Loading...
HomeMy WebLinkAboutC-8188-1 - PSA for Ocean Piers Maintenance - Inspection and Design ServicesAMENDMENT NO. ONE TO V PROFESSIONAL SERVICES AGREEMENT WITH COWI NORTH AMERICA, INC. FOR OCEAN PIERS MAINTENANCE — INSPECTION AND DESIGN SERVICES THIS AMENDMENT NO. ONE TO PROFESSIONAL SERVICES AGREEMENT ("Amendment No. One") is made and entered into as of this 24th day of October, 2017 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and COWI NORTH AMERICA, INC., a Delaware corporation ("Consultant"), whose address is 3780 Kilroy Way, Suite 200, Long Beach, California 90806, and is made with reference to the following: RECITALS A. On September 13, 2016, City and Consultant entered into a Professional Services Agreement ("Agreement") to provide inspection and design services related to the Ocean Piers Maintenance Project ("Project"). B. The parties desire to enter into this Amendment No. One to reflect additional Services not included in the Agreement, and to increase the total compensation. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. SERVICES TO BE PERFORMED Exhibit A to the Agreement shall be supplemented to include the Scope of Services, attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). Exhibit A to the Agreement, and Exhibit A to this Amendment No. One shall collectively be known as "Exhibit A." The City may elect to delete certain Services within the Scope of Services at its sole discretion. 2. COMPENSATION TO CONSULTANT Section 4.1 of the Agreement is amended in its entirety and replaced with the following: "City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Two Hundred Fifty Thousand Dollars and 00/100 ($250,000.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City." The total amended compensation reflects Consultant's additional compensation for additional Services to be performed in accordance with this Amendment No. One, including all reimbursable items and subconsultant fees, in an amount not to exceed Fifty Thousand Dollars and 00/100 ($50,000.00). 3. INTEGRATED CONTRACT Except as expressly modified herein, all other provisions, terms, and covenants set forth in the Agreement shall remain unchanged and shall be in full force and effect. [SIGNATURES ON NEXT PAGE] COWI North America, Inc. Page 2 IN WITNESS WHEREOF, the parties have caused this Amendment No. One to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: 10 /19 // 7 By: Aaron C. Harp City Attorney ATTEST: Date: �q 4 a- )1 In V `NW Leilani I. Brown City Clerk _ Attachments: CITY OF NEWPORT BEACH, a California municipal corporation Date: kijL1 �� Bv: Dave iff City Manager CONSULTANT: COWI North America, Inc.,, a Delaware corporation Date: Signed in Counterpart By: Warren L. Stewart Managing Director ND OF SIGNATURES] cope of Services COWI North America, Inc. Page 3 IN WITNESS WHEREOF, the parties have caused this Amendment No. One to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE FFICE Date: By: Aaron C. Harp KkW i1 City Attorney ATTEST: Date: 0 Leilani I. Brown City Clerk Attachments: CITY OF NEWPORT BEACH, a California municipal corporation Date: By: Dave Kiff City Manager CONSULTANT: COWI North America, Inc.,, a Delaware corporation Date: i1�1/7 /,/ By. I z JNLK erw'"4 Mamagilig cp 19-Ae'4 G«al [END OF SIGNATURES] Exhibit A — Scope of Services COW[ North America, Inc. Page 3 EXHIBIT A SCOPE OF SERVICES COWI North America, Inc. Page A-1 Mr Fong Tse Senior Engineer City of Newport Beach 100 Civic Center Drive Newport Beach, CA 92660 RE: Additional Services for NB Ocean Piers Maintenance; Change Order Request No. 1 to Contract No. C-8188-1 Professional Services Agreement for NB Ocean Piers Maintenance - Inspection and Design Services. Dear Fong cowl ADDRESS COWI Marine North America 3780 Kilroy Airport Way Suite 200 Long Beach, CA 90806 TEL 510-839-8972 e cowl-na.com DATE 10/19/17 PAGE 1/1 REF A086595.000 COWI North America, Inc. (COWI) is pleased to present this proposal for the subject services. Per your request, we agreed to provide additional services as detailed in the scope below. SCOPE OF SERVICES Provided additional supplemental inspections and testing services during construction, as needed and as authorized by the City's Project Administrator, including but not limited to above and underwater inspection, testing, and other services needed during construction. FEE PROPOSAL Fees for the above services will be billed in accordance with rates provided in the contract and the following schedule. Services for this amendment will not exceed $50,000. Thus, our current authorization of $200,000 will increase to $250,000. If this proposal for additional engineering services meets with your approval, we look forward to receiving an executed change order. Please feel free to contact me on my cell phone: 562-547-3918.Thank you. Sincerely, COWI NORTH AMERICA, INC. �% 4. J�� Warren A. Stewart, PE, SE, D.PE Project Manager Cc: J. Gerwick PROFESSIONAL SERVICES AGREEMENT WITH COWI NORTH AMERICA, INC. FOR OCEAN PIERS MAINTENANCE — INSPECTION AND DESIGN SERVICES THIS PROFESSIONAL SERVICES AGREEMENT ("Agreement") is made and entered into as of this 13th day of September, 2016 ("Effective Date"), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and COWI NORTH AMERICA, INC., a California corporation ("Consultant"), whose address is 3780 Kilroy Airport Way, Suite 200, Long Beach, California 90806, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide inspection and design services related to the Ocean Piers Maintenance Project ("Project'). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2018, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services" or "Work"). City may elect to delete certain Services within the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand -delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Two Hundred Thousand Dollars and 00/100 ($200,000.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement or specifically approved in writing in advance by City. 4.4 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. COWI North America, Inc. Page 2 Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Warren L. Stewart to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. City's Public Works Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work COWI North America, Inc. Page 3 conforms to the requirements of this Agreement, all applicable federal, state and local laws, and legally recognized professional standards. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement (collectively, the "Indemnified Parties), from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims"), which may arise under this Agreement or in any manner relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them. 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No COW[ North America, Inc. Page 4 civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint -venture or syndicate or co -tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50%) or more of the voting COWI North America, Inc. Page 5 power or twenty-five percent (25%) or more of the assets of the corporation, partnership or joint -venture. 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents, including all logins and password information to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 17.3 CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; COWI North America, Inc. Page 6 (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a CD, and should comply with the City's digital submission requirements for improvement plans available from the City's Public Works Department. The City will provide Consultant with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall be transmitted to City in formats compatible with Microsoft Office and/or viewable with Adobe Acrobat. 17.4 All improvement and/or construction plans shall be prepared with indelible waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting ("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90) days after finalization of the Project. For more detailed requirements, a copy of the City of Newport Beach Standard Design Requirements is available from the City's Public Works Department. 18. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents the Consultant's judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to Consultant or contractor bids or actual cost to City. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 21. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, COWI North America, Inc. Page 7 expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 22. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and/or restoration expense shall be bome by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 25. CONFLICTS OF INTEREST 25.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act"), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 25.2 If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. COWI North America, Inc. Page 8 26. NOTICES 26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 26.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: David A. Webb, Public Works Director Public Works Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 26.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Warren L. Stewart COWI North America, Inc. 3780 Kilroy Airport Way, Suite 200 Long Beach, CA 90806 27. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 28. TERMINATION 28.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure COWI North America, Inc. Page 9 such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. PREVAILING WAGES Pursuant to the applicable provisions of the Labor Code of the State of California, not less than the general prevailing rate of per diem wages including legal holidays and overtime Work for each craft or type of workman needed to execute the Work contemplated under the Agreement shall be paid to all workmen employed on the Work to be done according to the Agreement by the Consultant and any subcontractor. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the Work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the Agreement. A copy of said determination is available by calling the prevailing wage hotline number (415) 703-4774, and requesting one from the Department of Industrial Relations. The Contractor is required to obtain the wage determinations from the Department of Industrial Relations and post at the job site the prevailing rate or per diem wages. It shall be the obligation of the Contractor or any subcontractor under him/her to comply with all State of California labor laws, rules and regulations and the parties agree that the City shall not be liable for any violation thereof. 30. STANDARD PROVISIONS 30.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 30.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 30.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent COWI North America, Inc. Page 10 breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 30.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 30.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 30.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 30.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 30.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 30.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 30.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 30.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 30.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] COWI North America, Inc. Page 11 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: Aaron C. Harp City Attorney ATTEST: Date: 1�0 Leilani I. Brown City Clerk womrd CITY OF NEWPORT BEACH, a California municipal (�orp ai Date: l�� - CONSULTANT: COWI North America, Inc., a California corporation Date: Signed in Counterpart Bv: Warren L. Stewart Managing Director [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements COW] North America, Inc. Page 12 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: By: Aaron C. Harp �^^ ov�aclly City Attorney ATTEST: Date: Leilani I. Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation By: Diane B. Dixon Mayor CONSULTANT: COW[ North America, Inc., a Galifarnie corporation peLA.WA-IZe- Date: ' -201 By: "'4L. dr*&P-L—StewarF w i N S T o nr L, S (v�A-P T fVl. agling-BirectcT SC-"LL>VZ_ Pae5iocrv-7 [END OF SIGNATURES] Attachments: Exhibit A - Scope of Services Exhibit B - Schedule of Billing RateE Exhibit C - Insurance Requirements COWI North America, Inc. Page 12 EXHIBIT A SCOPE OF SERVICES OCEAN PIERS MAINTENANCE - INSPECTION & DESIGN SERVICES • Conduct underwater and above water inspection of the Newport and Balboa Piers. • Inspect all existing piles and support members of the Newport Pier to Bent 49. Structural members between Bents 49 to 53 are excluded. • Inspect all existing piles and support members of the Balboa Pier to Bent 47. • Prepare a comprehensive report that includes but is not limited to: o Inspection overview and methodology o Summary of findings and design recommendations, based on repair needs. o Assessment criteria. o Condition report of piles, pile caps, pile wraps, bracing, stringers, attaching hardware, and any noted attribute(s). o New improvements and repair needs recommendation. o Library of all images taken during the inspection process. • Professional design engineering services shall, at a minimum, include: o Prepare full plan, specs, and estimates for the identified repairs. o Provide bid support o Provide construction support and administration services o Prepare record drawings o Attend and/or facilitate coordination and progress meetings, as necessary. Based on previous experience, and in order to address the work outlined above, COWI has developed the following detailed work plan, divided into the major tasks described below. A discussion of the approach, key challenges, and strategies for overcoming these challenges is provided. All work will be performed in compliance with ASCE MOP 130 - Waterfront Facilities Inspection and Assessment , and ASCE Underwater Investigations, Standard Practice Manual No. 101. COWI North America, Inc. Page A-1 TASK 1 — DATA REVIEW AND PROJECT PLANNING PRE -INSPECTION SITE VISIT The project manager and field engineer will perform a site visit to familiarize themselves with the current conditions and any access constraints for the inspection teams as well as for the future repair contractor. COWI will coordinate with City staff on site access, safety, security requirements, emergency and on-site coordination contacts, and any other concerns that may arise. COWI will examine the site to note any remaining obstacles that would impact our inspection and bring such to the attention of the City. DATA GATHERING AND REVIEW COW] will review the existing drawings, previous inspection reports, and any completed repair drawings/ photographs provided, including the recent repairs completed under City project "Ocean Piers Maintenance, C-5539". COWI will identify any missing information that could be helpful for surveys and analyses. The drawings and reports will be used to develop an electronic database of members for survey and documentation of findings. During the above and underwater inspection, the note takers will record observations from the divers directly into an inspection database pre -populated with the results of the previous inspection findings and repair information. This will assist the divers with locating existing defects quickly and allow them to rapidly determine if the damage has increased in magnitude or extent. Prior to the field activities, the team will have an internal meeting to review the findings of the previous condition assessment reports- and the typical repair details that may be utilized for the repair. By reviewing these repair details in advance, the field inspection engineers will be able to assign most of the repair types while in the field. ENGINEERING INSPECTION PLANNING - UNDERWATER Engineer -divers from COW] will perform the underwater portion of the inspection under the supervision of a California registered professional engineer -diver. The proposed method for the underwater inspection of piles would then consist of the following: 1. Perform a Level I inspection on 100% of the piles: This level of effort includes a visual and tactile evaluation to detect gross defects or breakage. Observed defects will be noted and assigned an anticipated repair type. 2. Perform a Level Ill 2 inspection on approximately 10% of the piles: This level of effort will include cleaning of marine growth in order to detect surface defects that may otherwise be obscured by the marine growth. The existing protective wraps will not be removed. The cleaning will be performed at three elevations; mudline, mid- level, and top of growth. A visual inspection of the exposed portions of the pile will 1 As defined in ASCE Underwater Investigations, Standard Practice Manual No. 101. Level 11 is a detailed inspection requiring the removal of marine growth. Level Ill consists of testing using non-destructive or limited destructive measures to quantify damage or deterioration of key structural members. Typical sampling and tests could Include taking cores for later lab testing and in-situ ultrasonic testing. COWI North America, Inc. Page A-2 be completed. Observed defects will be recorded and an anticipated repair type will be assigned to the pile. 3. Perform Level III inspections for selected piles: A certain number of piles may also be selected for testing, depending upon results of the Level I and Level II inspections. This is considered optional work, and would be priced and authorized separately at time of need. Typically this may require the removal and replacement of the wraps. In order to identify all underwater defects requiring repair, it would be necessary to remove essentially all of the marine growth to observe splits, erosion, damage to wraps, etc. Since the full cleaning and inspection of all elements would be costly to complete, a sampling is used to estimate the total expected number of defects to be repaired. By performing the proposed inspection on a sample, COWI can reasonably determine final repair quantities in a short inspection time and at significantly reduced costs. Cleaning all the elements will not reduce the future construction cost, as the piles will need to be cleaned again prior to repair. If a significant percentage of piles are found to contain damage requiring action following the level II inspection, COWI will meet with the City to determine a course of action. Additional level II inspection may be recommended, or additional repair materials orders may be recommended based on the statistical findings. Locations for their application to be determined when the repair contractor is on site. ENGINEERING INSPECTION PLANNING — ABOVE WATER The above water inspection comprises the under -deck (including utilities) and above - deck portions of the structure. COWI will be using a snooper platform for the under -deck inspection that has been specially modified for working under California's ocean piers. This will allow our engineers to get their hands on structural elements, allowing for a much more thorough inspection, and also allow for up -close photographs. Generally speaking, it is not necessary to access every bay in this manner and this proposal assumes that every other bay will be accessed by the snooper, with intermediate bays visually inspected. In the event that a significant defect is observed in the adjacent bay requiring tactile inspection, the snooper can be so positioned. This is a key component of our inspection, but requires that full access to the deck be available. Generally this means that at least 15 feet of clearance along the rail be provided and tight corners will be avoided. Engineers will note, rate, and record visible defects, and assign a proposed method of repair. SAFETY PLANNING While coordinating our activities with the City, COWI will develop and submit work plans for the City's review and approval prior to the commencement of any field investigations. Steps included in the work plan are typically: • A pre-inspection/pre-dive kickoff meeting to be scheduled with the City and personnel with a discussion of known hazards at the site. • Vessel schedule review (if applicable) and an order of operations will be proposed for review and approval. COW] North America, Inc. Page A-3 • Notifications to the Coast Guard, life guards, police, and others as necessary that diving operations will be conducted at the facility. • Dive Safety Plans in conformance with the US Navy Diving Manual limits. • Emergency procedures, numbers, and routes to medical facilities. • A review of any unusual marine activity expected in the area. • Additional items as necessary as planning proceeds. Safety planning is for COWI personnel and the general public during our inspection activities only and does not include any other work performed by others, including any maintenance activities or construction contracts that may arise from this contract. TASK 2 - PERFORM REPAIR DESIGN INSPECTION COWI will perform a Repair Design Inspection 32 of the Pier as described above. This type of inspection collects specific information regarding quantities and types of repairs needed. It is more detailed than a Baseline or Routine Inspection as it anticipates that a repair project is imminent and that the information collected can be effectively incorporated into the repair contract documents. The advantage of this type of inspection is that a cost estimate for the project can be more accurately prepared, which is useful in evaluating options for repair. The team leader for the overall field inspection activities will be Mr. Warren Stewart, PE, SE (CA). The above water inspection will be led by Mr. Jim Kearney, P.E. (CA) and assisted by Mr. Gabriel Verdugo, P.E. (CA). The underwater inspection leader will be engineer -diver, Mr. David Jones, P.E. (CA), who will coordinate daily with Mr. Kearney. The above water and underwater teams will be onsite at the same time. Both teams have performed numerous pile -supported timber waterfront structure inspections, have worked together on previous projects, and are very familiar with the common deterioration mechanisms and repairs for marine timber structures. Our engineers and engineer -divers will record the following information: Type of defect (e.g. crack, erosion, or section loss) Location of defect (e.g. side of pile & elevation; deck soffit or bent sides, located X&Y) • Position of the defect on the structural component (e.g. vertical or horizontal) 2 As defined in ASCE Underwater Investigations, Standard Practice Manual No. 101. COWI North America, Inc. Page A 4 • Size of the defect (e.g. length, width, and depth) Photographs of the defects. Where visibility is limited, COWI will utilize a clearwater box with underwater DSLR camera to record general conditions and typical defects. For the above water inspections, COWI will perform a complete visual inspection with tactile inspection as needed and where possible. Photos will be taken to document findings. Interested City personnel are welcome to join COWI's inspection team as COWI concludes the above water inspection for a tour of the structure above and below the deck to gain personal knowledge of the extent and severity of the typical defects COWI identifies. The City shall be immediately notified of any imminently hazardous conditions observed should such be found. PREPARE A DATA REPORT OF ALL DEFECTS COWI will prepare a written report of findings, which will identify the type, size, location, and position of the defects observed, provide photographs of typical conditions and defects, and summarize the total quantities (data report). If requested, the report will be issued to City as a draft for review, questions, comment, and discussion prior to our completion of the Repair Recommendation Report; otherwise it will be included in the final report with recommendations. As previously noted, all the defect information will be included in an electronic database (such as MS Access). The data can then be sorted and queried according to a number of parameters. For example, detailed repair lists can be prepared depending upon the priority of the defects. Numerous lists can thus be easily generated based upon your requests. TASK 3 — COMPREHENSIVE REPORT Upon completion of the inspection and preparation of the defect database, COWI will prepare a comprehensive report of our findings and recommendations according to the following: PRIORITIZE NEEDED REPAIRS AND MAINTENANCE COWI will evaluate and prioritize the repairs needed. During the inspection, each defect will be assigned a repair type and given a priority code. Because all of the defects are included in a modem database, reports can be run to identify and group defects according to their severity code. From this list, a repair project can be created to COWI North America, Inc. Page A-5 address those that are most severe and then include lower priority repairs according to City budget. REPAIR QUANTITY DETERMINATION COW] engineers and engineer -divers are skilled at preparing repair design documents for rehabilitation. COWI has experience in specifying economical and durable details for repair of timber decks, beams, piles, wrap repair and connections. In addition to evaluating the defect sizes and locations, COWI will field -estimate the likely repair locations, extents, and quantities. All of the above will be inputted into the database for easy sorting and grouping. PREPARE A REPAIR RECOMMENDATION REPORT Upon completion of Prioritize Needed Repairs and Maintenance, COWI will prepare a Repair Recommendations Report that will incorporate all of the findings in the previous tasks and will identify the defects noted in the inspections, the proposed method, quantity, and estimated cost for the repairs, and priority for repair. Previous experience and ASCE's Waterfront Facilities Inspection & Assessment, Standard Practice Manual will be consulted as a guide for methods of repair. This report will also provide CAD sketches for the proposed repair types. Deliverables: A comprehensive report to include: (a) inspection overview and methodology; (b) summary of findings and design recommendations, based on repair needs; (c) assessment criteria; (d) condition report of piles, pile caps, pile wraps, bracing, stringers, attaching hardware, and any noted attributes; (e) new improvements and repair needs recommendation; and _(f) electronic library of all images taken during the inspection process. A draft report will be submitted for review and comment by the City. Upon receipt of written comments, COWI will address and incorporate comments as applicable into the report and submit a final report. COWI has assumed 5 hard copies and an electronic file (PDF) will be provided. TASK 4 — PLANS SPECIFICATIONS, AND COSTS ESTIMATES (PS&E) Upon acceptance of both the inspection and conceptual structural repair reports described above, COWI will prepare contract documents (PS&E) for the repairs desired by the City. COWI is assuming that both piers will be completed at the same time by the same contractor under one contract. Based upon our extensive experience with similar projects, COWI will use commonly accepted repair and improvement details in order to promote the greatest number of bids. These details have been thoroughly proved in previous projects for both ease of use and service life. COWI will make progress submittals of the PS&E's for review and comment at the 60% and 90% levels. Progress submittals will be made in electronic form only (PDF). COWI will discuss written comments when received by the City and incorporate necessary changes into the next submittal. The final submittal will electronic and be full-size hard COW] North America, Inc. Page A-6 copy signed and sealed by a California registered civil or structural engineer, ready to advertise. Drawings will be prepared using AutoCAD, formatted for 22 x 34 inch sheets, on the City's title block. Specification will be prepared using, in order of preference: (a) City standard sections; (b) Standard Specifications for Public Works Construction ("Green Book"); (c) standard marine construction specifications, edited for purpose. COWI shall assist the City in preparing the bid documents by editing their standard documents. COW[ estimates of probable cost will be prepared using methods typically used by contractors. Estimates will be prepared in accordance with the American Association of Cost Engineering, AACE International by a certified cost engineer. A contingency equal to the expected accuracy of the estimate will be included. As the design progresses, the accuracy of the estimate is expected to improve such that the final estimate has little or no contingency. The estimate will be for construction only at current dollars; soft costs for final design, construction management, inspection, the City's own internal costs, and escalation to the actual year the contract is let, will not be included. For purposes of this proposal COWI has assumed a bid package of approximately $300,000. However, the actual package could vary in size. COWI will negotiate the level of effort, fee, and schedule accordingly once the report has been accepted. Deliverables: Plans, Specifications, and Cost Estimates at 60%, 90% and Final TASK 5 — DESIGNER'S SERVICES DURING BIDDING AND CONSTRUCTION The following consist of typical tasks provided by the Engineer of Record during bidding and construction. It is assumed that a competent construction manager will be assigned or hired by the City independently of COWI's services. Construction management activities are not included in this proposal. BID SUPPORT During the bidding period, COWI engineers will be available to answer questions submitted in writing to the City. It is anticipated that these will be merely to clarify the bid process. Any addenda that need to be prepared will be done so at this time. Attendance at job walks and pre-bid meetings is not anticipated. If needed, these can be provided at additional cost based upon the rate schedule in the separate fee estimate accompanying this proposal. CONSTRUCTION SUPPORT AND ADMINISTRATION SERVICES Designer's construction phase services begin with the award of the construction contract. These are typically done on an as -needed basis. The level of effort is highly variable as the schedule of repairs and the capabilities and expertise of the contractor selected is unknown and beyond our control. The costs included in the price proposal are an estimate only. Actual costs will be billed on a time and material basis per the rate COWI North America, Inc. Page A-7 schedule, not to exceed the amount indicated for this task. COWI will notify the City when 50% and 90% of the costs have been accrued. Based upon the progress of the contractor at that point, COWI may request additional fees be authorized. COWI will have no obligation to continue the services if, due to no fault of our own, the additional fees are not authorized. Typical construction phase services include, as requested: 1. Attend pre -construction conference; 2. Review and approval of shop drawings and other submittals, as required by the contract; 3. Respond to written Requests for Information; 4. Attend and/or facilitate coordination and progress meetings, as necessary; 5. Periodic site visits for general observations (special inspection is not included); 6. Preparation of change orders, if needed; and 7. Other activities as requested and authorized by the City. PREPARE RECORD DRAWINGS COWI will prepare as -built record drawings assuming that the contractor has kept adequate records on-site and has provide same to the City for our use. Note: this is essentially a CAD operation as COWI assumes no responsibility in the accuracy or completeness of the information provided. As -built record drawings will not be sealed and signed. LIMITATIONS AND ASSUMPTIONS This proposal is based upon the following assumptions and limitations. Additional fees or adjustments to this scope of work may be required. See Section 2 for detail of fees adjustments known at this time. 1. Delays beyond COWI's control during inspection will be charged at the standby rates indicated in Section 2. 2. In order to take advantage of light wind and ocean swells in the morning, COWI will start work as soon as daylight permits. Although COWI plans on an 8 hour work day + lunch, circumstances may require additional hours. There will be no additional charge for over -time. Also, circumstances may require that COWI work on Saturdays. This is presented in light of Items 7 and 8 under General Requirements/Assumptions, page 6, in the RFP. 3. Areas under the foot of each pier are fenced off. COW] will inspect these areas as possible if provided access. Some area may be inaccessible due to unforeseen conditions. COWI will attempt a work -around, but the report and inspection data may not include this area. If authorized and with additional fee, COWI will remove and replace these obstructions to gain access. A proposal for this service will be prepared at the time of need. COWI North America, Inc. Page A-8 4. In order for the snooper to have access along the handrail, COWI will need to temporarily remove and replace various benches along the length of both piers. COWI has included the costs for this in our proposal. This requires the unbolting and reattachment of the bench legs. COWI will use proper care in handling, but COWI cannot be responsible for damage due to existing conditions. 5. The end of the Balboa pier is occupied by a restaurant building. This end is also frequented by fishermen. COWI expects to be in this portion of the pier approximately 1 to 2 days. Any obstacles to the free access of the handrails and the building envelope will need to be removed by others prior to our mobilization to this area. This would include the tables, seating, and umbrellas. 6. The snooper requires a 15 foot wide x 60 foot long area of exclusive access against the handrail to properly operate and protect the public. COWI will cordon this area off and provide warning signs. This area is moved multiple times per day along the length of one side of the pier and in some case on the other side as well. COWI will require that the public vacate the area as COWI moves. When removed, benches may be stored on opposite side of pier in a manner to discourage tampering or theft. 7. The City will provide reserved parking passes at no charge at the foot of each pier for 5 vehicles for the duration of the inspection work. The snooper will be left on the pier overnight. 8. COWI is aware that a pile has been broken near the end of the Balboa Pier at approximately Bent 40. If this pile is replaced before the inspection, COWI would prefer that the City save both pieces of the existing pile for COWI's inspection. COWI North America, Inc. Page A-9 ORGANIZATIONAL INFORMATION The following organization chart shows the roles and tight -knit relationships of the team COWI has built for this project. Note that two California registered Structural Engineers (SE) are assigned to this project. The expertise and roles for each individual in the organizational chart is provide in the section on key personnel that follows the chart. The same engineers responsible for the inspections will be involved in the repair design. This continuity helps ensure that the repair needs noted in the field are accurately reflected on the drawings. INSPECTION & REPORTING I I CONTRACT DOCUMENTS ABOVE WATER INSPECTION Jim, Ka_ w,, PE Gabrd Verdugo, PE UNDERWATER INVESTIGATION Dead Jcn s, PE Joh Acosta Anthcny Tedeschf REPAIR DESIGN Jim Kms_ my, PE GabrHl Vordugo, PE David .ones, PE COSTESTIMATING Tim Curth, PE, CEP CONSTRUCTION PHASE SERVICES C -Axle[ VOdugo, FE COWI North America, Inc. Page A-10 EXHIBIT B SCHEDULE OF BILLING RATES OCEAN PIERS MAINTENANCE —INSPECTION & DESIGN SERVICES 1. Data Gathering, Review, Project Initiation 100 52 208 254 1170 17,250 9,220 36,960 46,220 29,990 0 9,040 31,680 1,500 500 17,250 18,260 68,640 47,720 30,490 2. Mobilization and Demobilization 3. Inspection & Data Recording 4. Report 5. PS&Es for Repairs 6. Construction Phase Services 1104 I 17,140 1 500 17,640 TOTALS 1888 $156,780 $43,220 I $200,000 Optional Items 1. Up to 2 days of delays beyond COWI's control during inspection are included in the budget and will be mitigated by reordering the work, after which the daily standby rate of $5,000 will be charged. In the event that it will be cheaper to demobilize and remobilize at a later date in lieu of continuing standby charges, the City will be so notified and upon City's written instructions, COWI will demobilize and reschedule, and the amount of Task 2 will be charged. Any additional work not included in this proposal will be priced according to the Schedule of Charges for this project indicated on the following page. COW North America, Inc. Page B-1 Standard Fee Schedule — COWI North America, Inc. PROFESSIONAL, TECHNICAL, AND SUPPORT SERVICES Project Administrator $90.00/hour CAD Operator $110.00/hour CAD Manager $140.00/hour Tech Diver $120.00/hour Engineer I / Specialist I $140.00/hour Engineer II/ Specialist II $170.00/hour Cost Estimator $195.00/hour Senior Engineer $205.00/hour Project Manager $215.00/hour Sr. Project Manager/Sr. Specialist $225.00/hour Principal / Project Director $240.00/hour EQUIPMENT Field Truck $16.00/hour + Mileage $0.65/mile 13' Aluminum Boat $200/day Other Equipment As quoted OUT-OF-POCKET EXPENSES Outside expenses such as: equipment At Cost rental, outside services, printing, copying, travel, and subsistence Subcontractors (as indicated in Cost + 10% proposal or as authorized) COW North America, Inc. Page B-2 EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement. This policy shall also include an endorsement for Federal Acts including Longshore and Harbor Workers' Compensation Act. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant COWI North America, Inc. Page C-1 arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City, its City Council, boards and commissions, officers, agents, volunteers, employees and any person or entity owning or otherwise in legal control of the property upon which Consultant performs the Project and/or Services contemplated by this Agreement shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self- insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days' notice of cancellation (except for nonpayment for which ten (10) calendar days' notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: COWI North America, Inc. Page C-2 A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. COWI North America, Inc. Page C-3 G. Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractor's performance under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. COWI North America, Inc. Page C-4 CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach. * Date Received: 9/22/16 Dept./Contact Received From: Raymund Date Completed: 9/22/16 Sent to: Raymund By: Alicia Company/Person required to have certificate: COWI North America, Inc. — Ocean Piers Maintenance Type of contract: All Others GENERAL LIABILITY EFFECTIVE/EXPIRATION DATE: 4/1/16-4/1/17 A. INSURANCE COMPANY: Travelers Indemnity Company B. AM BEST RATING (A-: VII or greater): A++:XV C. ADMITTED Company (Must be California Admitted): Is Company admitted in California? ❑ Yes ® No D. LIMITS (Must be $1 M or greater): What is limit provided? 1M/2M E. ADDITIONAL INSURED ENDORSEMENT— please attach F. PRODUCTS AND COMPLETED OPERATIONS (Must include): Is it included? (completed Operations status does not apply to Waste Haulers or Recreation) G. ADDITIONAL INSURED FOR PRODUCTS AND COMPLETED OPERATIONS ENDORSEMENT (completed Operations status does not apply to Waste Haulers) H. ADDITIONAL INSURED WORDING TO INCLUDE (The City its officers, officials, employees and volunteers): Is it included? I. PRIMARY & NON-CONTRIBUTORY WORDING (Must be included): Is it included? J. CAUTION! (Confirm that loss or liability of the named insured is not limited solely by their negligence) Does endorsement include "solely by negligence" wording? K. ELECTED SCMAF COVERAGE (RECREATION ONLY): L. NOTICE OF CANCELLATION: IT. AUTOMOBILE LIABILITY EFFECTIVE/EXPIRATION DATE: 4/1/16-4/1/17 A. INSURANCE COMPANY: Travelers Indemnity Company B. C. AM BEST RATING (A-: VII or greater) A++:XV ADMITTED COMPANY (Must be California Admitted): Is Company admitted in California? ® Yes ❑ No /01 E ® Yes ❑ No ir44 oo 1m ® Yes ❑ No ❑ Yes ® No ® N/A ❑ Yes ❑ No ❑ N/A ® Yes ❑ No D. LIMITS - If Employees (Must be $1 M min. BI & PD and $500,000 UM, $2M min for Waste Haulers): What is limits provided? E LIMITS Waiver of Auto Insurance / Proof of coverage (if individual) (What is limits provided?) F. PRIMARY & NON-CONTRIBUTORY WORDING (For Waste Haulers only): G. HIRED AND NON -OWNED AUTO ONLY: H. NOTICE OF CANCELLATION: ❑ Yes ® No N/A ® N/A ❑ Yes ❑ No ❑ N/A ❑ Yes ® No ❑ N/A ® Yes ❑ No III. WORKERS' COMPENSATION EFFECTIVE/EXPIRATION DATE: 9/15/16-9115/17 A. INSURANCE COMPANY: Pennsylvania Manufacturers'Assoc Ins Co B. AM BEST RATING (A-: VII or greater): A:1X C. ADMITTED Company (Must be California Admitted): ® Yes ❑ No D. WORKERS' COMPENSATION LIMIT: Statutory ® Yes ❑ No E. EMPLOYERS' LIABILITY LIMIT (Must be $1 M or greater) 1 M F. WAIVER OF SUBROGATION (To include): Is it included? ® Yes ❑ No G. SIGNED WORKERS' COMPENSATION EXEMPTION FORM: ® N/A ❑ Yes ❑ No H. NOTICE OF CANCELLATION: ❑ N/A ® Yes ❑ No ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED N. PROFESSIONAL LIABILITY EFF: 4/1116-4/1117 CARRIER: LEXINGTON INS Rating: A: XV Non -Admitted LIMIT: 2M/2M ❑ N/A ® Yes ❑ No V POLLUTION LIABILITY ® N/A ❑ Yes ❑ No V BUILDERS RISK ® N/A ❑ Yes ❑ No HAVE ALL ABOVE REQUIREMENTS BEEN MET? ® Yes ❑ No IF N0, WHICH ITEMS NEED TO BE COMPLETED? Approved: , Agent of Alliant Insurance Services Broker of record for the City of Newport Beach 9/22/16 Date RISK MANAGEMENT APPROVAL REQUIRED (Non -admitted carrier rated less than Self Insured Retention or Deductible greater than $ ) ❑ N/A ❑ Yes ❑ No Reason for Risk Management approval/exception/waiver: Risk Management approval needed for the non -admitted status of the General Liability carrier. Approved by Sheri on 1/4/16. Risk Management approval needed for the non -admitted status of the Auto Liability (same as GL) & PL carrier. RM Approved 6/27/16. Approved: Risk Management Date * Subject to the terms of the contract.