Loading...
HomeMy WebLinkAboutC-2307 - 1981-82 Slurry seal ProgramTransamernc� Insurance Services 777777 May 21, 1984 Transamerica Insurance Group 2141 E. Highland, Sude 21,0 P0. Box 21247 Phoenix, Arizona 8503 (602) 956 -7000 City of Newport Beach Public Works Department P. 0. Box 1768 Newport Beach, California 92663 -3884 0/lieisl /nsurar S o f M 1984 m ONmpics M11 CERTIFIED RETURN RECEIPT REQUESTED Re: Our Claim No: 8,643,447 Our Principal: ECNA, Inc. Bond No: 5750 -82 -48 Project Description: 1981 -82 Slurry Seal Program - Contract No. 2307 Gentlemen: Transamerica Insurance Company is the surety on the performance and payment bond executed in connection with the project described above. Transamerica has received correspondence and Summons and Complaint from sub - contractors and suppliers who allege that they are owed monies for labor, equipment and material that were allegedly furnished to the principal in connection with the project described above. As the surety, Transamerica Insurance Company requests that you make no further payments of any contract funds of any nature, whether in the form of earned estimates, retainage, extras, etc., to the principal without the express written consent and authority of Transamerica. Transamerica hereby requests that all further sums that may be due and payable under the contract be paid directly to Transamerica. Very truly yours, Date ES SENTTO:`"`' ayor Lawrence Richardson ❑ COUnClltnell 3 Claim Representative Fagar S rney . D1r. ❑ GenSery Dir. ❑ FS & R Dir. LR /cf ❑ Planning fir. 0Police Chid `d'P W. Dir ❑ her 525 kz 'i '�J August 16, 1983 ECNA, Inc. 642 N. 17th Ave. Phoenix, AZ 85007 CITY OF NEWPORT BEACH OFFICE OF THE CITY CLERK (714) 640 -2251 Subject: Surety: Transamerica Insurance Co. Bonds No.: 5750 82 48 Project: Slurry Seal Program 1981 -82 Contract No.: C -2307 The City Council on July 11, 1983 accepted the work of subject project and authorized the City Clerk to file a Notice of Completion and to release the bonds 35 days after the Notice has been recorded. The Notice was recorded with the Orange County Recorder on July 20, 1983, Reference No. 83- 312809. Please notify your surety company that the bonds may be released 35 days after this recording date. Sincerely, Wanda E. Andersen City Clerk WEA:lr cc: Public Works City Hall • 3300 Newport Boulevard, Newport Beach, California 92663 Please return to: City Clerk City of Newport Beach 3300 Newport Blvd. P.O. Box 1768 Newport Beach, CA 92663 -3884 No mRSIOERAIS 83- 312809 p em«■■em ae.0"Or EXEMPT C2 NOTICE OF COMPLETION PUBLIC WORKS E '400 PM JUL 20 '83 10 All Laborers and Material Men and to Every Other Person Interested: YOU WILL PLEASE TAKE NOTICE that on the Public Works project consisting of Slurry Si on which ECNA Inc. 642 N 17th Ave Phoenix, A7 85007 was the contractor, and Transamerica Insurance Co., 1150 S. Olive St., Los Angeles was the surety, was completed. 90954 TY OF NEWPORT BEACH e 4�e 0, )44 Public Works Director VERIFICATION I, the undersigned, say: I am the Public Works Director of the City of Newport Beach; the foregoing Notice of Completion is true of my own knowledge. I declare under penalty of perjury that the foregoing is true and correct. Executed on July 13, 1983 at Newport Beach, California. ell v J C/'J' / �/ 4 Public Works Director VERIFICATION OF CITY CLERK I, the undersigned, say: I am the City Clerk of the City of Newport Beach; the City Council of said City on July 11, 1983 accepted the above described work as completed and ordered that a Notice of Completion be filed. I declare under penalty of perjury that the foregoing is true and correct. Executed on July 13, 1983 att� Newport Beach, California. City Clerk f STATE OF CALI"HIA GEORGE DEUKMEJIAN, GOwmor DEPARTMENT OF INDUSTRIAL RELATIONS AFM DIVISION OF LABOR STANDARDS ENFORCEMENT 245 W. BROADWAY, 4TH FLOOR, Ste. 450 LONG BEACH, CALIFORNIA 90802 (213) 590 -5044 C_ =a3 OLSE 905 FINAL STOP NOTICE DLSE Case No: Project Name: Contract No: Prime Contractor: Date: CITY CLERK CITY OF NEWPORT BEACH 300 Newport Blvd. Newport Beach, CA 92663 -3884 ATTN: G. P. DUNIGAN, JR. Public Works Department Gentlemen: 05- 13592 -1 /JD 1981 -82 SLURRY 2307 E.C.N.A., INC. July 21, 1983 7983A. r ., . After full investigation, this Division has determined that the above named employer has failed to pay prevailing wages as required by Labor Code Sections 1774 and 1815, to employees engaged in per- forming work in the execution of the above contract as follows: No. of violations 540 Penalties (at $25 per violation) $13,500.00 Prevailing wages due per Verified Claim and Stop Notice filed July 21 1983 $20,775.96 Total amount due $34.275.96 Pursuant to Labor Code Sections 1775, 1726 and 1727 and other pro - vision of law, you are requested to withhold the total sum shown above from any and all payments owed by you under the above contract now or in the future. If you receive notice of a suit filed by the contractor to recover the penalties, this amount should be retained pending the outcome of the suit as provided in Labor Code Section 1731. If no such notice of suit is received within the 90 -day period after cessation, 04'0. Ad. &Y.''n`� i1t".'?m'AVer'<Y: _ -mnx .z'X'vw�- rvssw4w/w••�:n+n.vhW!. _ FINAL STOP NOTICE Date: July 20, 1983 Page 2 acceptance, or completion of the job, the penalties withheld shall be remitted to the Division of Labor Standards Enforcement at the above address for transmittal to the State Treasurer. In addition, if the contractor consents in writing, the amount withheld as pre- vailing wage underpayments shall be remitted to the Division of Labor Standards Enforcement at the above address. Filed: July 21, 1983 By'� OSEP M. DIFRANCESCO Senior Special Investigator Labor Code Section 1726 The body awarding the contract for public work shall take cognizance of violations of the provisions of this chapter committed in the course of the execution of the contract. Labor Code Section 1727 Before making payments to the contractor of money due under a con- tract for public work, the awarding body shall withhold and retain therefrom all amounts which have been forfeited pursuant to any stipulation in a contract for public work, and terms of this chapter. But no sum shall be withheld, retained or forfeited, except from the final payment, without a full investigation by either the Division of Labor Standards Enforcement or by the awarding body. JMD:rcp Enc. cc: Prime Contractor: E.C.N.A., INC. Bonding Company: Transamerica Insurance Company Contractor's License Board (local) Area Administrator Peter J. irsfeld, Atty. At Law STATE Or EALIrORNIA • • OEPARTNERT Or #NOUSTRIAL RELATION DIVISION Or LABOR STANDARDS EN/OREENEw VERIFIED CLAIM AND STOP NOTICE To: CITY CLERK CITY OF NEWPORT BEACH 3300 Newport Blvd. Newport Beach, CA 92663 -3884 1981 -82 SLURRY PROGRAM Project 2307 Contract Number Please take notice that the persons named on the attached exhibits have performed labor for E.C.N.A., INC. or other person acting by your authority on the work of improvement in progress or being completed at your property at, in, and-about the City of Newport Beach, California. The total amount of said contract is the sum of $161,091.00 (one hundred sixty -one thousand and ninety -one dollars) and payments for labor performed have been made incorrectly. There now remains due, owing, and unpaid $20,775.96 (twenty thousand seven hundred seventy -five dollars and ninety -six cents) after deducting all just credits and offsets. Said labor was performed for and furnished to E.C.N.A., INC. upon the work of improved named above. (see attachments) This Notice is given pursuant to the provisions of the laws of the State of California and particularly Sections 3103 and Sections 3181 through 3187 of the Civil Code, and Section 1727 of the Labor Code. You are hereby required, pursuant to said laws, to withhold any and all payments which are or here- after may become due to the Contractor hereinabove named to the extent of the total claim as hereinabove shown. I declare under penalty of perjury as follows: I Investigator acting for the State Labor Commission declitation on behalf of the workmen whose names a I have read the foregoing Verified Claim and have of the facts relating thereto, and based upon all at this time and based upon all of the statements me at this time. I am informed and believe that th Claim is true and correct, and that the facts have this Verified Claim. am a Senior Special er. I execute this re set forth herein. made an investigation the facts known to me and information given e foregoing Verified been found to support Executed on this 20th day of July, 1983 at Long Beach, California. VICTOR VESSEY STATE LABOR COMMISSIONER (� OSEPH M. AIFRANCESCO Senior Special Investigator JMD:rcp HG EnH6) H4 •-i4 C-A Ow •' Or• 'd a 8 :r0 r. rr q I OC w r• KO a x Oa •C O .0 a G 7 Mo w � B �''w %'C q r•r• % q p. q w 6: R w O M a q fD A 0�! •� M e OA Otn AO �Mp C: dry+ L► �ONZ wr 1p M�H�C. A A� H 0 n7 tom' A K K "(n O wo t• y T� O y �o L7 �1 O M M M M r o W r r r r r r F• r r \ r F+ \ \ F• F+ \ \ O \ F• \ •D 0) \ \ r r \ \ F• r \ \ � N, � O) to \N NM Nw r r F•F• NN NN OD& H\ & 01 0 to W tD W A W 0) A too %00 \ \ \ \ CD CO 0) O 07 O 0) O 0) W 03 0) 0) Cr N N N N 0 W N w N W N W N N N N N W N w W N O r 41 O 0) O O 0) �' N y w to co �o w w �o H R P 0i a o r F• r r r F• w W r 1'' ro W J W W • � J O M • W • 10 • W • W W J W J • \0 • o W W 01 A V J A r r A � ro %O r %0 %0 O7 co �O �o �0 • M O H N Ln N N N r N N N O O M M r W �' r r h• F• r r r r N N N A J A W W A A A O A A w w A A A F• �" y as A �, VI q. r F• p, o� J rn r ON w r o J D1 T W A W J J 0% N W b ii J N N O A N {n 0) O Ln �{ q J • In • 0) • N O J • In • N N • W 6 n q O W 01 N N N H •D N � •� R d F C O• T A V F• 4m N W W N W W N A r q M 0) W N O In �0 W 01 O 10 �0 W J � go m r N to 0) A Vi V+ J R d C q r r r N N 0) p N, O J A G 00% Ln Ln O w m co O W cl 0. 0) In W 0) A • O N F H In N O 0� 0 0� M 0% ON J O ro q OD 10 CD r M w w J N O N In J J V J N ~ In In O 1n O M 0 In (A W • • . • • • • W O O O O O O 0 0 a o � x0 in tnx HH4 Hq HHx ►eIH4 Hx Hlq onty VIM jWO x Lf 7'O C O .qW G NOO Rr 'O a NO Or a N NOn Pi Y NOO n NW A+ N N N � OA N F D ~ so �n N m rt W W 1.- 0-0 Mp W M0 Sd M� 0 0 H 1ng•x+ mHpA W. tr w0Y r70 r r• n C4 go 9%% 01 � K to ° A A °a n 0 to ��0.»y 0 to tt% w r n K 0 O O 0 0 0 0 0 0 M M � �qq If rP% Wm %D CD m %0 OD mm NO Yr %D CD %0 OD Yw w YN YY N YN NJ Y N YY h+Y YN NY rt mY OD Y mm Y\ co tow OD mm %O W \\ \\ \ \\ I \m \\ \\ \\ \\ \\ 0 CD m CD m OD m N m m m m CD CO m m m m N N N N N N N N N N W N N N N N W N Y OD w Y m �D m m m m co m :J • • Y • • . • • • M H rt t0 .O •D zD �D zD O n O% H N Y N Y N H a. r Y Y r Y r r .O w w pM. • w ►3 r• p A V to J J J J J Y O O O) 07 %0 m 'D m m W •p • zO O. O� w t0 • • ON �0 O+ z0 zO b. yqn as O O Y Y N w N Y Y N H C M M H M O to u+ w w A w A w w p 7 i0 tD t0 W w A W A w W Al O O J V w J W J J O Y p, In Y O %n J w O1 N A fA ti VI W J m to N A A N • A N m t0 Q. W 01 A W O m m N at In K d G a A Y A m Y M+ L" m M w m w Y N y a► .D w o w J J •D �"' �'' N R In A • B O Y to Y O w Y N N K C 1•+ n r r Y ► t! t Y %0 O J LA O% V O t0 zD W N m N m A J m %D N w W in J Y W N r. n LA Ln Y A N w J M A m �"• to N O W O O In to %n L" R 0 0 0 • 0 • 0 0 0 0 0 0 ►' O O (? O O O O O O O n v n � � 6 m °•gym o z m o w N �••, o p m o o J O r A C w w n J O A N h ` C Nn to v m m x zo ul o� r b rn m m p 0% Ln A O b h O O p w t . . . R Y • w ( w° M M c cK p xa w nP; x x tv M µ K K 0 0p n y o M µ n p pe p py pay y �yvD B B M M 'C O� yy � a H H 0 0 O t" A Al a to K K W K K 0 0 K O O r OD A, p " OD CD O OD 0 0ODD CD p N N W W N N N r O O, c co 7 7d n no m r r r r m m r J M M � a A � a M y M a N N o o Y Y W r W r r r p J L Ln H p .y z z0 � HM P O O p p Y r a a . w a OD m m N N a a a ti O ro y m~ r O r r t to t to p p kG r H i i-'• tv • • • • • • p p N p p K G o m m o o• W+ n G m H H A c+ y m o o m m ro m o a m . . . . ° ° V * w p + 0 J r r W W w pM y * p p o r+ J J r r N N W H c a h h h m J chi a Y • 0 SEW pp CITY OF NEWPORT BEACH ,_, CqC /pp RNxP Mayor Evelyn R. Hart Mayor Pro Tern Philip R. Maurer Council Members July 13, 1983 Bill Agee Lee A. Branch John C. Cox Jr. County Recorder Jackie Heather P.O. Box 238 Ruthelvn Plummer Donald A. Strauss Santa Ana, CA 92702 Dear Mr. Branch: Enclosed for recordation are 3 Notices of Completion of Public Works projects consisting of: 1. Installation of Traffic Signals and Lighting @ Jamboree and Birch and Balboa and 15th Street, Contract No. 2359 on which Baxter - Griffin was the Contractor and Ohio Farmers Insurance Co. was the Surety. 2. Morning Canyon Road and Seaward Road Storm Drain Rehabilitation, Contract No. 2339 on which Ameron, Inc. was the Contractor and Federal Insurance Co. was the Surety. 3. 1981 -82 Slurry Seal Program on which ECNA, Inc. was the Contractor and Transamerica Insurance Co, was the Surety, Contract No. 2307. Please record and return to us. Sincerely, Z� � 4#�' Wanda E. Andersen City Clerk WEA:Ir attach. City Hall • 3300 Newport Boulevard, Newport Beach, California 92663 i 0 TO: CITY COUNCIL BY THE CITY COUNCIL CITY OF NEWPORT BEACH ns Era a, FROM: Public Works Department C - J3v-) July 11, 1983 CITY COUNCIL AGENDA ITEM NO. F —IY SUBJECT: ACCEPTANCE OF 1981 -82 SLURRY SEAL PROGRAM (C -2307) RECOMMENDATIONS: 1. Accept the work. 2. Authorize the City Clerk to file a Notice of Completion. 3. Authorize the City Clerk to release the bonds 35 days after Notice of Completion has been filed. 4. Assess liquidated damages in the amount of $8,300. DISCUSSION: The contract for the construction of the 1981 -82 Slurry Seal Program has been completed to the satisfaction of the Public Works Department. The bid price was $161,091.00 Amount of unit price items constructed 178,859.74 Amount of change orders None Total contract cost $178,859.74 Funds were budgeted in the General Fund. The increase in the contract cost over the bid price was due to a slightly (less than 1 /64th inch) thicker application of the slurry seal mater- ial. The design engineering was performed by the Public Works Department. The contractor is ECNA, Inc., of Phoenix, Arizona. The contract date of completion was August 31, 1982. The contract required completion of the work within 45 days of award resulting in a completion date of August 31, 1982. Due to other work, with staff concurrence, the contractor did not start this project until August 9. Starting the 45 -day period on that date would result in a completion date of September 23. The work was not completed until December 15, 83 days after the adjusted completion date. It is recommended that, in accordance with the contract's Standard Specification, liquidated damages be assessed in the amount of $8,300 ($100 per day). j Benjamin B. Nolan Public Works Director GPD:jd �f July 11,1983 CITY OF NEWPORT BEACH P.O. BOX 1768, NEWPORT BEACH, CA 92663 -3884 PUBLIC WORKS DEPARTMENT 714/640 -2281 Irsfeld, Irsfeld & Younger Attorneys at Law. 7060 Hollywood Boulevard Hollywood, California 90028 Attention: Mr. Peter J. Irsfeld Subject: ECNA, 1981 -82 Slurry Seal Program (C -2307) Gentlemen: This is in response to your letter of July 8, 1983 regarding the recommendation for imposition of liquidated damages on the above contract. Your client's position, and your letter regarding the matter, will be conveyed to the City Council so that your concerns may be taken into consideration in making a decision. With regard to some of the specific points raised in your letter, we would like to reply as indicated herein. First, the work which was redone was evidently not disputed by ECNA because it was so clearly defective that the need for remedial work was obvious. The calculation of the number of days for which assessment of liquidated damages was recommended did not include a reduction for weekends and holidays as the contract provides that liquidated damages are to be assessed on a calendar day rather than a working day basis. The calculation did not reflect a reduction for rainy days as the work extended into the rainy season only because of the need to redo the original defective work.. We feel that.your client, ECNA Inc., acted in a responsible manner in correct- ing the defective work. Nonetheless, the work was in fact defective, and had to be corrected to provide a satisfactory finished product. In addition, we be- lieve the work could have been conducted more expeditiously than was the actual case. The net result included significant and prolonged inconvenience to the general public, and extra costs and damages incurred by the City. ry truly yours Ga2� min Nolan Public Works Director cc: City Council BBN:jd City Attorney 3300 Newport Boulevard, Newport Beach JAMES B. IRSFELD, JR. N ENN ETH C. YOUNGER R. WENDELL BUTTREY ROBERT W. GARCIN JOHN H. BRINK' CHARLES W. STOLL PETER J. IRSFELD JAMES J. WALDORF' WILLIAM A. FRANCIS MICHAEL 8, LUFTMAN' C. PHILLIP JACKSON ROSS R. HART PETER C. WRIGHT MICHAEL R. YOUNGER CARLA D. ALTIZER L. REID HANSON. JR. PAUL E. PIERCE, JR. 'A PROFESSIONAL CORPORATION 1 IRSFELD, IRSFELD S YOUNGER ATTORNEYS AT LAW GLENDALE OFFICE 226 WEST BROADWAY, SUITE 500 7060 HOLLYWOOD BOULEVARD GLENDALE. CALIFORNIA 91204 HOLLYWOOD, CALIFORNIA 90028 TELEPHONE 12131 242 -6859 TELEPHONE 12131 466-4161 July 8, 1983 Mr. Benjamin B. Nolan Public Works Director City of Newport Beach 3300 Newport Boulevard Newport Beach, California 92663 RE: 1981 -82 Slurry Seal Program (C -2307) E.C.N.A. Dear Mr. Nolan: .. JAMES B. IRSFELD 11880 -19661 JOHN A. WEYL OF COUNSEL � 7 0 Please be advised that we represent E.C.N.A. We are in receipt of Mr. Dunnigan's June 29, 1983, letter to our client and the Public Works Department's recommendations to the City Council regarding acceptance of the work performed by, our client. The purpose of this letter is to set forth our client's position concerning the Department's recommendations. I would appreciate if you would present these comments to the City Council so they may have the benefit of our client's position on this matter. The recommendation states a starting date of August 9th and a completion date of December 15, 1982. The contract provided for completion within 45 days of commencement and hence the recom- mendation is for the assessment of liquidated damages ($100 per day) for 83 days. First, the number of days between August 9th and December 15th is 128 days. If 45 days is substracted a total of 80 days rather than 83 days is left. Secondly, no consideration has been given for the inclusions of Saturdays and Sundays in the time computation. It is our under- standing that the contract did not require weekend work and therefore we do not believe Saturdays and Sundays should be com- puted in determining time of performance. Also, no considera- tion was given for holidays. Labor Day (September 5); Admis- sion Day (September 9) and Thanksgiving (November 24) fell dur- ing this period. we calculate a total of 36 Saturdays and Sun- days and three holidays during this period. This reduces the possible days upon which to assess liquidated damages to 44 days. • Benjamin B. Nolan July 8, 1983 Page Two 9 Third, approximately 20 days delay was due to E.C.N.A. having to rework a number of streets. Although E.C.N.A. did not agree with the job site inspector, it elected to redo the work rather than to dispute the item with the City. we do not believe it is equitable to charge these days to E.C.N.A. for purposes of computing liquidated damages. Fourth, no consideration has been given to rain days which pre- vented work by our client. This information should be readily available from the weather service and we believe it is the Department's responsibility to take such matters into considera- tion in determining the assessment of liquidated damages. At no time during the performance of the contract did anyone from the City of Newport Beach mentioned the subject of liqui- dated damages or inform our client that the City intended to enforce this provision of the contract. Some months after the contract had been completed, our client had several conversa- tions with Mr. Dunnigan in an effort to speed up the acceptance procedure so as to have the retention monies paid. For some reason, Mr. Dunnigan became hostile during these conversations and this was the first time that the subject of liquidated dam- ages arose. I also spoke to Mr. Dunnigan in the latter part of June, 1983 and experienced his feelings of animosity towards our client. I mention these factors only because the Depart- ment's recommendation seems so harsh as to border on an non- objective approach to this situation. I believe it is also important for you to know that our client lost between $25,000 to $35,000 on this job. A large portion of this loss was attributable to its not contesting the in- spector's decision concerning acceptance of certain streets and the redoing of those streets. I believe this is an important factor for you to consider in that it evidences my client's desire to work with the City and produce a job satisfactory to the City even to the extent of losing money on the contract. I feel confident that when the above time periods are recalcu- lated, you will see that this is not a situation where our client should be punished by the imposition of liquidated dam- ages. Very truly yours, IRS&E4D, IRSFEIJD & YOUNGER J. Irfseld PJI:mtg cc: Carroll G. Wilson SENT BY MESSENGER 0 0 STATE OF CALIFORNIA GEORGE DEUKMEJIAN, Governor DEPARTMENT OF INDUSTRIAL RELATIONS DIVISION OF LABOR STANDARDS ENFORCEMENT 12,45 W. BROADWAY, 4TH FLOOR Ste. 450 (213)ACALIFORNIA 0 SOSOz 4 PRELIMINARY STOP NOTICE IN REPLY REFER TO: May 18, 1983 05- 13592/JD CLERK CITY CITY OFNEWPORT BEACH NF�YPpj OF 3300 Newport Blvd. to "9 Newport Newport Beach, CA 92663 -3884 dry Re: ECNA Z �'98N6 Project No. 2307 Dear Sir: This agency is currently involved in an ongoing in- vestigation of complaints regarding prevailing wage violations, California Labor Code Section 1774 by the above name contractor. Pursuant to Section 1727 of the California Labor Code, we respectfully request at this time that you withhold Payment from the contractor pending the disposition of the investigation by this Division. If you have any questions, please feel free to contact the undersigned. Very truly yours, STATE LABOR COMMISSIONER SEPH M. DIFRANCESCO Senior Special Investigator JMD:rcp DLSE WS Date s� = Ciii'IES SENTTO: Cs Mayor D Councilmen mpager wrTtorneY Q Bldg. Dir. ❑ GenSery Mr. L7PB&RDir. ❑ Planning Dir. C_l P e Chief LWPX Dir nV N V'XATP(1R' P RF A ru DATE: July 20,1982 TO: FINANCE DIRECTOR PUBLIC WORKS FROM: City Clerk SUBJECT: Contract No. 2307 Description of Contract Program OFFICE OF THE CITY CLERK (714) 640 -2251 -to C9& -2 /.;0/rL 1981 - 82 Slurry Effective date of Contract July 20, 1982 Authorized by Resolution No. Min.Act, adopted on 6/28/82 Contract with ECNA, INC. Address 642 N. 17th Avenue Phoenix, AZ 85007 Amount of Contract $161,091.00 Wanda E. Andersen City Clerk WEA : 1 r City Mall • .3300 Newport Boulevard, Newport Beach, 92663 I July 16, 1982 TO: CITY CLERK FROM: Public Works Department SUBJECT: 1981 -82 SLURRY PROGRAM, C -2307 Attached are four copies of the subject contract documents. Please have executed on behalf of the City, retain your copy and the insurance certificates, and return the remaining copies to our department. Gilbert Wong Project Engineer GW:em Att. I I "I am aware of and will comply with Section 3700 of the Labor Code, requiring every employer to be insured against liability for.Workers' Compensation or to undertake self- insurance before commencing any of the work." ,o �9�v Date Si nature Contractor C -2307 STATEE OF CALIFORNIA I OFFICIAL SEAL ' F ECNA INCO ?PJWZD OCT. 26, 1976 << - - oouleva CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT PROPOSAL • Page 1 Proposal 1981 -82 SLURRY SEAL PROGRAM CONTRACT NO. 2307 To the Honorable City Council City of Newport Beach 3300 Newport Boulevard P.O. Box 1768 Newport Beach, CA 92663 -3884 Gentlemen: The undersigned declares that he has carefully examined the location of the work, has read the Instructions to Bidders, has examined the Plans and Special Provisions, and hereby pro- poses to furnish all materials and do all the work required to complete this Contract in accordance with the Plans and Special Provisions, and will take in full payment therefor the following unit price for the wgrk, complete in place, to wit: ITEM QUANTITY ITEM DESCRIPTION UNIT TOTAL NO. AND UNIT UNIT PRICE WRITTEN IN WORDS PRICE PRICE 1. 2,700 Furnish all labor, equipment and material; Extra Long and perform all work necessary to prepare Tons for and apply emulsion- aggregate slurry as shown on the plan @ Fifty -three Dollars and Eighty -three Cents $ 53.83 $ 145,341.00 Per Extra Long Ton 2. Lump Sum Traffic striping and pavement markings Fifteen Thousand Seven @ Hundred Fifty Dollars and No Cents $ 15,750.00 Per Lump Sum TOTAL PRICE WRITTEN IN WORDS: One Hundred Sixty -one Thousand Ninety -one Dollars and No Cents $ 161,091.00 379937 - Class A ECNA INC Contractor's Lic. No. & Classification Bidder (6021 258 -7443 Bidders a ephone No. vpr,MMVML'I:i'� S /Jack M. Mitchell. President Authorized Signature/Title 0 • Page 2 INSTRUCTIONS TO BIDDERS The following contract documents shall be completed, executed and received by the City Clerk in accordance with NOTICE INVITING BIDS: 1. PROPOSAL 2. INSTRUCTIONS TO BIDDERS 3. DESIGNATION OF SUBCONTRACTOR(S) 4. BIDDER'S BOND (sum not less than 10% of total bid price) 5. NON- COLLUSION AFFIDAVIT 6. STATEMENT OF FINANCIAL RESPONSIBILITY 7. TECHNICAL ABILITY AND EXPERIENCE REFERENCES except that cash, certified check or cashier's check (sum not less than 10% of the total bid price) may be received in lieu of the Bidder's Bond. The title of the project and the words SEALED BID shall be clearly marked on the outside of the envelope containing the bid. Bids shall not be received from bidders who are not licensed in accordance with the provisions of Chapter 9, Division III of the Business and Professions' Code. The low bidder shall also be required to possess a City of Newport Beach business license prior to execution of contract. Bids shall be submitted on the attached PROPOSAL form. The additional copy of the PROPOSAL form may be retained by the bidder for his records. The estimated quantities indicated in the PROPOSAL are approximate, and are given solely to allow the comparison of bid totals. Bids are to be computed upon the estimated quantities indicated in the PROPOSAL multiplied by unit price submitted by the bidder. In the event of dis- crepancy between wording and figures, bid wording shall prevail over bid figures. In the event of error in the multiplication of estimated quantity by unit price, the correct multiplication will be computed and the bids will be compared with correctly multiplied totals. The City shall not be held responsible for bidder errors or omissions in the PROPOSAL. Contract documents shall bear signatures and titles of persons authorized to sign on behalf of the bidder. For corporations, the signatures shall be of the President or Vice President. For partnerships, the signatures shall be of a general partner. For sole ownership, the signature shall be of the owner. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the con- tract. A copy of said determination is available in the office of the City Clerk. All parties to the contract shall be governed by all provisions of the California Labor Code relating to prevailing wage rates (Sections 1770 -7981 in- clusive). The Contractor shall be responsible for compliance with Section 1777. of the California Labor Code for all apprenticeable occupations. 379937 - Class A ECNA, INC. Contr's Lic. No. & Classification Bidder _ June 17, 1982 S /Jack M. Mitchell, President Date Authorized Signature /Title 0 Page 3 DESIGNATION OF SUBCONTRACTOR(S) The undersigned certifies that he has used bid(s) of the following listed subcontractor(s) in making up his bid,and that the subcontractor(s) listed will be used for the work for which they bid, subject to the approval of the Engineer and in accordance with the applicable provisions of the Specifications. No change of subcontractor may be made except with the prior approval of the Engineer.and as provided by State law. Item of Work Subcontractor Address 1. Striping Consley - Monigny 4551 N: Baldwin Ave., 2. 3. 4. 5. 6. 7. 8. 9. 10. 11. 12. E1 Monte, CA ECNA, INC. Bidder S /Jack M. Mitchell, President Authorized Signature /Title FOR ORIGINAL SEE CITY CLERKALE COPY Page 4 BIDDER'S BOND KNOW ALL MEN BY THESE PRESENTS, That we, ECNA, INC. , as bidder, and TRANSAMERICA INSURANCE COMPANY , as Surety, are held and firmly bound unto the City of Newport Beach, California, in the sum of an amount equal to ten percent of the accompanying bid Dollars ($ 10% ), lawful money of the United States for the payment of which sum well and truly to be made, we bind ourselves, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH, That if the proposal of the above bounden bidder for the construction of 1981 -82 SLURRY PROGRAM 2307 Title of Project Contract No. in the City of Newport Beach, is accepted by the City Council of said City, and if the above bounden bidder shall duly enter into and execute a contract for such construction and shall execute and deliver the "Payment" and "Faithful Performance" contract bonds described in the Specifications within ten (10) days (not including Saturday, Sunday, and Federal holidays) from the date of the mailing of a notice to the above bounden bidder by and from said City that said contract is ready for execution, then this obligation shall become null and void; otherwise it is and shall remain in full force and effect, and the amount specified herein shall be forfeited to the said City. In the event that any bidder above named executed this bond as an indi- vidual, it is agreed that the death of any such bidder shall not exonerate the Surety from its obligations under this bond. IN WITNESS WHEREOF, we hereunto set our hands and seals this 17th day of June , 1982. (Attach acknowledgement of Attorney -in -Fact) Maurine Woods Notary Public Commission expires 8- 13 -84. ECNA, INC. Bidder S /Jack M. Mitchell. President Authorized Signature /Title TRANSAMERICA INSURANCE COMPANY Surety By S /Charles J. West Title Attorney in Fact • • NON- COLLUSION AFFIDAVIT Page 5 The bidder, by its officers and agents or representatives present at the time of filing this bid, being duly sworn on their oaths, say that neither they nor any of them have, in any way, directly or indirectly, entered into any arrange- ment or agreement with any other bidder, or with any public officer of such CITY OF NEWPORT BEACH whereby such affiant or affiants or either of them, has paid or is to pay to such bidder or public officer any sum of money, or has given or is to give to such other bidder or public officer anything of value whatever; or such affiant or affiants or either of them has not directly or indirectly, entered into any arrangement or agreement with any other bidder or bidders, which tends to or does lessen or destroy free competition in the letting of the contract sought for by the attached bids; that no bid has been accepted from any subcontractor or materialman through any bid depository, the bylaws, rules or regulations of which prohibit or prevent the bidder from con- sidering any bid from any subcontractor or materialman which is not processed through said bid depository, or which prevent any subcontractor or materialman from submitting bids to a bidder who does not use the facilities of or accept bids from or through such bid depository; that no inducement of any form or character other than that which appears upon the face of the bid will be sug- gested, offered, paid or delivered to any person whomsoever to influence the acceptance of the said bid or awarding of the contract; nor has the bidder any agreement or understanding of any kind whatsoever with any person whomso- ever to pay, deliver to, or share with any other person in any way or manner, any of the proceeds of the contracts sought by this bid. ECNA, INC. Bidder S /Jack M. Mitchell, President Authorized Signature /Title Subscribed and sworn to before me this 17th day of June 19 82. My commission expires: _ August 13, 1984 S /Maurine Woods Notary Public Page 6 IN ORIGINAL SEE CITY CLERK'S FILZ COPY STATEMENT OF FINANCIAL RESPONSIBILITY The undersigned submits herewith a statement of his financial responsibility or agrees to submit a statement within 1 work day after the bid opening if the undersigned is the apparent low bidder. On file with City Clerk. ECNA. INC. Bidder fit'"' M_ ll Mitche, Prede sint Authorized Signature /Title • 0 Page 7 TECHNICAL ABILITY AND EXPERIENCE REFERENCES The undersigned submits herewith a statement of the work of similar character to that proposed herein which he has performed and successfully completed. Year Completed For Whom Performed (Detail) Person to Contact Telephone No. ECNA, INC. oiaaer ---- S /Jack M. Mitchell, President Authorized Signature/Title 0 NOTICE • Page 8 The following are samples of contract documents which shall be completed and executed by the successful bidder after he receives letter of award from the City of Newport Beach: PAYMENT BOND (pages 9 & 10) FAITHFUL PERFORMANCE BOND (pages 11 & 12) CERTIFICATE OF INSURANCE & ENDORSEMENTS (pages 13, 14, 15) CONTRACT (pages 16 & 17) Since the City of Newport Beach will not permit a substitute format for these contract documents, bidders are advised to review their content with bonding, insuring and legal agents prior to sub- mission of bid. BONDING COMPANIES shall be acceptable as sureties in accordance with the latest revision of Federal Register Circular 570. INSURANCE COMPANIES shall be assigned Policyholders' Rating B (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Ke Ratin Guide: Property Casualty. Coverages shall be provide for a Y ES OF INSURANCE checked on the CERTIFICATE OF INSURANCE. All costs associated with the specifications of these contract documents shall be absorbed in the bid. Such specifications shall include those contained in (1) each contract document and (2) the Standard Specifications for Public Works Construction.(latest edi- tion adopted for use in the City of Newport Beach , except as supplemented or modified by the Special Provisions for this project. • • Page 9 Bond No. 5750 82 48 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS, That WHEREAS, the City Council of the City..of Newport Beach, State of California, by motion adopted June 28 1982, has awarded to ECNA hereinafter designated as the "Principal ", a contract for. 1981 -82 SLURRY SEAL PROGRAM (C -2307) in the City of Newport Beach, in strict conformity with the Drawings and Specifications and other contract documents on file in the office of the City Clerk of the City of Newport Beach; WHEREAS, said Principal has executed or is about to execute said contract and the terms thereof require the furnishing of a bond with said contract, providing that if said Principal or any of his or its subcontractors, shall fail to pay for any materials, provisions, provender, or other supplies or teams used in, upon, for, or about the per- formance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth: NOW, THEREFORE, We ECNA, INC. as Principal, TRANSAMERICA INSURANCE COMPANY as Surety, are held firmly bound unto the City of Newport Beach, in the sum of One Hundred Sixty One Thousand Ninety -One and o0 /100 - -- -Dollars ($ 161,091.00 - - - - -- ), said sum being one -half of the estimated amount payable by the City of Newport Beach under the terms of the contract, for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if the above bounden Principal or his subcontractors, fail to pay for any materials, provisions, provender, or other supplies or teams, used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind or for amounts due under the Unemployment Insurance Code with respect to such work or labor, that the Surety or Sureties will pay for the same, in an amount not exceeding the sum specified in the bond, and also, in case suit is brought upon the bond, a reasonable attorney's fee, to be fixed by the Court as required by the provisions of Section 3250 of the Civil Code of the State of California. This bond shall inure to the benefit of any and all persons, companies, and corporations entitled to file claims under Section 3181 of the California Civil Code so as to give a right of action to them or their assigns in any suit brought upon 0 6 Page 10 Payment Bond (Continued) this bond, as required by the Provisions of Sections 3247 et. seq. of the Civil Code of the State of California. And said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alterations or additions to the terms of the contract or to the work to be performed thereunder or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alterations or additions to the terms of the contract or to the work or to the specifications. In the event that any principal above named executed this bond as an individual, it is agreed that the death of any such principal shall not exonerate the Surety from its obligations under this bond. IN WITNESS WHEREOF, this /instrument has been-duly executed by the Princi 1 and Surety above named, on the C Qfk day of 19 STATE OF CALIFORNIA OFFICIAL SEAL OF E C N A INCORPORATED OCT. 26, 1976 Approved as to form: City Attorney LCNA, --MCC- (Seal ) Name of Contractor (Principal) e- AutAorized Signature and Titer Authorized Signature and Title TRANSAMERICA INSURANCE COMPANY (Seal) Name of Surety 1150 S. Olive St., Los Angeles, CA ..90054 IArnee of Cura +v e . vaiiarp c>_ nI- uacy— iaa— .ua<_v - N. 16th St., C -152, Phoen!x, AZ 85016.. of Agent (620) 264 5848 Telephone No. of A ent Countersigned by Smith & Elgart 231 Sansome St. San Francisco, CA 94104 T Transarica Insurance Services i Transamerica Insurance Company A STOCK COMPANY HOME OFF4CE: LOS ANGELES, CALIFORNIA POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That TRANSAMERICA INSURANCE COMPANY, a corporation of the State of California, does hereby make, constitute and appoint JOHN J. GALLAGHER OR CHARLES J. WEST OF PHOENIX, ARIZONA --EACH- - its true and lawful Attorneys) -in -Fact, with full power and authority, for and on behalf of the Company as surety, to execute and deliver and affix the seal of the Company thereto, if a seal is required, bonds, undertakings, recognizances or other written obligations in the nature thereof, as follows: AN Y AND ALL BONDS AND UNDERTAKINGS IN AN UNLIMITED AMOUNT, IN ANY SINGLE INSTANCE, FOR OR ON BEHALF OF THIS COMPANY, IN ITS BUSINESS AND IN ACCORDANCE WITH ITS CHARTER, and to bind TRANSAMERICA INSURANCE COMPANY thereby, and all of the acts of said Attorneys) -in -Fact, pursuant to these presents, are hereby ratified and confirmed. This appointment is made under and by authority of the following by -laws of the Company which by -laws are now in full force and effect: ARTICLE VII SECTION 30. All policies, bonds, undertakings, certificates of insurance, cover notes, recognizances, contracts of indemnity, endorsements, stipulations, waivers, consents of sureties, re- insurance acceptances or agreements, surety and co- surety obligations and agreements, underwriting undertakings, and all other instruments pertaining to the insurance business of the Corporation, shall be validly executed when signed on behalf of the Corporation by the President, any Vice President or by any other officer, employee, agent or Attorney -in -Fact authorized to so sign by (i) the Board of Directors, (ii) the President, (iii) any Vice President, or (iv) any other person empowered by the Board of Directors, the President or any Vice President to give such authorization; provided that all policies of insurance shall also bear the signature of a Secretary, which may be a facsimile, and unless manually signed by the President or a Vice President, a facsimile signature of the President. A facsimile signature of a former officer shall be of the same validity as that of an existing officer. The affixing of the corporate seal shall not be necessary to the valid execution of any instrument, but any person authorized to execute or attest such instrument may affix the Corporation's seal thereto. This Power of Attorney is signed and sealed by facsimile under and by the authority of the following resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of October 1963. "Resolved, That the signature of any officer authorized by the By -laws and the Company seat may be affixed by facsimile to any power of attorney or special power of attorney or certification of either given for the execution of any bond undertaking, recognizance or other written obligation in the nature thereof; such signature and seal, when so used being hereby adopted by the Compawl as the original signature of such officer and the original seal of the Company, to be valid and binding upon the Company with the same force and effect as though manually affixed" , IN WITNESS WHEREOF, TRANSAMERICA INSURANCE COMPANY has caused these presents to be signed by its proper officer and its corporate seal to be hereunto affixed this 4T H day of NOVEMBER 198o By 0 • \„ J. W. FLESHMAN, Vice President State of California ) County of Los Angeles ) ss On this )4TH day of NOVEMBER , 1980, before me personally came J.W. Fleshman to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sierra Madre, State of California; that he is a Vice - President of Transamerica Insurance Company, the corporation described in and which executed the above instrument; That he knows the seal of said Corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. Notary Public 17196 (Over) 15501 SEAL ELIZABETH AHERNE NOTARY PUBLIC CALIFORNIA @MyOFFICIAL PRINCIPAI. OFFICE IN LOS ANGCI� colutm Ca Im Ts. n Exp. Mn.3t1.1967 Notary Public 17196 (Over) 15501 6 I . mapisaJd ao'n IUOI$IssV'H3NNVl'H ' f v V ;o Aep oiunajaq aneq I ;oaiat4m Auowiisal ;o pjeog aqi ;o uoilniosaa aql pue Apliao laglin; pue'2ojo; ut 11ps si pu aqi legi A4gjao Agaaaq op 'Auedwo (4) 6t sigi Auedwoo pies aql 10 leas aql paxi; ;e pue aweu Aw paquosgns ul •aoao; ui 11(1s aie Aawo11V ;o Jannod pies ui qlJo; 10s 'sioloan4 Auedwoo aq1 ;o sme-I-Ag aql ;o Ian aIoi1JV ;o p£ uoilaag 1eg1 e Adoo loexa pue @nil e si g1ao; ias ajo;aq uialaq Aawoliy ;o Jannod eouejnsul P3'JawesueJl 10 luapisaJd aoin lueisissV 'Jauuel 'H 'f 'I E STATE OF ARIZONA ) ss.: COUNTY OF MARICOPA 3 0 On this_ 12th _day July--.1982, before me personally came ___,john J. Gal laghQr, to me known to be an Attorney -in -Fact of TRANSAMERICA INSURANCE COMPANY, the corporation described in the within instrument, and he acknowledged that he executed the within instrument as the act of the said TRANSAMERICA INSURANCE COMPANY in accordance with authority duly conferred upon him by said Company. Notary Public My Commission Expires Rev, 14, 1985 0 0 STATE OF ARIZONA COUNTY OF MARICOPA ON July 12th 1982 before me, the undersigned, a Notary Public in and for said State, personally appeared Jack M. Mitchell known Cu me to bu the -- iresident of the the Corporation that executed the within instrument, known to me to be the person who executed the within instrument on bv- half or the Corporation, therein named, and acknowledged to me that such Corporation executed the same. WITNESS my hand and oi-FicLai meat. STATE OF A;?1,7f)NA M.ARICOP;. J)"Ss. jnd n1lifiAl Se3i My Commission Expires Feb, 17, 1986 0 FAITHFUL PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS, That • Page 11 WHEREAS, the City Council of the City of Newport Beach, State of California, by motion adopted June 28, 1982, has awarded to ECNA, INC. hereinafter designated as the "Principal ", a contract for 1.981 -82 SLURRY PROGRAM (C -2307) in the City of Newport Beach, in strict conformity with the Drawings and Specifications and other contract documents on file in the office of the City Clerk of the City of Newport Beach; WHEREAS, said Principal has executed or is about to execute said contract and the terms thereof require the furnishing of a bond for the faithful performance of said contract; NOW, THEREFORE, We, ECNA, INC, as Principal, and TRANSAMERICA INSURANCE COMPANY as Surety, are held and firmly bound unto the City of Newport Beach, in the sum of One Hundred Sixty One Thousand Ninety -One and 00 /100 - - - - -- Dollars ($ 161,091.00- - - - -), said sum being equal to 100% of the estimated amount of the contract, to be paid to the said City or its certain attorney, its successors, and assigns; for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if the above bounden Principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, con- ditions, and agreements in the said contract and any alteration thereof made as therein provided on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of Newport Beach, its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall remain in full force and virtue. And said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alterations or additions to the terms of the contract or to the work to be performed thereunder or to the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice Faithful Performance Bond (Continued) Page 12 of any such change, extension of time, alterations or additions to the terms of the contract or to the work or to the specifications. In the event that any principal above named executed this bond as an individual, it is agreed that the death of any such principal shall not exonerate the Surety from its obligations under this bond. IN WITNESS WHEREOF, this ipq�ent has been dulyed by the Principal end Surety above named, on the (�(� day of 19 y_ STATE OF CALIFORNIA OFFICIAL SEAL OF ECNA INCORPORATED OCT. 26, 1976 Approved as to form: City Attorney WW1I 9A.10, (Seal) Name of Contractor (Principal) Authorized Signature and Title Authorized Signature and Title TRANSAMERICA INSURANCE COMPANY (Seal) Name of Surety 1150 S. Olive St., Los Angeles, CA.:,90054 Address of Surety S' n ure Title of thorized ent oh J, Gallagher Attorney -in- #t 5150 N. 16th St., C -152 Phoenix, AZ 85016 ddress of Agent (602) 264 5848 Telephone No. of Agent Countersigned by Smith & Elgart / 231 Sansome St. San Francisco, CA 94104 0 CERTIFICATE OF INSURANCE • City of Newport Beach 3300 Newport Boulevard Newport Beach, CA 92663 NAME AND ADDRESS OF INSURED ECNA, Inc., a Corporation 642 N. 17th Ave., Phoenix, Arizona 85007 Page 13 NG A Transamerica Insurance Company "' B r_ ny C r_ ny D r_ ny E r This is to certify that policies of insurance listed below have been issued to the insured named above and are in force at this time, including attached endorsement(s). NOTE: The Comprehensive General Liability and Automotive Liability policies are endorsed with the attached City of Newport Beach Endorsements. CANCELLATION: Should any of the above described policies be cancelled or coverage reduced before the expiration date thereof,;tha•Insurance Company affording coverage shall provide 30 days' advance notice to the City of Newport Beach by registered il,.atten ion: Public Works Department. By: Agency: Gallagher & West Insurance Counsellors u o d RepresentAtive 7�/_3— D ee Issued Description of operations /locations /vehicles: All operations performed for the City of Newport Beach by or on behalf of the named insured in connection with the following designated contract: 1981 -82 Slurry Program Contract No. 2307 (Project Title and Contract Number) NOTICE: his certificate or verification of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded by the policies listed herein. Notwith- standing any requirement, term, or condition of any contract or other document with respect to which this certificate or verification of insurance may be issued or may pertain, the insurance afforded by the policies described herein is subject to all the terms, exclusions and conditions of such policies, including attached endorsements. FE Policy LIMITS OF LIABILITY IN THOUS NDS 000 g. ro uc s/ COMPANY TYPES OF INSURANCE Policy Exp. LETTER COVERAGE REQUIRED No. Date Each Completed Occurrence Operations GENERAL LIABILITY Bodily Injury $ $ A Comprehensive Form 188 79 6 -14$3 Property Damage $ $ Premises - Operations Explosion & Collapse Hazard Ix 777 Underground Hazard Products /Completed Operations Bodily Injury Hazard and Property x Contractual Insurance Damage Combined $ 1,000 $ 1,000 x Broad Form Property Damage x Independent Contractors x Personal Injury Marine Personal Injury $ 11000 Aviation .AUTOMOTIVE LIABILITY x[ ]' Comprehensive Form Bodily Injury $ A Same Same (Each Person �J Owned $ Bodily injury Each Occurrence ❑x Hired ro ert Damage Bodily njury and [� Non -owned Property Damage Combined $ 1,000 EXCESS LIABILITY ❑ Umbrella Form Bodily Injury ❑ Other than Umbrella Form and Property Damage Combined $ $ WORKERS' COMPENSATION CA Statutor 100 000 Accident) Accident) , A and EMPLOYER'S LIABILITY WC1098 098 6 -14 -89 NOTE: The Comprehensive General Liability and Automotive Liability policies are endorsed with the attached City of Newport Beach Endorsements. CANCELLATION: Should any of the above described policies be cancelled or coverage reduced before the expiration date thereof,;tha•Insurance Company affording coverage shall provide 30 days' advance notice to the City of Newport Beach by registered il,.atten ion: Public Works Department. By: Agency: Gallagher & West Insurance Counsellors u o d RepresentAtive 7�/_3— D ee Issued Description of operations /locations /vehicles: All operations performed for the City of Newport Beach by or on behalf of the named insured in connection with the following designated contract: 1981 -82 Slurry Program Contract No. 2307 (Project Title and Contract Number) NOTICE: his certificate or verification of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded by the policies listed herein. Notwith- standing any requirement, term, or condition of any contract or other document with respect to which this certificate or verification of insurance may be issued or may pertain, the insurance afforded by the policies described herein is subject to all the terms, exclusions and conditions of such policies, including attached endorsements. FE 0 0 Page 14 CITY OF NEWPORT BEACH AUTOMOTIVE LIABILITY INSURANCE ENDORSEMENT It is agreed that: 1. With respect to such insurance as is afforded by the policy for Bodily Injury and Property Damage Liability, the City of Newport Beach, its officers and employees are additional insureds but only with respect to liability for damages arising out of the ownership, maintenance or use of automobiles (or autos) used by or on behalf of the named insured in connection with the contract designated below. The insurance extended by this endorsement to said additional insured does not apply to bodily injury or property damage arising out of automobiles (1) owned by or registered in the name of an additional insured, or (2) .leased or rented by an additional insured, or (3) operated by an additional insured. The insurance afforded the additional named insured(s) shall apply as primary insurance and no other insurance maintained by the City of Newport Beach will be called upon to contribute with insurance provided by this policy. 2. The policy includes the following provision: "The insurance afforded by the policy applies separately to each insured who is seeking coverage or against whom a claim is made or suit is brought, except with respect to the limits of the Insurance Company's liability." 3. The limits of liability under this endorsement for the additional insureds named in paragraph 1 of this endorsement shall be the limits indicated below for either Multi- ple Limits or Single Limit, whichever is indicated by the letter X in the appropriate box. ( ) Multiple Limits Bodily Injury Liability $. Property Damage Liability (->�) Single Limit Bodily Injury Liability and Property Damage Liability Combined each occurrence $ each occurrence $ 1,000,000 each occurrence The limits of liability as stated in paragraph 3 of this endorsement shall not in- crease the total liability of the Insurance Company for all damages as the result of any one accident or occurrence in excess of the limits of Liability stated in the policy as applicable to Automobile Liability Insurance. 4. Should the policy be cancelled or coverage reduced before the expiration date thereof, the Insurance Company shall provide 30 days' advance notice to the City of Newport Beach by registered mail, Attention: Public Works Department. 5. Designated Contract: 1981 -82 Slurr Pro ram a Contract No. 2307 ro�ect it an Contract No.). This endorsement is effective ,lulu 13. 1982, at 12:01 A.M. and forms a part of Policy No. 18879777 Named Insured ECNA, Inc., a Corporation Endorsement No. 2 Name of Insurance Company Transamerica gy -(J u or a <ep n a v CITY OF NEWPORT BEACH COMPREHENSIVE GENERAL LIABILITY INSURANCE ENDORSEMENT It is agreed that: Page 15 1. With respect to such insurance as is afforded by the policy for Comprehensive General Liability, the City of Newport Beach, its officers and employees are additional in- sureds but only with respect to liability arising out of operations performed by or on behalf the named insured in connection with the contract designated below or acts and omissions of the City of Newport Beach in connection with its general supervision of such operations. The insurance afforded said additional insured shall apply as primary insurance and no other insurance maintained by the City of Newport Beach will be called upon to contribute with insurance provided by this policy. 2. The policy includes the following provision: "The insurance afforded by the policy applies separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the Insurance Company's liability." 3. The insurance afforded by the policy for Contractual Liability Insurance (subject to the terms, conditions and exclusions applicable to such insurance) includes liability assumed by the named insured under the indemnification or hold harmless provision con- tained in the written contract, designated below, between the named insured and the City of Newport Beach. 4. With respect to such insurance as is afforded by this policy, the exclusions, if any, pertaining to the explosion hazard, collapse hazard and underground property hazard (commonly referred to as "XCU "hazards) are deleted. 5. The limits of liability under this endorsement for the additional insured named in paragraph I of this endorsement shall be the limits indicated below for either Multiple Limits or Single Limit, whichever is indicated by the letter X in the appropriate box. ( ) Multiple Limits Bodily Injury Liability Property Damage Liability $ (>�) Single Limit each occurrence each occurrence Bodily Injury Liability $ 1,000,000 each occurrence and Property Damage Liability Combined The applicable limit of the Insurance Company's liability for the insurance afforded for contractual liability shall be reduced by any amount paid as damages under this endorsement in behalf of the additional insureds. The limits of liability as stated in this endorsement shall not increase the total liability of the Insurance Company for all damages as the result of any one occurrence in excess of the limits of liability stated in the policy as applicable to Comprehen- sive General Liability Insurance. 6. Should the policy be cancelled or coverage reduced before the expiration date thereof, the Insurance Company shall provide 30 days' advance notice to the City of Newport Beach by registered mail, Attention: Public Works Department 7. Designated Contract: 1981 -82 Slurry Program Contract No. 2307 Project Title and Contract No. This endorsement is effective July 13, 1982,at 12:01 A.M. and forms a part of Policy No. 18879777 Named Insured ECNA, Inc., a Corporation Endorsement No. I Name of Insurance Company Transamerica By �^✓ u on a Represent ve Page 16 CONTRACT THIS AGREEMENT, entered into ay of 19 by and between the CITY OF NEWPORT B fiereinafter "Cit and hereinafter "Contractor,' is made with reference to the following facts: (a) City has heretofore advertised for bids for the following described public work: 1981 -82 SLURRY PROGRAM 2307 Title of Project Contract No. (b) Contractor has been determined by City to be the lowest responsi- ble bidder on said public work, and Contractor's bid, and the compensation set forth in this contract, is based upon a careful examination of all plans and specifications by Contractor, NOW, THEREFORE, the parties hereto agree as follows: 1. Contractor shall furnish all materials and perform all of the work for the construction of the following described public work: N 2307 ontract No. which project is more fully described in the contract documents. Contractor shall perform and complete this work in a good and workmanlike manner, and in accordance with all of the contract documents. 2. As full compensation for the performance and completion of this work as prescribed above, City shall pay to Contractor the sum of One Hundred Sixty -one Thousand Ninety -one and No /100 Dollars ($7UT_.U9T 00_). This compensation includes (1) any loss or damage arising from the nature of the work; (2) any loss or damage arising from any unforeseen difficulties or obstruc- tions in the performance of the work; (3) any expense incurred as a result of any suspension or discontinuance of the work; but excludes any loss resulting from earthquakes of a magnitude in excess of 3.5 on the Richter Scale and tidal waves, and which loss or expense occurs prior to acceptance of the work by City. 3. All of the respective rights and obligations of City and Contractor are set forth in the contract documents. The contract documents are incorporated herein by reference as though set out in full and include the following: (a) Notice Inviting Bids (b) Instruction to Bidders and documents referenced therein (c) Payment Bond (d) Faithful Performance Bond (e) Certificate of Insurance and endorsement(s) Page 17 (f) Plans and Special Provisions for 1981 -82 SLURRY PROGRAM e OT Nroject Contract No. (g) This Contract. 4. Contractor shall assume the defense of, and indemnify and hold harmless, City and its officers, employees and representatives from all claims, loss or damage, except such loss or damage proximiately caused by the sole negligence of City or its officers, employees and representatives. IN WITNESS WHEREOF, the parties hereto have caused this contract to be executed the day and year first above written. CITY OF NEWPORT BEACH A I 1 1. - M"'WoMAI a M CITY APPROVED AS TO FORM: City Attorney Contractor By Its CONTRACTOR CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT 1981 -82 SLURRY PROGRAM CONTRACT NO. 2307 INDEX TO SPECIAL PROVISIONS SECTION PAGE I. SCOPE OF WORK . . . . . . . . . . . . . . . . . . . . 1 II. QUALIFICATIONS OF BIDDERS AND BUSINESS LICENSE . . . 1 III. SCHEDULING AND COMPLETION OF WORK. . . . . . . . . . 1 IV. VEHICULAR AND PEDESTRIAN TRAFFIC CONTROL . . . . . . 2 V. NOTIFICATION TO RESIDENTS AND BUSINESSES . . . . . . 2 VI. WATER . . . . . . . . . . . . . . . . . . . . . . . . 3 VII. APPLICATION . . . . . . . . . . . . . . . . . . . . . 3 VIII. SLURRY . . . . . . . . . . . . . . . . . . . . . . . 3 A. Mix Design . . . . . . . . . . . . . . . . . . . 3 B. Materials . . . . . . . . . . . . . . . . . . . . 4 IX. TRAFFIC STRIPING AND PAVEMENT MARKINGS . . . . . . . 4 I. II. CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT SPECIAL PROVISIONS FOR 1981 -82 SLURRY SEAL PROGRAM CONTRACT NO. 2307 SCOPE OF WORK SP of The work to be done under this contract includes constructing an emulsion - aggregate slurry, hereinafter referred to as "slurry ", of various streets in the City of Newport Beach as shown on the Plan (Drawing Nos. R- 5449 -L, T- 5258 -S, 5259 -S, T- 5264 -S, T- 5265 -S, T- 5266 -S, T- 5272 -S, T- 5273 -S, T- 5275 -S, T- 5276 -S, T- 5277 -S, T- 5278 -S, T- 5279 -S, T- 5280 -S, T- 5281 -S, T- 5282 -S.) The contract requires completion of all the work in accordance with these Special Provisions; the Plan; the City's Standard Special Provisions; the Standard S t5 ci f tions for Public Works Construction, 1979 Edition and supplements to mate; Internationa slurry ea Association Test Method No. T -100; and applicable por- tions of the American Society for Testing and Materials Specifications. QUALIFICATIONS OF BIDDERS AND BUSINESS LICENSE Only bids from responsible bidders will be considered. To qualify as a responsible bidder, the Contractor shall have a successful performance record in the applica- tion of Cationic or Anionic quick -set slurry and shall have actually placed at least 5,000 extra long tons. Bidders shall submit, with their bids, the name of the proposed foreman who must have a minimum of two years' experience in this type of work. This foreman shall be present whenever slurry is being applied. III. SCHEDULING AND COMPLETION OF WORK The Contractor shall submit to the Engineer within 10 days after notification of award (1) a complete schedule of work showing the geographical areas and the approximate periods of time planned for work in each area, and (2) a proposed slurry design mix, See Section VIII -A. No work shall begin until the schedule of work and slurry design has been approved by the Engineer. Requests for changes in the schedule may be submitted to the Engineer for approval at least 72 hours prior to the scheduled slurry of streets. All work under this contract shall be completed by August 31, 1982, (or within forty -five (45) consecutive calendar days after the start of obstruction to traffic, whichever comes first). It will be the Contractor's responsibility to ensure the availability of all materials prior to the start of work. Unavailability of materials will not be sufficient reason to grant the Contractor an extension of time. IV. • • SP2of 5 VEHICULAR AND PEDESTRIAN TRAFFIC CONTROL The Contractor shall schedule his operations so that all streets can be opened to traffic by 4:00 P.M., except when unexpected weather conditions require a longer curing period. In this event, the Contractor shall install sufficient lighted barricades, interspersed within the treated lane to prevent use until curing is completed. On streets with raised median, the Contractor shall work on only one roadway at a time. A minimum of one open traffic lane shall be maintained at all times on the roadway being slurried. On undivided streets, a minimum of one open traffic land in each direction shall be maintained at all times unless otherwise per- mitted by the Engineer. Street closures must be approved by the Engineer. The Contractor shall submit to the Engineer a Traffic Control Plan showing the signing and traffic flow for a typical street three (3) working days prior to the start of work in each area. Work shall not begin in that area until the Traffic Control Plan has been approved by the Engineer. Where any restrictions herein mentioned necessitate temporary prohibition of parking during construction, the Contractor shall furnish, install, and maintain in place "NO PARKING" signs (even if streets have posted "NO PARKING" signs) which he shall post at least 40 hours in advance of the need for enforcement. In addition, it shall be the Contractor's responsibility to notify the City's Police Department, Traffic Division, at (714) 644 -3742, for verification of post- ing at least 40 hours in advance of the need for enforcement. The signs shall (1) be made of white card stock; (2) have minimum dimensions of 12 inches wide and 18 inches high; and (3) be similar in design and color to sign number R -38 on the Caltrans' Uniform Sign Chart. The Contractor shall print the hours, day and date of closure in 2- inch -high letters and numbers. A sample of the completed sign shall be approved by the Engineer prior to posting. Vehicular and pedestrian access shall be maintained at all times to businesses and residences adjacent to the project area; however, where conditions preclude such access for reasonable periods of time (as determined by the Engineer), access shall be restored at the end of each work day. When necessary to provide vehicular or pedestrian crossing over fresh slurry, the Engineer shall direct the Contractor to spread sufficient sand on the affected area to eliminate tracking or damage to the slurry. V. NOTIFICATION TO RESIDENTS AND BUSINESSES Between 48 and 55 hours before closing a section of street or alley or restrict- ing vehicular access to garages or parking spaces, the Contractor shall distri- bute to each affected address a written notice stating when construction opera- tions will start and approximately when vehicular accessibility will be restored. The written notices will be prepared by the Engineer. The Contractor shall insert the applicable dates at the time he distributes the notice. Errors in E • SP3of 5 distribution, false starts, acts of God, stricken or other alterations of the schedule will require Contractor renotification using an explanatory letter furnished by the Engineer. VI. WATER The Contractor shall make provisions for obtaining and applying water necessary to perform his work. If the Contractor elects to use City water free of charge, it shall be his responsibility to make arrangements by contacting the City's Utilities Superintendent, Mr. Gil Gomez, at (714) 640 -2221. VII. APPLICATION Insofar as is possible, slurry shall be applied to cul -de -sac areas in the early morning. Add the following in lieu of the first sentence of subsection 302 - 4.32 "Spreading ": Prior to applying the slurry, the surface to be slurried shall be cleared and cleaned by the Contractor of all loose material, vegetation, oil, and other objectionable material. In addition to subsection 302 -4.32 "Spreading ", it shall be the Contractor's responsibility to protect and clean slurry from existing street markers, reflectors, and valve, monument, and manhole covers. VIII. SLURRY A. Mix Design The Contractor shall submit a slurry mix design and the results of the International Slurry Seal Association Test Method No. T -100 wet track abrasion test, performed on the design mix, to the City for approval within ten (10) calendar days after notification of award of the contract by the City. The design mix shall be such that the maximum allowable wear value is 75 grams per square foot of emulsified asphalt when subject to the wet tract abrasion test. The Contractor will be responsible for tests needed for verification of the mix design and materials. (This does not include field tests needed for control of construction, except as otherwise noted herein.) The results of the test shall be reported as follows: 1. The average wear value (WTAT loss) in grams per square foot for each quantity of emulsified asphalt. 2. Total water added (percent based on aggregate weight) to arrive at pouring consistency. Mixing water shall be held to a minimum. 3. Any tendencies observed towards mix segregation during preparation. 4. Observations as to texture, signs of surface skinning, or tackiness in the specimen during test. 0 • SP4of5 5. The type and percentage of admixtures added. . . .if required to overcome mix segregation at free - flowing consistency and to adjust the curing time. Materials 1. Emulsified Asphalt Emulsified asphalt shall be of the Cationic quick -set Type QSK -h, Type I, using penetration grade 60 -70 paving asphalt as a base. If Cationic QSK -h is not available Anionic QS -1H emulsion may be used as an alternate. Emulsified asphalt shall meet the following speci- fication when tested according to appropriate ASTM methods: Emulsion Furol Viscosity at 770 F. Sec. Residue from distillation; % by weight Sieve Test (% retained on No. 20) Storage stability; one -day settlement Residue Penetration @ 770 F Solubility in Trichlorethylene, % Ductility at 770 F, cm. ASTM Test No. 20 -100 D244 57 min. D244 10 max. D244 1% max. D244 40 -110 sec. D5 97.5 min. D2042 40. min. D113 The Contractor shall submit to the Engineer certified copies of test reports in accordance with Std. Spec. of 203 -1.3. 2. Aggregate Aggregate shall be per Std. Spec. of 203 =5.2. 3. Admixtures Portland cement shall be used as the accelerator for Anionic Emulsion - Aggregate Slurry and Ammonium Sulfate in liquid form shall be used as a retardant for Cationic Emulsion- Aggregate Slurry. The amount of admixture shall be that amount necessary to adjust the curing time to conform with the provisions of Section VIII of these Special Provisions and to prevent the slurry from setting up prematurely in the spreader box. Any other admixtures and proportioning system shall be subject to evaluation and approval by the Engineer. IX. TRAFFIC STRIPING AND PAVEMENT MARKINGS This item of work shall be done in accordance with section 210 -1.6 "Paint for Traffic Striping, Pavement Marking and Curb Marking" and Section 310 -5.6 "Painting Traffic Striping, Pavement Markings, and Curb Markings" of the Standard Specifications, except as supplemented or modified below: I1 �J • SP5of 5 Paint for traffic striping and pavement markings shall be white Formula Number 42A9 and yellow Formula Number 480A9 as manufactured by J. E. Bauer Company or approved equal. Delete paragraph 1 of Subsection 310 - 5.6.7, "Layout, Alignment, and Spotting," of the Standard Specifications for Public Works Construction and add the following: The Contractor shall perform all layout, alignment and spotting. The Contractor shall be responsible for the completeness and accuracy of all layout alignment and spotting. Traffic striping shall not vary more than 1/2 inch in 50 feet from the alignment shown in the plans. The Contractor shall mark or otherwise delineate the new traffic lanes and pavement markings within 24 hours after the removal of the existing striping and markings. No street shall be without the proper striping over a weekend. Payment All work, materials, labor, etc. relating to traffic stripes, pavement markings, and pavement markers for removal, painting, and repainting as shown on the plans, shall be included in the "Lump Sum" bid. (o . \\ /�� ••�. SAN rAt1mo I I Vt R (60A RAT P`_� c 004 F VC... lie PROJECT LOCATIONS F � ti VICI N 1TY MAP 1/4 0 14 1/2 3i4 1 CITY OF NEWPORT BE PUBLIC WORKS DEPARTMEI 1981-82 SLURRY SEAL PROGRAM C - 2307 DRAWN R.G. DATE 31111 APPROVED PUBLIC WORKS DIRE R.E. NO. DRAWING NO. R- 5449 -1 B RAKER sr. c a a J ORANGE cJAi1 O ! P A t. °. ` c0 /116! ORANGE CO* CO1� FAIR G ROUND 4� •r & Gj P 0 40 SHEET N 5 oa --- cl ET NO. 6 A. ?� yo U p ER uNivEAS �r :� f NEWPORT RAT ! u c 1 s1 ♦ t dry / CIT OF °C = o °SHEET N0.3 w c t NEWPORT a j��yEy4�.% +r BEACH ; Ch I o At �t ��.. RD. b ■. �•�• �.1 \\ /�� ••�. SAN rAt1mo I I Vt R (60A RAT P`_� c 004 F VC... lie PROJECT LOCATIONS F � ti VICI N 1TY MAP 1/4 0 14 1/2 3i4 1 CITY OF NEWPORT BE PUBLIC WORKS DEPARTMEI 1981-82 SLURRY SEAL PROGRAM C - 2307 DRAWN R.G. DATE 31111 APPROVED PUBLIC WORKS DIRE R.E. NO. DRAWING NO. R- 5449 -1 B ..,7 . 20 T� srI i PAVEMENT AREA E SLURRY SEALED E PAVEMENT 5;'W1P1Na gA10 M4,(-W1N6 TO BE GONE BY 0711,FRS. :('EEP CLEAR" 'E1WER6ENCY ACCESS ROAD" �G NEWPORT PJER�\ CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT 1981-82 SLURRY SEAL PROGRAM C- 2307 HEET 2 OF DATE I APPROVED PUBLIC WORKS DIRE( R.E. NO.. DRAWING No. R- 5449 —L f 71 ! �l I ENT AREA TO BE S ^ NY I / r 1 �p1 Ld �5 J i_el c'.. 7 .4ri Y 3 C `Q n � \ c TTN- `� 11��1 t SCALE I"=800' CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT 1981-82 SLURRY SEAL PROGRAM C-2307 -11 SEALED .20. APPROVED DATE • i PUBLIC WORKS DIRECTOR R.E. NO. ZA2.6 DRAWING No. R- 5.449- L -,rte ` PAVEMENT AREA TO BE SLURRY SEALED SCALE illl� I 80 PATOL /TA AP SAA/TANA —Tt� K- ryAAtdA A ,, Q �Y.ipE• � � : i CITY OF NEWPORT 13E PUBLIC WORKS DEPARTMEI 1981-82 SLURRY SEAL PROGRAM C -2307 �® H n � � �--- SH Er 4 OF i j�RA� i.Cnt.Cr� .GAi,! 8J41187= kPF�RbY�:D ' rUyLiC Yibox ZAREC 06 RU. NG. DRAWING NO. R- 54149 -1- i to f PAVEMENTIOEA TO BE SLURRY S LED 7 �i � .F g/X!A 6r o ep 0 1 opo 5f �I E: I"=800' CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT 1981-82 SLURRY SEAL PROGRAM C -2307 DRAWN R.G. DATE APPROVE PUBLIC WORKS DIRE R.E. NO. O6 DRAWING NO. R- 5449 -L IF MEanoh -14f C-11 2 SCALE: I "= 800' ENT AREA TO BE SLUJOY SEALED 5' -4Mr4 13.4BEL 4146. ,II ��� sT a V CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT 1981-82 SLURRY SEAL PROGRAM C -2307 I i 1 1 I 1 l� v SHEET 6 OF 6 DRAWN RR. DATE 5/11/82 APPROVED PUBLIC WORKS DIRE X06 R.E. NO. DRAWING NO. R- 5449 —L a Pow 00 OA TO 0A comic . .... ». ..F - 741041 Page 1 . CITY OF NEWPORT BEACH Proposal PUBLIC WORKS DEPARTMENT PROPOSAL 1981 -82 SLURRY SEAL PROGRAM CONTRACT NO. 2307 To the Honorable City Council City of Newport Beach 3300 Newport Boulevard P.O. Box 1768 Newport Beach, CA 92663 -3884 Gentlemen: The undersigned declares that he has carefully examined the location of the work, has read the Instructions to Bidders, has examined the Plans and Special Provisions, and hereby pro- poses to furnish all materials and do all the work required to complete this Contract in accordance with the Plans and Special Provisions, and will take in full payment therefor the following unit price for the work, complete in place, to wit: WRITTEN IN WORDS 1. 2,700 Furnish all labor, equipment and material; Extra Long and perform all work necessary to prepare Tons for and apply emulsion- aggregate slurry as shown on the plan CE @ fiFTY TWE15-: Dollars E 1 G ►-11Y _T1 R�>; , Cents $ 23, 83 $ Per Extra Long Ton 2. Lump Sum Traffic striping and pavement markin s ;FiFfr-eN Tl` - i-4�SP SEVIEhJ @ NU ViMp 4--1F'IY Dollars and NliDo Cents Per Lump Sum TOTAL PRICE WRITTEN IN WORDS: OtifE oMiyi t7 SIXTY- -ot4e -rFU n� SJio71( CANE Dollars _ and bSa�tDO Cents z 379937 - Class A ECNA, INC. Contractor's Lic. No. & Classification Bidder 607 -258- 44 idder s e ep h one No. June 17, 1982 Date gnature/ i i t i e $ IS 5O = $ t IDgI.= 642 N. 17th Ave., Phoenix, Az 85007 Bidders Address ORIGINAL ` Page 2 INSTRUCTIONS TO BIDDERS The following contract documents shall be completed, executed and received by the City Clerk in accordance with NOTICE INVITING BIDS: 1. PROPOSAL 2. INSTRUCTIONS TO BIDDERS 3. DESIGNATION OF SUBCONTRACTOR(S) 4. BIDDER'S BOND (sum not less than 10% of total bid price) S. NON - COLLUSION AFFIDAVIT 6. STATEMENT OF FINANCIAL RESPONSIBILITY 7. TECHNICAL ABILITY AND EXPERIENCE REFERENCES except that cash, certified check or cashier's check (sum not less than 10% of the total bid price) may be received in lieu of the Bidder's Bond. The title of the project and the words SEALED BID shall be clearly marked on the outside of the envelope containing the bid. Bids shall not be received from bidders who are not licensed in accordance with the provisions of Chapter 9, Division III of the Business and Professions' Code. The low bidder shall also be required to possess a City of Newport Beach business license prior to execution of contract._ Bids shall be submitted on the attached PROPOSAL form. The additional copy of the PROPOSAL form may be retained by the bidder for his records. The estimated quantities indicated in the PROPOSAL are approximate, and are given solely to allow the comparison of bid totals. Bids are to be computed upon the estimated quantities indicated in the PROPOSAL multiplied by unit price submitted by the bidder. In the event of dis- crepancy between wording and figures, bid wording shall prevail over bid figures. In the event of error in the multiplication of estimated quantity by unit price, the correct multiplication will be computed and the bids will be compared with correctly multiplied totals. The City shall not be held responsible for bidder errors or omissions in the PROPOSAL. Contract documents shall bear signatures and titles of persons authorized to sign on behalf of the bidder. For corporations, the signatures shall be of the President or Vice President. For partnerships, the signatures shall be of a general partner. For sole ownership, the signature shall be of the owner. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the con- tract. A copy of said determination is available in the office of the City Clerk. All parties to the contract shall be governed by all provisions of the California Labor Code relating to prevailing wage rates (Sections 1770 -7981 in- clusive). The Contractor shall be responsible for compliance with Section 1777.5 of the California Labor Code for all apprenticeable occupations. 379937- Class A Contr's Lic. No. & Classification June 17, 1982 ite ECNA, INC. I Pres. uthorizeduthorized Signature /Title . • Page 3 DESIGNATION OF SUBCONTRACTORS) The undersigned certifies that he has used bid(s) of the following listed subcontractor(s) in making up his bid,and that the subcontractor(s) listed will be used for the work for which they bid, subject to the approval of the Engineer and in accordance with the applicable provisions of the Specifications. No change of subcontractor may be made except with the prior approval of the Engineer.and as provided by State law. Item of Work Subcontractor Address l . Syp { PIrSU eonis �Y- N1aJ l G rl Y 45 i 1�1. �,�1 bw� J�. 2. 3. 4. 5. 6. 7. 8. 9. 10. 11. 12. ECNA, INC. r C�l�12�i Pres. Authorized Signatur6/,Title • • Page 4 BIDDER'S BOND KNOW ALL MEN BY THESE PRESENTS, That we, .4CAIr4 37r171r . as bidder, TRA NSAMERICA INSURANCE COMPANY and as Surety, are held and firmly bound unto the City of Newport Beach, California, in the sum of .m &!Aau Apr- f�.rr rArt �-n°,�� '�E *r ��"E.Q'' CjFSJT�`0� %, J, Dollars ($� -... ), lawful money of the United States for the payment of which sum well and truly to be made, we bind ourselves, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH, That if the proposal of the above bounden bidder for the construction of 1981 -82 SLURRY PROGRAM 2307 Title of Project Contract No. in the City of Newport Beach, is accepted by the City Council of said City, and if the above bounden bidder shall duly enter into and execute a contract for such construction and shall execute and deliver the "Payment" and "Faithful Performance" contract bonds described in the Specifications within ten (10) days (not including Saturday, Sunday, and Federal holidays) from the date of the mailing of a notice to the above bounden bidder by and from said City that said contract is ready for execution, then this obligation shall become null and void; otherwise it is and shall remain in full force and effect, and the amount specified herein shall be forfeited to the said City. In the event that any bidder above named executed this bond as an indi- vidual, it is agreed that the death of any such bidder shall not exonerate the Surety from its obligations under this bond. IN WITNESS WHEREOF, we hereunto set our hands and seals this 17th day of June , 19 82 Nt 4�mkc..rr_.v.ir...,ene,..,.rs (Attach acknowledgement of Attorney -in -Fact) Notary Public ECNA, INC STATE Of CALIFORNIA ECNA INCORPORATED OCT. 26, 1976 gnature /litre Pres . TRANSWERICR INSURANCE COMPAW Commission expires 8 -13 -84 Surety By Title CHARLES J.,)NEST o�N1 In _..__ _� Transameica • Insurance Services Transamerica Insurance Company A STOCK COMPANY HOME OFFICE: LOS ANGELES, CALIFORNIA POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That TRANSAMERICA INSURANCE COMPANY, a corporation of the State of California, does hereby make, constitute and appoint JOHN J. GALLAGHER OR CHARLES J. WEST OF PHOENIx, ARfZONA --EACH- - its true and lawful Attorney(s)-in -Fact, with full power and authority, for and on behalf of the Company as surety, to execute and deliver and affix the seal of the Company thereto, if a seal is required, bonds, undertakings, recognizances or other written obligations in the nature thereof, as follows: AN y AND AL L BONDS AND UNDERTAKINGS IN AN UNLIMITED AMOUNT, IN ANY SINGLE INSTANCE, FOR OR ON BEHALF OF THIS COMPANY, IN ITS BUSINESS AND IN ACCORDANCE WITH ITS CHARTER, and to bind TRANSAMERICA INSURANCE COMPANY thereby, and all of the acts of said Attorney(s) -in -Fact, pursuant to these presents, are hereby ratified and confirmed. This appointment is made under and by authority of the following by -laws of the Company which by -laws are now in full force and effect: ARTICLE VII SECTION 30. All policies, bonds, undertakings, certificates of insurance, cover notes, recognizances, contracts of indemnity, endorsements, stipulations, waivers, consents of sureties, re- insurance acceptances or agreements, surety and co- surety obligations and agreements, underwriting undertakings, and all other instruments pertaining to the insurance business of the Corporation, shall be validly executed when signed on behalf of the Corporation by the President, any Vice President or by any other officer, employee, agent or Attorney -in -Fact authorized to so sign by (i) the Board of Directors, (ii) the President, (iii) any Vice President, or (iv) any other person empowered by the Board of Directors, the President or any Vice President to give such authorization; provided that all policies of insurance shall also bear the signature of a Secretary, which may be a facsimile, and unless manually signed by the President or a Vice President, a facsimile signature of the President. A facsimile signature of a former officer shall be of the same validity as that of an existing officer. The affixing of the corporate seal shall not be necessary to the valid execution of any instrument, but any person authorized to execute or attest such instrument may affix the Corporation's seal thereto. This Power of Attorney is signed and sealed by facsimile under and by the authority of the following resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 17th day of October 1963. "Resolved, That the signature of any officer authorized by the By -laws and the Company seal may be affixed by facsimile to any power of attorney or special power of attorney or certification of either given for the execution of any bond undertaking, recognizance or other written obligation in the nature thereof; such signature and seal, when so used being hereby adopted by the Company as the original signature of such officer and the original seal of the Company, to be valid and binding upon the Company with the same force and effect as though manually affixed." IN WITNESS WHEREOF, TRANSAMERICA to be signed by its proper officer and its corporate seal NOVEMBER 11980 State of California county of Los Angeles ) ss INSURANCE COMPANY has caused these presents to be hereunto affixed this 4T H day of By J. W. FLESHMAN, Vice President On this 4TH day of NOVEMBER , 196Q before me personally came J.W. Fleshman to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sierra Madre, State of California; that he is a Vice - President of Transamerica Insurance Company, the corporation described in and which executed the above instrument; that he knows the seal of said Corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. OFFICIAL SEAL ELIZABETH AHERNE l NOTARY PUBLIC L NIA J MtmCIPAI OFFICE t LOS ANGELf8 My Comm sson Exp. .1980 Notary Public 17198 (Over) (5-80) 0 ivapiswda fA iueIS!UV'H3NNV /lH'f vV E \�oa v +� J Nei q!jo n 1 ;o Aep G/ slyi Auedwoo pies ayx }o leas aye paxl ; ;e pue aweu Aw paquosgns o;unaJay aney I ;oajo4m Auow!lsal ul •a3io; w lllis aie Aauao44y ;o Jannod pies w y1Jo; )as 'sJohaJlp ;o pjeog ay; ;o uollnjosaa ay1 pue Auedwoo ayl ;o sme-1 -AB ayl ;o HA alal}JV ;o pC uoi1oaS leyi A pjoo jaypin; pue'aojo; ul Ilns sl pue Adoo loexe pue ania a sl gjjo; las ajo;aq ulajay Aauaoj3V ;o jamod ayl leyl A;Iljao Agajay op'Auedwoo aouejnsul eouawesuejl ;o zuapisaad aoln IuelslssV 'Aauuel'H 'f 11 State of Arizona County of Maricopa On this o ° day of June,19K before me personally came CHARLES J. WEST to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Phoenix, State of Arizona; that he is ATTORNEY -IN FACT of Transamerica Insurance Company, the corporation described in and which ex- ecuted the above instrument; that he knows the seal of said Corporation; that the seal affixed to the said instrumeit.is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said cor- poration and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. — My commission expires: a_t -y a- ..f,/ai °.✓ Aug. 13, 1984 Notary Public NON- COLLUSION AFFIDAVIT Page 5 The bidder, by its officers and agents or representatives present at the time of filing this bid, being duly sworn on their oaths, say that neither they nor any of them have, in any way, directly or indirectly, entered into any arrange- ment or agreement with any other bidder, or with any public officer of such CITY OF NEWPORT BEACH whereby such affiant or affiants or either of them, has paid or is to pay to such bidder or public officer any sum of money, or has given or is to give to such other bidder or public officer anything of value whatever; or such affiant or affiants or either of them has not directly or indirectly, entered into any arrangement or agreement with any other bidder or bidders, which tends to or does lessen or destroy free competition in the letting of the contract sought for by the attached bids; that no bid has been accepted from any subcontractor or materialman through any bid depository, the bylaws, rules or regulations of which prohibit or prevent the bidder from con- sidering any bid from any subcontractor or materialman which is not processed through said bid depository, or which prevent any subcontractor or materialman from submitting bids to a bidder who does not use the facilities of or accept bids from or through such bid depository; that no inducement of any form or character other than that which appears upon the face of the bid will be sug- gested, offered, paid or delivered to any person whomsoever to influence the acceptance of the said bid or awarding of the contract; nor has the bidder any agreement or understanding of any kind whatsoever with any person whomso- ever to pay, deliver to, or share with any other person in any way or manner, any of the proceeds of the contracts sought by this bid. Subscribed and sworn to before me this 17th day of June 19B2—. My commission expires: ECNA, INC, Pres. % Authorized Signatul-e /Title Notary Public • Page 6 STATEMENT OF FINANCIAL RESPONSIBILITY The undersigned submits herewith a statement of his financial responsibility or agrees to submit a statement within 1 work day after the bid opening if the undersigned is the apparent low bidder. ECNA, INC. Bidder CynG,y✓{l, Pres. Authorized Signature /Title Page 7 TECHNICAL ABILITY AND EXPERIENCE REFERENCES The undersigned submits herewith a statement of the work of similar character to that proposed herein which he has performed and successfully completed. Year Completed For Whom Performed (Detail) Person to Contact Telephone No We recently purchased this Corporation and the past records have not been examined. Our proposed foreman on this job will be Mr. Jerry Phipps who has been associated with slurry seal work for approximately 15 years. I i , ECNA, INC. Bidder Pres. sized Signature /Title n n 11 MC') --I Z O — 0 Z -i Z T F, mn z N O -Ni I t g Y rX O I r ��t i CD cn , z monsoon MC') --I Z O — 0 Z -i Z T F, mn z N O -Ni I t g Y rX O I r ��t i CD cn , z TO: CITY COUNCIL FROM: Public Works Department SUBJECT: 1981 -82 SLURRY PROGRAM, C -2307 RECOMMENDATION: June 28, 1982 CITY COUNCIL AGENnA ITEM N0. — JUN 2 8 1982 By the CITY COUNCIL CITY OF 0*71 T RUCH Award Contract No. 2307 to ECNA, Inc., for $161,091, and authorize the Mayor and the City Clerk to execute the contract. DISCUSSION: At 11:00 A.M. on June 17, 1982, the City Clerk opened and read the following bids for this project: Bidder Amount Rid Low ECNA, Inc. $161,091 2 Ted R. Jenkins 161,550 3 Roy Alley Slurry Seal, Inc. 189,860 4 Pavement Coating Co. 195,375 The low bid is 8% below the Engineer's estimate of $175,000. This project provides for slurry sealing approximately 5,000,000 square feet of asphalt streets in the West Newport, Eastbluff, Spy Glass Hill, Irvine Terrace, Newport Center, and Harbor Highlands areas of the City, as shown on the attached exhibit. The slurry treatment will extend pavement life and delay the need for costly resurfacing. The low bidder, ECNA, Inc., has recently been purchased by Slurry Seal of Arizona. Although ECNA has not previously performed contract work for the City, a reference check reveals that the parent corporation has satisfactorily completed many similar projects at defense installations in southern California and in other cities in the southwest. Sufficient funds are available in the Street and Alley Seal Coat- ing Program, Account No. 02- 3381 -014. The plans and specifications were prepared by the Public Works Department. The contract requires completion of all work by August 31, 1982. v 4�) X4 Benjamin B. Nolan Public Works Director GW:jd Att. vy dr DIRECTOR DRAWING N0. R.E. N0. pw TO BE SLURRY 54,9Ze0 �em �o� Qom.. �� , �. N, A� . . . . . . . . . . . . m Y A, CITY OF NEWPORT BEACH DRAWN --ejg-�— DATE -41�92 PUBLIC WORKS DEPARTMENT APPROVED 82 PUBLIC WORKS DIRECTOR 54egloq4ey p#vo4f#fA*w R.E. C- 2307 DRAWING NO. exA1149NO. 1 THE NEWPORT ENSIGN n PROOF OF PUBLICATION (2015.5 C.C.P.) STATE OF CALIFORNIA, ss County of Orange, I am a citizen of the United States and a resident of the County aforesaid; I am over the age of eighteen years, and not a party to or interested in the above - entitled matter. I am the principal clerk of the printer of the Newport Harbor Ensign newspaper of general circula- tion, printed and published weekly in the city of Newport Beach, County of Orange, and which news- paper has been adjudged a newspaper of general circulation by the Superior Court of the County of Or- ange, State of California, under the date of May 14, 1951, CASE NUMBER A -20178 that the notice, of which the annexed is a printed copy (set in type not smaller than nonpareil) has been published in each regular and entire issue of said newspaper and not in any supplement thereof on the following dates to -brit. May 26, 1982 certify (or declare) under penalty of perjury that the foregoing is true and correct. Dated al Newport Beach, California, this 26 dayofMay ,199622 Signature THE NEWPORT ENSIGN 2721 E. Coast Hwy., Corona del Mar, California 92625. G -a3o� space- :a for the County Clerk's Filing Stamp A PUBLIC NOTICE NOTICE INVITING BIDS Proof of Publication of PROOF OF PUBLICATION PUBLIC NOTICE Non" INVInNG BIDS Sealed . ul the BW . wyoM „ bnmety a y C llypm e kCr. eA cn 96 eew al wthd e - I -' C • 0 -Q a &r TO: CITY COUNCIL FROM: Public Works Department SUBJECT #87 BrJ`i U]tfitY PROGRApf; C =2307 May 24, 1982 CITY OC 1 AGENDA N ITEM N0. . —1 RECOMMENDATIONS: r C' t e " 41. 1. Approve the plans and specifications. 2. Authorize the City Clerk to advertise for bids to be opened at 11:00 A.M. on June 17, 1982. DISCUSSION: This project provides for slurry sealing approximately 5,000,000 square feet of asphalt streets in the West Newport, Eastbluff, Spy Glass Hill, Irvine Terrace, Newport Center, and Harbor Highlands areas of the City, as shown on the attached exhibit. The slurry treatment will extend pavement life and delay the need for costly resurfacing. The estimated cost of the work is $175,000. Sufficient funds are available in the current street and alley seal coating program account. The plans and specifications were prepared by the Public Works Department. The contract requires completion of all work by August 31, 1982. 4� - -a. k4 Benjamin B. Nolan Public Works Director GW:jd Att. 11v'01c.4re-s A*4 ra BE 154'ell0ey 56qzh0 v 711�1'7 P WOO \v PIK Q% jog N 4, CITY OF NEWPORT BEACH DRAWN .P.6. DATE s 92 PUBLIC WORKS DEPARTMENT APPROVED PUBLIC WORKS R.E. NO. 54daR#eY KS DIRECTOR DRAWING NO. exhplal r C- Z307