by this contract,
then said policies shall be "following form" of the underlying policy
coverage, terms, conditions, and provisions and shall meet all of the
insurance requirements stated in this contract, including, but not limited
to, the additional insured and primary & non-contributory insurance
requirements stated herein. No insurance policies maintained by the
City, whether primary or excess, and which also apply to a loss covered
hereunder, shall be called upon to contribute to a loss until the
Consultant's primary and excess/umbrella liability policies are
exhausted.
4. Other Insurance Requirements. The policies are to contain, or be endorsed
to contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Contract shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents,
volunteers and employees, or shall specifically allow Consultant or
others providing insurance evidence in compliance with these
requirements to waive their right of recovery prior to a loss. Consultant
hereby waives its own right of recovery against City, and shall require
similar written express waivers and insurance clauses from each of its
subcontractors.
B. Additional Insured Status. All liability policies including general liability,
excess/umbrella liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide
that City, its City Council, boards and commissions, officers, agents,
volunteers and employees shall be included as additional insureds
under such policies.
STANTEC CONSULTING SERVICES INC. Page C-2
C. Primary and Non -Contributory. Consultant's insurance coverage shall
be primary insurance and/or the primary source of recovery with respect
to the City, its City Council, boards and commissions, officers, agents,
volunteers and employees. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-
insurance maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation or nonrenewal of coverage (except
for nonpayment for which ten (10) calendar days' notice is required) for
each required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to
the following:
A. Evidence of Insurance. Consultant shall provide certificates of insurance
to City as evidence of the insurance coverage required herein, along
with a waiver of subrogation endorsement for workers' compensation
and other endorsements as specified herein for each coverage. All of
the executed documents referenced in this Contract must be returned
to City within ten
(10) regular City business days after the date on the "Notification
of Award". Insurance certificates and endorsements must be approved
by City's Risk Manager prior to commencement of performance. Current
certification of insurance shall be kept on file with City at all times during
the term of this Contract. The certificates and endorsements for each
insurance policy shall be signed by a person authorized by that insurer
to bind coverage on its behalf. At least fifteen (15) days prior to the
expiration of any such policy, evidence of insurance showing that such
insurance coverage has been renewed or extended shall be filed with
the City. If such coverage is cancelled or reduced, Consultant shall,
within ten (10) days after receipt of written notice of such cancellation or
reduction of coverage, file with the City evidence of insurance showing
that the required insurance has been reinstated or has been provided
through another insurance company or companies. City reserves the
right to require complete, certified copies of all required insurance
policies, at any time.
B. City's Right to Revise Requirements. The City reserves the right at any
time during the term of the Contract to change the amounts and types
of insurance required by giving Consultant ninety (90) calendar days'
advance written notice of such change. If such change results in
substantial additional cost to Consultant, City and Consultant may
renegotiate Consultant's compensation.
STANTEC CONSULTING SERVICES INC. Page C-3
C. Right to Review Subcontracts. Consultant agrees that upon request, all
agreements with subcontractors or others with whom Consultant enters
into contracts with on behalf of City will be submitted to City for review.
Failure of City to request copies of such agreements will not impose any
liability on City, or its employees. Consultant shall require and verify that
all subcontractors maintain insurance meeting all the requirements
stated herein, and Consultant shall ensure that City is an additional
insured on insurance required from subcontractors. For CGL coverage,
subcontractors shall provide coverage with a format at least as broad as
CG 20 38 04 13.
D. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no
additional obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features
or limits contained in this Section are not intended as a limitation on
coverage, limits or other requirements, or a waiver of any coverage
normally provided by any insurance. Specific reference to a given
coverage feature is for purposes of clarification only as it pertains to a
given issue and is not intended by any party or insured to be all inclusive,
or to the exclusion of other coverage, or a waiver of any type. If the
Consultant maintains higher limits than the minimums shown above, the
City requires and shall be entitled to coverage for higher limits
maintained by the Consultant. Any available proceeds in excess of
specified minimum limits of insurance and coverage shall be available
to the City.
F. Self -Insured Retentions. Any self -insured retentions must be declared
to and approved by City. City reserves the right to require that self -
insured retentions be eliminated, lowered, or replaced by a deductible.
Self-insurance will not be considered to comply with these requirements
unless approved by City.
G. City Remedies for Non -Compliance. If Consultant or any subconsultant
fails to provide and maintain insurance as required herein, then City
shall have the right but not the obligation, to purchase such insurance, to
terminate this Agreement, or to suspend Consultant's right to proceed
until proper evidence of insurance is provided. Any amounts paid by
City shall, at City's sole option, be deducted from amounts payable to
Consultant or reimbursed by Consultant upon demand.
STANTEC CONSULTING SERVICES INC. Page C-4
H. Timely Notice of Claims. Consultant shall give City prompt and timely
notice of claims made or suits instituted that arise out of or result from
Consultant's performance under this Contract, and that involve or may
involve coverage under any of the required liability policies. City
assumes no obligation or liability by such notice, but has the right (but
not the duty) to monitor the handling of any such claim or claims if they
are likely to involve City.
Consultant's Insurance. Consultant shall also procure and maintain, at
its own cost and expense, any additional kinds of insurance, which in its
own judgment may be necessary for its proper protection and
prosecution of the Work.
STANTEC CONSULTING SERVICES INC. Page C-5
dd
W
G
L 1
Ot
ly
'tea
LPL
d
CL
4
r�
o'
co
CR
CIO
P
co
�
!
I
LL
i
I
I
l
I
V
I
(u
cn
m
a
cm
I
I
II 1
i
j
I
I
I
I
I I II
Ili
03
lb
!
i
III
I
I
v
g
I G1
'
l]
i
a;
a
ni
p
I
a�
w
a