HomeMy WebLinkAboutC-8492-1 - PSA for Oil Well Leak Detection, Repair and Reporting Services(1W
PROFESSIONAL SERVICES AGREEMENT
WITH MONTROSE AIR QUALITY SERVICES, LLC FOR
OIL WELL LEAK DETECTION, REPAIR AND REPORTING SERVICES
THIS PROFESSIONAL SERVICES AGREEMENT ("Agreement') is made and
entered into as of this 11 th day of May, 2017 ("Effective Date"), by and between the CITY
OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and
MONTROSE AIR QUALITY SERVICES, LLC, a Delaware limited liability company
("Consultant'), whose address is 1631 East Saint Andrew Place, Santa Ana, California
92705, and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide oil well leak detection, repair and
reporting services ("Project').
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on May 10, 2022 unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
Consultant shall diligently perform all the services described in the Scope of
Services & Schedule of Billing Rates attached hereto as Exhibit A and incorporated herein
by reference ("Services" or "Work"). City may elect to delete certain Services within the
Scope of Services at its sole discretion.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A. In the absence of a specific schedule, the Services shall be performed to
completion in a diligent and timely manner. The failure by Consultant to strictly adhere to
the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely
manner may result in termination of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand-delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not-to-
exceed basis in accordance with the provisions of this Section and the Scope of Services
& Schedule of Billing Rates attached hereto as Exhibit A and incorporated herein by
reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Seventy Five Thousand Dollars and 00/100 ($75,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit A to this Agreement or specifically approved in writing in advance by
City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Montrose Air Quality Services, LLC Page 2
Compensation for any authorized Extra Work shall be paid in accordance with the Scope
of Services & Schedule of Billing Rates as set forth in Exhibit A.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Tanya Jackson to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Municipal Operations Department.
City's Director of Municipal Operations, Utilities or designee shall be the Project
Administrator and shall have the authority to act for City under this Agreement. The
Project Administrator shall represent City in all matters pertaining to the Services to be
rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
Montrose Air Quality Services, LLC Page 3
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers and employees (collectively, the "Indemnified Parties), from and against any
and all claims (including, without limitation, claims for bodily injury, death or damage to
property), demands, obligations, damages, actions, causes of action, suits, losses,
judgments, fines, penalties, liabilities, costs and expenses (including, without limitation,
attorneys' fees, disbursements and court costs) of every kind and nature whatsoever
(individually, a Claim; collectively, "Claims'), and which relate (directly or indirectly) to the
negligence, recklessness, or willful misconduct of the Consultant or its principals, officers,
agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone
employed directly or indirectly by any of them or for whose acts they may be liable, or any
or all of them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable. The policy limits do
not act as a limitation upon the amount of indemnification to be provided by the
Consultant.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis
and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
Montrose Air Quality Services, LLC Page 4
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement orfor other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit B, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
Montrose Air Quality Services, LLC Page 5
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A. Consultant shall be fully responsible to City for all acts and
omissions of any subcontractor. Nothing in this Agreement shall create any contractual
relationship between City and any subcontractor nor shall it create any obligation on the
part of City to pay or to see to the payment of any monies due to any such subcontractor
other than as otherwise required by law. City is an intended beneficiary of any Work
performed by the subcontractor for purposes of establishing a duty of care between the
subcontractor and City. Except as specifically authorized herein, the Services to be
provided under this Agreement shall not be otherwise assigned, transferred, contracted
or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 CADD data delivered to City shall include the professional stamp of the
engineer or architect in charge of or responsible for the Work. City agrees that Consultant
shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the
modification or misuse by City, or anyone authorized by City, of CADD data; (b) the
decline of accuracy or readability of CADD data due to inappropriate storage conditions
or duration; or (c) any use by City, or anyone authorized by City, of CADD data for
additions to this Project, for the completion of this Project by others, or for any other
Project, excepting only such use as is authorized, in writing, by Consultant. By
acceptance of CADD data, City agrees to indemnify Consultant for damages and liability
Montrose Air Quality Services, LLC Page 6
resulting from the modification or misuse of such CADD data. All original drawings shall
be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a
CD, and should comply with the City's digital submission requirements for improvement
plans available from the City's Public Works Department. The City will provide Consultant
with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall
be transmitted to City in formats compatible with Microsoft Office and/or viewable with
Adobe Acrobat.
17.4 All improvement and/or construction plans shall be prepared with indelible
waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six
inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to
City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting
("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90)
days after finalization of the Project. For more detailed requirements, a copy of the City
of Newport Beach Standard Design Requirements is available from the City's Public
Works Department.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
Montrose Air Quality Services, LLC Page 7
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act"), which (1) requires such persons to
disclose any financial interest that may foreseeably be materially affected by the Work
performed under this Agreement, and (2) prohibits such persons from making, or
participating in making, decisions that will foreseeably financially affect such interest.
24.2 If subject to the Act, Consultant shall conform to all requirements of the Act.
Failure to do so constitutes a material breach and is grounds for immediate termination
of this Agreement by City. Consultant shall indemnify and hold harmless City for any and
all claims for damages resulting from Consultant's violation of this Section.
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: George Murdoch - Director of Municipal Operations, Utilities
Municipal Operations Department
City of Newport Beach
100 Civic Center Drive
Montrose Air Quality Services, LLC Page 8
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Tanya Jackson
Montrose Air Quality Services, LLC
1631 East Saint Andrew Place
Santa Ana, CA 92705
26. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in writing,
all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set
forth in the Agreement, Consultant shall be required to file any claim Consultant may have
against City in strict conformance with the Government Claims Act (Government Code
sections 900 et seq.).
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
Montrose Air Quality Services, LLC Page 9
28. PREVAILING WAGES
If any of the Work contemplated under the Agreement is considered a "public
work", pursuant to the applicable provisions of the Labor Code of the State of California,
including but not limited to Section 1720 et seq., not less than the general prevailing rate
of per diem wages including legal holidays and overtime Work for each craft or type of
workman shall be paid to all workmen employed on such. In accordance with the
California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has
ascertained the general prevailing rate of per diem wages in the locality in which the Work
is to be performed for each craft, classification, or type of workman or mechanic needed
to execute the Agreement. A copy of said determination is available by calling the
prevailing wage hotline number (415) 703-4774, and requesting one from the Department
of Industrial Relations. The Contractor is required to obtain the wage determinations from
the Department of Industrial Relations and post at the job site the prevailing rate or per
diem wages. It shall be the obligation of the Contractor or any subcontractor under
him/her to comply with all State of California labor laws, rules and regulations and the
parties agree that the City shall not be liable for any violation thereof.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
Montrose Air Quality Services, LLC Page 10
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Montrose Air Quality Services, LLC Page 11
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM: CITY OF NEWPORT BEACH,
CITY ATTORNEY'S OFFICE a California municipal corporation
Date:/ �i 7 Date: z5 _,1g: _ 2,0 t
By: BC—eo7re
Aaron C. Harp o504.1-+ Mu doch
City Attorneys Director of Municipal Operations,
Utilities
ATTEST: n CONSULTANT: Montrose Air Quality
Date: Services, LLC, a Delaware limited liability
K,
By:
Nxk—
Leilani I. Brown
City Clerk
�qcr Fay%
Attachments
company
Date:
By: (/ ; -
Vijay Manthripragada
President
Date: 51►2h
By:
Allan cks
Treasurer
[END OF SIGNATURES]
Exhibit A — Scope of Services & Schedule of Billing Rates
Exhibit B— Insurance Requirements
Montrose Air Quality Services, LLC Page 12
EXHIBIT A
SCOPE OF SERVICES & SCHEDULE OF BILLING RATES
Montrose Air Quality Services, LLC Page A-1
MCSNTR 5E
I AlK t-EIALITY SERVtCES
SCOPE OF SERVICES FOR THE CITY OF NEWPORT BEACH (CNB)
LEAK DETECTION AND REPAIR
Our primary service will be to provide an ongoing routine Leak Detection and Repair (LDAR) program. Component
inspections will be conducted pursuant to the requirements of EPA Method 21 and summarized as follows:
1. MAIDS will provide field technicians to conduct inspections pursuant to the requirements of SCAQMD Rules,
including quarterly fugitive emissions monitoring, annual inaccessible, first attempt repairs', and re -inspection of
repaired leaks.
2. Technicians will be uniformed and safety trained, and equipped with truck, tools, instrumentation and personal
protective gear as required.
3. Instrument calibration will be performed before each inspection day and documented as required by the District.
Calibration gases, spare parts and charging equipment are maintained in our Regional Field Offices.
4. Following the repair of a leaking component, a MAIDS field technician will re -inspect the repaired component
utilizing EPA Method 21. MAQS technicians will conduct re -inspections as soon as practical following repairs,
and will make every attempt to do so during the inspection sequence for the involved facility; i.e., while
technicians are still conducting their work in the same general area.
5. Our service will include Project Management for oversight and QA/QC as well as a District Manager to manage
scheduling and field level detail.
CONSULTING SERVICES FOR ANNUAL EMISSIONS REPORTING
MAQS will provide environmental consulting services in the preparation of Annual Emissions Reporting (AER) each
year. The purpose of the Annual Emissions Report is to calculate all of the emissions produced by the facility
operations. This is accomplished by gathering data such as oil through -puts, hours of operation, chemical and solvent
usage etc. MAIDS will submit a profile sheet each year to the CNB requesting the information needed.
i Our field technicians are trained in a variety of industrial processes, and are often hired with extensive experience. As a leak is identified,
a first attempt will be made by a field technician to minimize the leak. This service at the time of inspection will be limited to "quick fixes", at
the discretion of the technician, such as tightening down on valve packing. Repairs beyond the immediate repair capabilities of MAOS
technicians will be referred to CNB using the Request for Repair Form (RFR). The cost for performing "quick fixes" is inclusive.
Pagel of 4
rptONTROSlk QUALITY .E
For each oil field process, MAQS will then calculate the mass emissions which are emitted to the atmosphere using
calculation methods that are approved by the SCAQMD. The final submission will then be uploaded on the SCAQMD
online portal by MAQS.
RECORD KEEPING AND REPORTING
SCAQMD Rules require that a facility record all leaks, repairs and re -inspections and create a report for District
submittal. MAQS will prepare the necessary reports and submit them to CNB for review in a quarterly reporting
package approximately 15 calendar days after the end of the quarter. CNB will then be responsible for District
submittals. MAQS will maintain a copy of all reports and they will be available upon request.
DATABASE MANAGEMENT
MAQS will provide access with basic functionality to its online custom web application, used to manage client WAR
programs. Access to the application will provide CNB with the ability to view the facility inventories and summaries,
monitor the WAR program in real time, view leaks on a daily, weekly or monthly basis, view repair status and pending
repair deadlines, greatly assisting environmental managers with the ability to stay current, more involved and better
equipped to make critical decisions regarding its LDAR program.
PROJECT MANAGEMENT
MAQS will provide Project Management support for all our services. Our Project Managers will be the liaisons
ensuring that CNB is given the highest level of responsiveness and quality possible. They will also provide
experience and for oversight and QA/QC.
MAQS also provides an additional level of field supervision with our District Manager. These personnel are:
Contact
Role
Region
Office Phone
Dan Oliva
District Manager
Los Angeles
310-261-3481
For the Services mentioned above, the costs shall be:
WAR Inspection Cost ............................................ ..................................................$1,550 per quarter
Our fixed rate cost is designed to be inclusive. It includes unlimited telephone support relating to WAR, making
minor repairs, re -inspections, reporting and basic access to Montrose Portal).
Preparation of Annual Emissions Report ..............................................................................$1,850 per year
MANAGEMENT OF CHANGE
It is important for MAQS to stay abreast of the ongoing changes in equipment owned and operated by CNB. If
equipment is changed at the facility, MAQS will initiate a Tagging Project. MAQS will provide a crew of Inventory
Technicians to perform the tagging and inventory field work at the onset of the project. The Project Manager will
define the areas needing to be inventoried and other details as needed to meet the requirements of the Rules.
MAQS will provide a data entry clerk to enter the inventoried components into an electronic format.
Page 2 of 4
MONTROSE
Alk' QUALITY SFPNVICliS
TAGGING AND INVENTORY
Rules 1173 and 1176 require that facilities maintain a current component inventory listing all of the components
associated to the LDAR program. This data is used for tracking leaks and for the reporting of fugitive mass emissions
for the Annual Emissions Program. This service will be needed as new equipment is added or piping changes have
occurred.
MAQS will rely on the CNB to notify us when such changes made in the field so that we can schedule and plan
accordingly. We will also identify such modifications during our routine quarterly inspections. When a tagging project
is required, we will bill based on time & materials. For the purposes of approving this project, the cost is a not to
exceed amount of $6,500.00.
OPTICAL IMAGING
In recent years, the use of an optical imaging camera had proven to be successful in finding gas leaks. In particular,
this type of inspection works well when inspecting the tops of tanks or for conducting pre -inspections prior to a District
inspection. This is described as follows:
1. MAQS will provide a trained Field Technician (certified as a FUR thermographer) to conduct inspections
with the infrared camera on specific pieces of equipment including inaccessible and unsafe to monitor
components tanks, heaters, vessels, pits and pipelines.
2. Images taken with the camera will be downloaded and edited (image clarification) to provide the best
representation of any leakage and repairs. This can include cropping, splicing, captions, etc. If the CNB also
wants images showing non -leaking vessels, this can be requested. MAQS will provide an interactive leak
report containing digital pictures of the leaks found including any repairs made. This report will be made
available on the Montrose Portal. Reports can be downloaded on CD to be used by the repair crew allowing
them to see the nature of the leaks.
3. Following the repairs, MAQS will then conduct a follow-up inspection to capture images of the successful
repair. For tank inspections, we recommend coordinating our inspections with the tank repair company so
that we can determine if the repair was successful while the repair crew is still on location. Please note that
inspections need to be scheduled in advance and is based on the availability of the camera.
4. For the purposes of approving this project, the cost is $2,500.00 per year.
Page 3 of 4
MONTE
i \IR QJJALITY S[PVtCES
Should CNB require additional services for permitting, greenhouse gas reporting, annual emissions reporting,
tagging and inventory or other consulting services, an amendment to the Agreement will be required and will
be based on our prevailing hourly rates shown below, unless agreed upon otherwise.
Service
Rate
MAR Project Manager
$ 135/hour
Leak Detection and Repair Technician (Includes truck, tools and TVA)
$ 95/hour
Tagging and Inventory Technician
$ 85/hour
Field Technician with IR Camera
$150/hour
Field Technician (Man watch)
$ 75/hour
Video Editing for IR Camera Images
$ 75/hour
Regular Overtime
1.5 x Hourly Rate
Computer Operator (Data Entry)
$ 75/hour
Identification Tags and Wires
$125/100 tags
Page 4 of 4
EXHIBIT B
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers and employees.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
Montrose Air Quality Services, LLC Page B-1
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date, or
retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers
and employees or shall specifically allow Consultant or others providing
insurance evidence in compliance with these requirements to waive their
right of recovery prior to a loss. Consultant hereby waives its own right of
recovery against City, and shall require similar written express waivers from
each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers
and employees shall be included as insureds under such policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
Montrose Air Quality Services, LLC Page B-2
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
G. Timely Notice of Claims. Contractor shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Contractor's
performance under this Contract, and that involve or may involve coverage
under any of the required liability policies. City assumes no obligation or
liability by such notice, but has the right (but not the duty) to monitor the
handling of any such claim or claims if they are likely to involve City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
Montrose Air Quality Services, LLC Page B-3
CERTIFICATE OF INSURANCE
CHECKLIST
City of Newport Beach
This checklist is comprised of requirements as outlined by the City of Newport Beach. *
Date Received: 10/31/16
Dept./Contact Received From: Joan
Date Completed: 4/27/17 Sent to: Joan By: Alicia
Company/Person required to have certificate: Avanti Environmental, Inc.
Type of contract:
All Other
GENERAL LIABILITY
EFFECTIVE/EXPIRATION DATE: 12/31/16-12/31/17
A. INSURANCE COMPANY: Crum & Forster Specialty Insurance Co.
B. AM BEST RATING (A-: VII or greater): A: XII
C. ADMITTED Company (Must be California Admitted):
Is Company admitted in California? ❑ Yes ® No
D. LIMITS (Must be $1M or greater): What is limit provided?
E. ADDITIONAL INSURED ENDORSEMENT—please attach
F. PRODUCTS AND COMPLETED OPERATIONS (Must
include): Is it included? (completed Operations status does
not apply to Waste Haulers or Recreation)
G. ADDITIONAL INSURED FOR PRODUCTS AND
COMPLETED OPERATIONS ENDORSEMENT (completed
Operations status does not apply to Waste Haulers)
H. ADDITIONAL INSURED WORDING TO INCLUDE (The City
its officers, officials, employees and volunteers): Is it
included?
I. PRIMARY & NON-CONTRIBUTORY WORDING (Must be
included): Is it included?
J. CAUTION! (Confirm that loss or liability of the named insured
is not limited solely by their negligence) Does endorsement
include "solely by negligence" wording?
K. ELECTED SCMAF COVERAGE (RECREATION ONLY):
L. NOTICE OF CANCELLATION:
1 M/2M
® Yes
❑ No
® Yes
❑ No
® Yes
❑ No
® Yes
❑ No
® Yes
❑ No
❑ Yes
® No
® N/A ❑ Yes
❑ No
❑ N/A ® Yes
❑ No
II. AUTOMOBILE LIABILITY
EFFECTIVE/EXPIRATION DATE: 12/31/16-12/31/17
A.
INSURANCE COMPANY: Travelers Indemnity Company of CT
B.
AM BEST RATING (A-: VII or greater) A++: XV
C.
ADMITTED COMPANY (Must be California Admitted):
Is Company admitted in California?
® Yes ❑ No
D.
LIMITS - If Employees (Must be $1M min. BI & PD and $500,000
UM, $2M min for Waste Haulers): What is limits provided?
1M
E
LIMITS Waiver of Auto Insurance / Proof of coverage (if individual)
(What is limits provided?)
N/A
F.
PRIMARY & NON-CONTRIBUTORY WORDING (For Waste
Haulers only):
® N/A ❑ Yes ❑ No
G.
HIRED AND NON -OWNED AUTO ONLY:
❑ N/A ❑ Yes ® No
H.
NOTICE OF CANCELLATION:
❑ N/A ® Yes 0 No
III. WORKERS' COMPENSATION
EFFECTIVE/EXPIRATION DATE: 12/31/16-12/31/17
A.
INSURANCE COMPANY: Commerce and Industry Insurance Company
B.
AM BEST RATING (A-: VII or greater): A; XV
C.
ADMITTED Company (Must be California Admitted):
® Yes
❑ No
D.
WORKERS' COMPENSATION LIMIT: Statutory
® Yes
❑ No
E.
EMPLOYERS' LIABILITY LIMIT (Must be $1M or greater)
1,000,000
F.
WAIVER OF SUBROGATION (To include): Is it included?
® Yes
[]No
G.
SIGNED WORKERS' COMPENSATION EXEMPTION FORM:
® N/A ❑ Yes
❑ No
H.
NOTICE OF CANCELLATION:
❑ N/A ® Yes
❑ No
ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED
IV. PROFESSIONAL LIABILITY SAMEASGL EFF12131116-12131/17
❑ N/A ® Yes ❑ No
V POLLUTION LIABILITY
V BUILDERS RISK
HAVE ALL ABOVE REQUIREMENTS BEEN MET?
IF NO, WHICH ITEMS NEED TO BE COMPLETED?
Approved:
4/27/17
Agent of Alliant Insurance Services Date
Broker of record for the City of Newport Beach
® N/A ❑ Yes ❑ No
® N/A ❑ Yes ❑ No
® Yes ❑ No
RISK MANAGEMENT APPROVAL REQUIRED (Non -admitted carrier rated less than _;
Self Insured Retention or Deductible greater than $ ) ❑ N/A ❑ Yes ❑ No
Reason for Risk Management approval/exception/waiver:
Risk Management approval needed due to GL carrier being non -admitted
Approved:
Risk Management Date
* Subject to the terms of the contract.