Loading...
HomeMy WebLinkAboutC-2664 - Construct Restroom and Other Improvements in Channel ParkCITY OF NEWPORT BEACH May 4, 1989 OFFICE OF THE CITY CLERK P.O. BOX 1768, NEWPORT BEACH, CA 92658-8915 (714) 644 -3005 Graco Construction Corp. 10535 Foothill Blvd., Suite 230 Rancho Cucamonga, CA 91730 Subject: Surety: Continental Surety Company of California, Inc. Contract No.: C -2664 Project: Construct Restroom and Other Improvements in Channel Park The City Council of Newport Beach on April 10, 1989, accepted the work of subject project and authorized the City Clerk to file a Notice of Completion and to release the bonds 35 days after the Notice has been recorded in accordance with applicable portions of the Civil Code. The Notice was recorded by the Orange County Recorder on April 12, 1989, Reference No. 89- 191281. Sincerely, / /-2 G��l _Zz � J Wanda E. Raggio City Clerk WER:pm cc: Public Works Department 3300 Newport Boulevard, Newport Beach ,ARDING REQUESTED BY AND JEN RECORDED RETURN TO: City Clerk 2& 7"t�`n6l v' City of Ne rt Beath 3300 Newport Boulevard Newport Beach, CA 92663 89!191281: INEMPf ING REQUEST PER �TCODE 6103 EXEMPT C1 NOTICF. OF CO LETION PUBLIC WORKS RECORDED IN OFFICIAL RECORDS OF ORANGE COUNTY, CALIFORNIA -H RA AN APR 12'89 �^ a' � RECORDER I o All Laborers and Material Men and to F.v_ery Other Person Interested: YOU WILL PLEASE TAKE NOTI ,6E that on April 10, 1989 the Public Works project consisting of Construct Restroom and Other Improvements in _ Channel Park (C -2664) on which Graco Construction Co was the contractor, and Conti wary, was completed a RECEIVE Na� undersigned, say: .. 10535 Foothill Blvd.. Suite 230. Rancho 10822 Edison Court, Rancho Cucamonga, CA 91730 VERIFICATION CI Y OF NEWPORT BFACH Pubric Works Director 91730 I am the Public Works Director of the City of Newport Beach; the foregoing Notice of Completion is true of my own knowledge. I declare under penalty of perjury that the foregoing is true and correct. Executed on April 11, 1989 at Newport Beach. California. rliuu Public Works Director VERIFICATION OF CITY CLERK I, the undersigned, say: I am the City Clerk of the City of Newport Beach; the City Council of said City on April 10, 1989 accepted the above described work as completed and ordered that a Notice of Completion be filed. I declare under penalty of perjury that the foregoing is true and correct. Executed on April 11, 1989 at Newport Beach, California. City Clerk I� 83914X3 - RuYi1=3A'Mmf COD M TN3MAA3'OW vi'1 1 ;lV +mm o CITY 'OF NEWPORT BEACH OFFICE OF THE CITY CLERK P.O. BOX 1768, NEWPORT BEACH, CA 92658 -8915 April 12, 1989 County Recorder's Office P.O. Box 238 Santa Ana, California 92702 (714) 644 -3005 Enclosed is the following docment for recordation and return to the above -named office: C -2664 (Construct Restroom and Other Improvements in Channel Park); and C -2468 (Little Balboa Island Seawall Raising and Street Light Conversion) Sincerely, 11 Wo City Clerk 3300 Newport Boulevard, Newport Beach • *April 10, 1989 • TO: CITY COUNCIL FROM: Public Works SUBJECT: ACCEPTANCE 0 CONTRACT NO. RECOMMENDATIONS: CITY COUNCIL AGENDA ITEM NO. F -15 Department OY .k'` ,ITY - 0UNCIL CITY A ;IEWPORT BEACI CHANNEL PLACE PARK IMPROVEMENTS APR 10 1989 2664 _._ APPROVED 1. Accept the work. 2. Authorize the City Clerk to file a Notice of Completion. 3. Authorize the City Clerk to release the bonds 35 days after the Notice of Completion has been recorded in accordance with applicable portions of the Civil Code. DISCUSSION: The contract for the construction of the restroom, shade /picnic structure and hardscape in Channel Place Park has been completed to the • satisfaction of the Public Works Department. During the course of construction a number of Notices to Withhold Funds from subcontractors and material suppliers have been received. These will be handled in the appropriate legal manner. The first step in the process is the filing of the Notice of Completion as recommended above. The bid price was $158,632.00 Amount of unit price items constructed 159,131.00 Amount of change orders 3,969.00 Total contract cost $163,100.00 The increase in the amount of the unit price items constructed was due to the replacement of the sidewalk on Channel Place which had not been included in the original plans. One change order was issued to provide for the replacement of the curb and gutter on Channel Place. Funds for the project were budgeted in the General Fund, Account No. 02- 7797 -331, the Park and Recreation Fund, Account No. 10- 7797 -001 and the Building Excise Tax Fund, Account No. 27- 7697 -322. • The Contractor is Graco Construction Corporation of Rancho Cucamonga. The contract date of completion was January 21, 1989. Completion was delayed due to the lack of availability of the specified flush valves. The work was c leted on Marc 30, 1989. Benjamin B. Nolan Public Works Director PD:so a 0 CITY OF NEWPORT BEACH PUBS WORKS DEPARTMENT ...:., .....: April 4, 1989 TO: City Clerk FROM: Field Engineer SUBJECT: Improvement of Channel Place Park (C -2462) At the meeting of April 10, the Council will be requested to accept the work on the the subject project and authorize the City Clerk to file a Notice of Completion. Due to the large number of 'Stop Notices' which have been received the Notice of Completion should be filed as soon as possible and the recordation inforroation sent to the sub- contractors and suppliers. In order to expidite the process, I will take the Notice to the Recorder's office as soon as the document is prepared and signed. Please call me at 3311 when it is ready. XG.P, Dunigan, Jr, Field Engineer l-1 0 CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT P.O. BOX 1768, NEWPORT BEACH, CA 92658 -8915 (714) 6443311 November 22, 1988 Vallette b Bassin, Lawyers 3500 W. Olive Avenue, Suite 820 Toluca Lake, CA 91505 Attention: Kent Leeds Vallette Subject: Graco Construction Contract Bonds - Contract No. 2664 Gentlemen: The City approved Continental Surety Company of California, Inc. as a corporate surety in the belief that it met the requirements of the bid documents for corporate sureties. Continental Surety Company of California, Inc. has not received a Certificate of Authority from the Insurance Commissioner of the State of California to transact surety insurance in the State of California, and it is not listed in the 1988 Edition of Circular 570 which was published in The Federal Register on July 1, 1988. As soon as it had been determined that the bonds were not acceptable, Graco was requested to substitute acceptable bonds. The specifications provide that the contractor must renew the bonds within 10 days after being notified by the agency. Graco has not been able to do so. The proposal to substitute individual sureties for.corporate sureties is not acceptable to the City. The method of securing releases from all labor and material suppliers and is-uing joint checks outlined in your letter of November 18, 1988, is not acceptable. It might have been acceptable had the City and all other suppliers of labor and materials to Graco been protected by acceptable surety. The City has no way of determining how many persons may have claims against the City until the contract is finished, a Notice of Completion is recorded, and the 30 day notice period has elapsed. If the project should turn out to be underbid, and the first suppliers have been paid off in full, later claimants might not get their fair share of the proceeds. It is therefore requested that acceptable surety be posted so that progress payments may be made. If there are any questions please call me at (714) 644 -3311. Very truly yours, Athrry ,� Office Engineer KLP:so cc: City Attorney City Clerk Graco Constru36UNfoW Boulevard, Newport Beach November 16, 1988 CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT P.O. BOX 1768, NEWPORT BEACH, CA 92658 -8915 (714) 644 -3311 Graco Construction Corporation 10535 Foothill Boulevard, Suite 230 Rancho Cucamonga, CA 91730 Attention: Leonardo Barrios II, President Subject: Contract Bonds Construct Restroom and Other Improvements in Channel Park Contract No. 2664 Gentlemen: The Payment Bond and the Faithful Performance Bond submitted to the City for Contract No. 2664 do not meet the requirements of the Specifications for the project. Section 2.4 of the Standard Specifications for Public Works Construction, 1988 Edition, requires that the contract bonds shall be duly executed by a responsible corporate Surety authorized to issue such bonds in the State of California; and the Notice Inviting Bids requires that the Bonding Company shall be acceptable as Sureties in accordance with the latest revision of Federal Register Circular 570. Continental Surety Company of California, Inc. has not received a Certificate of Authority from the Insurance Commissioner of the State of California to transact surety insurance in the State of California. In addition, Continental Surety Company of California, Inc. is not listed in the 1988 Edition of Circular 570 which was published in The Federal Register on July 1, 1988. The Specifications require that should any bond become insufficient, the Contractor shall renew the bond within 10 days after receiving notice from the agency. On October 20, 1988, the City of Newport Beach notified Graco Construction Corporation that the bonds of Continental Surety Company of California, Inc. were insufficient. To date no new bonds meeting the requirements listed above have been submitted to the City. 3300 Newport Boulevard, Newport Beach 0 To: Graco Construction Corporation Subject: Channel Park Contract Page 2 It is therefore requested that a new Payment Bond and a new Faithful Performance Bond, each issued by a bonding company listed in the 1988 Edition of Circular 570 and holding a current Certificate of Authority from the Insurance Commissioner of the State of California, be substituted for the bonds of Continental Surety Company of California, Inc. If it is impossible to obtain bonds listed on the Treasury List, the City will accept in lieu of the two bonds a Letter of Credit issued by California bank for the full amount of the contract, or a Cash Deposit for the full amount of the contract. Any interest on a cash deposit would be credited to Graco Construction Corporation. No further funds will be disbursed by the City of Newport Beach to Graco Construction Corporation until a new Surety shall qualify and be accepted by the City. If there are any questions please call me at (714) 644 -3311. Very truly yours, Ke neth L. Perry Office Engineer cc: City Attorney City Clerk • 9tober 24, 1988 CITY COUNCIL AGENDA ITEM NO. F -11 BY THe CITY COUNCIL CITY Or NEV:'PO'T BEACE OCT 2 41988 ! TO: CITY COUNCIL APPROVED FROM: Public Works Department SUBJECT: CONSTRUCT RESTROOM AND OTHER IMPROVEMENTS IN CHANNEL PARK CONTRACT NO. 2664 RECOMMENDATION: Affirm the Negative Declaration of Environmental Impact for the restroom and other improvements in Channel Park. DISCUSSION: On July 8, 1988, the City published a notice in the Orange Coast Daily Pilot to the effect that a Negative Declaration had been prepared by the City of Newport Beach in connection with the Park. The notice further stated that it + was the present intention of the City to accept the Negative Declaration and supporting documents. Because the staff did not recommend acceptance of the bids, there was no recommendation that the City Council accept the Negative Declaration; con- sequently, the Negative Declaration has never been accepted by the City Council. A copy of the Negative Declaration is attached to this memo. Benjamin B. Nolan Public Works Director KP:so Attachment ()S) l • • 0 NEGATIVE DECLARATION E CONSTRUCT RESTROOM AND OTHER IMPROVEMENTS IN CHANNEL PARK CONTRACT NO. 2664 NO City of Newport Beach Public Works Department 1. PROJECT LOCATION: This project is located in the northwesterly corner of Channel Park which is located on Balboa Peninsula in a northerly direction from the intersection of 44th Street and Channel Place. 2. PROJECT DESCRIPTION: The project will consist of construction of a new 625 square foot public restroom building and park improvements including picnic shelter, sidewalks and low decorative walls. No additional parking will be provided. 3. PROJECT GOALS: To provide public restroom facilities for users of Channel Park and for beach goers who have walked from the nearby ocean front beaches. 4. EFFECT ON THE ENVIRONMENT: There will be no significant long -term irreversible or irretrievable effects on the environment. There will be minimal, acceptable short -term disturbances caused by construction activity. 5. BASIS FOR NEGATIVE DECLARATION: This project is consistent with the General Plan of the City of Newport Beach and will not have a significant effect on the environment. 6. INITIAL STUDY: The Public Works Department of the City of Newport Beach has prepared the Negative Declaration and its Initial Study in accordance with Article 6, Chapter 3, Guidelines for Implementation of the California Environmental Quality Act. Copies of the Initial Study may be obtained from the Public ors apartment during normal business hours. Benjamin B. Nolan Public Works Director j October 19, 1988 CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT P.O. BOX 1768, NEWPORT BEACH, CA 92658 -8915 (714)644 -3311 Gracc Construction Corporation 10535 Foothill Blvd., Suite 230 Rancho Cucamonga, CA 91730 Attention: Leonardo Barrios II, President Subject: Construct Restroom and Other Improvements in Channel Park (Contract 2664) Gentlemen: The Faithful Performance Bond and the Payment Bond issued by Continental Surety Company of California, Inc. and submitted to the City of Newport Beach for the subject project does not meet the requirements of the City. The NOTICE INVITING BIOS requires that the Bonding Company shall be acceptable as sureties in accordance with the latest revision of Federal Register Circular 570. The name of CONTINENTAL SURETY COMPANY OF CALIFORNIA, INC., 10822 Edison Court, Rancho Cucamonga, California 91730, does not appear in the 1988 edition of Circular 570 which was published in The Federal Register on July 1, 1988. It is therefore requested that a new Faithful Performance Bond and a new Payment Bond issued by a bonding company listed in the 1988 edition of Circular 570 be substituted for the bonds of Continental Surety Company of California, Inc. No further funds will be disbursed by the city until new bonds have been provided. If there are any questions please call me at (714) 644 -3311. Kenneth L. Perry Office Engineer KLP:eu cc: City Attorney City Clerk 3300 Newport Boulevard, Newport Beach I 5 STEEN CONSTRUCTION CO. September 14, 1988 • (OUNCIt A NDA go F -4(b) 1 BOO E. McFADOEN SUITE 101 SANTA ANA. CALIFORNIA 92705 (71 4) 542 -7075 BY THE CITY COUNCIL CITY OF NEWPORT BEACH City of Newport Beach City Council 67 SEP 2 6 19$8 J 3300 Newport Boulevard Newport Beach, CA 92658 -8915 Re: Channel Park improvements - Project #2664 Dear Sirs, ! . RECEIVED SP 14 a I hereby protest the action taken by the city to award a contract on the above project. 1. The contractor awarded the contract did not bid the project properly. 2. It is highly irregular to award a contract when the bid proposal is not followed properly. 3. Addendums #1 and #2 were not submitted or followed in the contractor's bid package. 4. All bidders should be allowed the privilege of bidding a public project without adhereing to the contract documents presented prior to bid time. 5. The city is being unfair to those who bid the project correctly. 6. The bid as submitted was not on the proper bid form. To prevent legal action, please contact me to discuss my protest. Sincerely, �p Orrison L. Steen Owner - Steen Construction Company Date 9 -1� CfiF iES SEMTM 0 Mayur F t=men r y 0 Bldg, Dir. 0 Gen5ery Dir. gPDbRDir. q Piano' Dir. qP a iei .W. Dir m other • 1 CITY OF NEWPORT BEACH Mr. Orson L. Steen Steen Construction 1800 East McFadden Suite 101 OFFICE OF THE CITY ATTORNEY P.O. BOX 1768, NEWPORT BEACH, CA 92658 -8915 (714) 644 -3131 September 19, 1988 Company Santa Ana, CA 92705 Re: Channel Park Improvements - Proiect Number 2664 Dear Mr. Steen: RectIV to PUB11( -WORKS "Pp 1 91989 A NEWp -HCH This letter is written in response to your September 14, 1988 correspondence protesting the award of Contract Number 2664 to Graco Construction. As you know, Contract No. 2664 calls for the construction of restrooms and other improvements at Channel Park. In my opinion, the City Council followed appropriate procedures and its award to Graco is consistent with the purpose and intent of public bidding statutes as well as the Charter of the City of Newport Beach. Prior to the award of the contract the City Council determined that Graco's failure to submit bid documentation in accordance with the revised proposal and addenda was a minor irregularity. The City Council, by appropriate motions, waived the irregularity and awarded the contract to the lowest responsible bidder - Graco Construction. The Council's decision to award to Graco is supported by the facts. The revised proposal and addendum call for a change in the method of payment for the sewer lateral, clarification of several construction items, and increases as well as decreases in the quantity of certain work. Graco confirmed, in writing, their willingness to perform the contract, in accordance with the revisions, for the original bid price. The courts have consistently held that waiver of minor bid irregularities is appropriate. A minor irregularity is one which has not given the low bidder a competitive advantage over other bidders and does not increase the contract price to the public entity. There is no substantial evidence that suggests either factor is present in this case. The revised proposal and addenda called for substantially the same work. A comparison of the quantities and unit prices confirms that Graco's bid would be substantially the same under either proposal. 6 3300 Newport Boulevard, Newport Beach The City had the option to reject all bids. However, rebidding the project would have delayed construction and, in all probability, increased the cost to the City. The City of Newport Beach understands, and shares, your concerns relative to the integrity of the public bidding process. The City does not often waive irregularities and would not consider such action unless it is consistent with a purpose and intent of public bidding statutes. We hope your well qualified company will continue to bid on public works projects in the City of Newport Beach. Very truly yours, —UL I Carol A. Korade Assistant City Attorney CAK /mlh cc: Ben Nolan, Public Works Director 7 CITY OF NEWPORT BEACH OFFICE OF THE CITY CLERK P.O. BOX 1768, NEWPORT BEACH, CA 92658 -8915 TO: FINANCE DIRECTOR FROM: CITY CLERK DATE: September 23, 1988 (714) 644 -3005 SUBJECT: Contract No. C -2664 Description of Contract Construct Restroom and Other Improvements in Channel Park Effective date of Contract September 23, 1988 Authorized by Minute Action, approved on September 12, 1988 Contract with Graco Construction Corporation Address 10535 Foothill Boulevard, Suite 230 Rancho Cucamonga,, CA 91730 Amount of Contract $158,632.00 s 4e Wanda E. Raggio City Clerk WER:pm Attachment 3300 Newport Boulevard, Newport Beach CITY CLERK NOTICE INVITING BIDS Sealed bids may be received at the office of the City Clerk, 3300 Newport Boulevard, P. 0. Box 1768, Newport Beach, CA 92658 -8915 until 11:00 a.m. on the 24th day of AU9USt 1988, at whi tcTi m- at such bids sfia ff be opened —and--Fe-ad for FA U 2664 Contract No. $167,000 Engineer's Estimate �0 \ • %z, Approved by the City Council this 11th day of July , 1988. i.zz' an a E. aggio City Clerk Prospective bidders may obtain one set of bid documents at no cost at the office of the Public Works Department, 3300 Newport Boulevard, P. 0. Box 1768, Newport Beach, CA 92658 -8915. For further information, call Kenneth Perry at 644 -3311. Project Manager .. �A2-A s :r a CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT CONSTRUCT RESTROOM AND OTHER IMPROVEMENTS IN CHANNEL PARK CONTRACT NO. 2664 TABLE OF CONTENTS NOTICE INVITING BIDS TABLE OF CONTENTS BIDDING REQUIREMENTS Proposal Instructions to Bidders Designation of Subcontractors Bidder's Bond Non- Collusion Affadavit Technical Ability and Experience References CONTRACT FORMS Notice Payment Bond Faithful Performance Bond Certificate of Insurance and Endorsements Contract CONDITIONS OF THE CONTRACT Index Special Provisions ARCHITECTURAL SPECIFICATIONS The Architectural Specifications are printed on the Plans. i 7 O N N V UM= o M a+ a•) U � C 3 4- S- o•r r O •r 61�Y )oaupp,s- J.�ro 03 C tr 7UW 4J 4J N rt V) W t • r C r O q 4- 3c O O 01r + r° W' a u M 'O C �Cpp i N 40 E O 7 0 iLL r V) 4J Q! O U •r N O L G) U 4) N d C 6 a +) n- .o w O Y 4� 4J ut O N O O C r T r v) O c v) u r r O C C > p•r o L N A in 6 N •r O T C > U N i N O y 41 > E m E w d) U L ++ a r N 7 L L 0 P = yy a+ C C q L LLO ; — U Et 3 w L a u u 4 t o m i o ;wv au z z o Z a < W cr a m O O cc z o m �- O Q [� Q Z � W O U 1 I • CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT CONSTRUCT RESTROOM AND RENOVATE CHANNEL PLACE PARK PROPOSAL CONTRACT NO. 2664 To the Honorable City Council City of Newport Beach 3300 Newport Boulevard P. 0. Box 1768 Newport Beach, CA 92658 -8915 Gentlemen: PR 1.1 The undersigned declares that he has carefully examined the location of the work, has read the Instructions to Bidders, has examined the Plans (Drawing No. B- 5122 -S consisting of 14 sheets, and Drawing No. P- 5130 -S consisting of 4 sheets), and the Special Provisions, and hereby pro- poses to furnish all materials and transportation necessary, and do all the work required to complete this Contract No. 2664 in accordance with the Plans and Special Conditions, and will take in full payment therefor the following prices for the work, complete in place, to wit: 'ITEM QUANTITY ITEM DESCRIPTION UNIT TOTAL NO. AND UNIT UNIT PRICE WRITTEN IN WORDS PRICE PRICE RESTROOM 1. Lump Sum Construct restroom facility, includ- ing attached shade structures, sewer lateral, connections to water supply and existing electrical service, for the lump sum price of: @ One Hundred Four Thousand--- - - - - -- Dollars and No/ 100---------------------- - - - - -- -Cents $ 104,000.00 2. Lump Sum Construct sewer lateral complete in place, for the lump sum price of @ Two Thousand Five Hundred--- - - - - -- Dollars and No/ 100---------------------- - - - - -- -Cents $ 2,500.00 PR 1.2 PARK IMPROVEMENTS 3. Lump Sum Construct picnic structure, complete in place, for the lump sum price of: @ Fourteen Thousand Two Hundred . Dollars and Nineteen and No /100--------- - - - - -- Cents $14,219.00 4. Lump Sum Furnish and install drinking fountain, complete in place, including dry well, for the lump sum price of: @ One Hundred Seventy Five--- - - - - -- Dollars and No/ 100---------------------- - - - - -- -Cents $175.00 5. Lump Sum Construct 18 feet wide curb access ramp, Case D, per Std. - 181 -L, for the lump sum price of: @ Nine Hundred Eighty-------- - - - - -- Dollars and No/ 100---------------------- - - - - -- -Cents $980.00 6. 6400 Construct 4" thick p.c.c. sidewalk s.f. for the unit price of: @ Two--------- ---- ------ ----- - - - - -- Dollars and 50/ 100---------------------- - - - - -- Cents $ 2.50 $16,000.00 per square foot 7. 390 Construct 8" thick concrete block wall, l.f. including footings, for the unit price of: @ Twenty Seven--------------- - - - - -- -Dollars and No/ 100--------------------- - - - - -- -Cents $ 27.00 $10,530.00 per linear foot 8. 204 Construct 16" thick concrete block wall, l.f. including footings, for the unit price of: @ Thirty Three--------------- - - - - -- Dollars and No /100-- ------------------- - - - - -- -Cents $_33.00 $ 6,732.00 per linear foot PR 1.3 9. 274 Construct p.c.c. mow strip for the l.f. unit price of: Four ------------------------ - - - - -- Dollars and No/ 100--- ------------------- - - - - -- -Cents $-4.00 $ 1.096.00 per linear foot 10. 8 each Provide and install pre -cast concrete bollards, for the unit price of: Three Hundred--------------- - - - - -- Dollars and No/ 100---------------------- - - - - -- -Cents $_300.00 $400.00 eac TOTAL PRICE WRITTEN IN WORDS (Items 1 through 23 inclusive) One Hundred Fifty Eight Thousand Six Hundred Thirty TwoDollars and No/ 100------------------------------------ ------- - - - - -- Cents $ 158.632.00 August 24, 1988 Date (714) 945 -4730 Binder's lelep one Number #492622 C1 sses A & B Contractor's License No. & C assification ll Boulevard 2 0 Bid er's Address Rancho Cucamonga, CA 91730 INSTRUCTIONS TO BIDDERS The following contract documents shall be completed, executed and received by the City Clerk in accordance with NOTICE INVITING BIDS: 1. PROPOSAL 2. INSTRUCTIONS TO BIDDERS 3. DESIGNATION OF SUBCONTRACTORS) 4. BIDDER'S BOND (sum not less than 10% of total bid price) 5. NON - COLLUSION AFFIDAVIT 6. TECHNICAL ABILITY AND EXPERIENCE REFERENCES except that cash, certified check or cashier's check (sum not less than 10% of the total bid price) may be received in lieu of the Bidder's Bond. The title of the project and the words SEALED BID shall be clearly marked on the outside of the envelope containing the bid. The City of Newport Beach will not permit a substitute format for the contract documents listed above. Bidders are advised to review their content with bonding and leoal agents prior to submission of bid. Bids shall not be received from bidders who are not licensed in accordance with the provisions of Chapter 9, Division III of the Business and Professions' Code. The low bidder shall also be required to possess a City of Newport Beach business license prior to execution of contract. The estimated quantities indicated in the PROPOSAL are approximate, and are given solely to allow the comparison of bid totals. Bids are to be computed upon the estimated quantities indicated in the PROPOSAL multiplied by unit price submitted by the bidder. In the event of discrepancy between wording and figures, bid wording shall prevail over bid figures. In the event of error in the multiplication of estimated quantity by unit price, the correct multiplication will be computed and the bids will be compared with correctly multiplied totals. The City shall not be held respon- sible for bidder errors and omissions in the PROPOSAL. Contract documents shall bear signatures and titles of persons authorized to sign;on behalf of the bidder. For corporations, the signatures shall be of a corporate officer or an individual authorized by the corporation. For part- nerships, the signatures shall be of a general partner. For sole ownership, the signature shall be of the owner. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the contract. A copy of said determination is available in the office of the City Clerk. All parties to the contract shall be governed by all provisions of the California Labor Code relating to prevailing wage rates (Sections 1770 -7981 inclusive). The Contractor shall be responsible for compliance with Section 1777.5 of the California Labor Code for all apprenticeable occupations. #492622 Classes A & B Graco Cons ri tion Contr's Lic. No. & C asst ication Bidder August 24, 1988 s /Leo d6 resident Date Authqyized Signature /Title Page 2 • • Page 3 DESIGNATION OF SUBCONTRACTOR(S) The undersigned certifies that he has used bid(s) of the following listed subcontractor(s) in making up his bid,and that the subcontractor(s) listed will be used for the work for which they bid, subject to the approval of the Engineer and in accordance with the applicable provisions of the Specifications. No change of subcontractor may be made except with the prior approval of the Engineer-and as provided by State law. Subcontract Work 1. Electric Subcontractor Electrico Address Montebello, CA 2. Plumbing E & A Plumbing Pomona, CA 3, Masonry Upland Masonry Cucamonga, CA 4. Roofing Luce Brothers Baldwin Park, CA 5. Drywall 6. Painting 7. 8. 9. 10. 11. 12. Silvio Curtolo Yale Painting Pomona, CA N. Hollywood, CA Graco Cans r tion fl Bidder , President FMVTTte • BIDDER'S BOND KNOW ALL MEN BY THESE PRESENTS, That we, Graco Construction Corporation and Continental Surety Company of California, Inc. 0 Page 4 as bidder, as Surety, are held and firmly bound unto the City of Newport Beach, California, in the sum of Ten (10) Percent of amount bid Dollars ($ 10% ), lawful money of the United States for the payment of which sum well and truly to be made, we bind ourselves, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH, That if the proposal of the above bounden bidder for the construction of Construct Restroom and Other Improvements in Channel Park Contract #2664 Title of Project Contract No. in the City of Newport Beach, is accepted by the City Council of said City, and if the above bounden bidder shall duly enter into and execute a contract for such construction and shall execute and deliver to said City the "Payment" and "Faithful Performance" contract bonds described in the Specifications within ten (10) days (not including Saturday, Sunday, and Federal holidays) from the date of the mailing of contract documents for execution to the above bounden bidder by and from said City, then this obligation shall become null and void; otherwise it is and shall remain in full force and effect, and the amount specified herein shall be forfeited to the said City. In the event that any bidder above named executed this bond as an individual, it is agreed that the death of any such bidder shall not exonerate the Surety from its obligations under this bond. IN WITNESS of August WHEREOF, we 19 hereunto set our hands and seals this 23rd day 88. (Attach acknowledgement of Attorney -in -Fact) ,IN 1 Stnrknc+st Notary Public Commission Expires: November 24, 1989 Continental Suretv Comnanv of California Surety G Bys John Gr y Title . Attorn-act 0 NON- COLLUSION AFFIDAVIT • Page 5 The bidder, by its officers and agents or representatives present at the time of filing this bid, being duly sworn on their oaths, say that neither they nor any of them have, in any way, directly or indirectly, entered into any arrange- ment or agreement with any other bidder, or with -any public officer of such CITY OF NEWPORT BEACH whereby such affiant or affiants or either of them, has paid or is to pay to such bidder or public officer any sum of money, or has given or is to give to such other bidder or public officer anything of value whatever; or such affiant or affiants or either of them has not directly or indirectly, entered into any arrangement or agreement with any other bidder or bidders, which tends to or does lessen or destroy free competition in the letting of the contract sought for by the attached bids; that no bid has been accepted from any subcontractor or materialman through any bid depository, the bylaws, rules or regulations of which prohibit or prevent the bidder from con- sidering any bid from any subcontractor or materialman which is not processed through said bid depository, or which prevent any subcontractor or materialman from submitting bids to a bidder who does not use the facilities of or accept bids from or through such bid depository; that no inducement of any form or character other than that which appears upon the face of the bid will be sug- gested, offered, paid or delivered to any person whomsoever to influence the acceptance of the said bid or awarding of the contract; nor has the bidder any agreement or understanding of any kind whatsoever with any person whomso- ever to pay, deliver to, or share with any other person in any way or manner, any of the proceeds of the contracts sought by this bid. Subscribed and sworn to before me this 24th day of August , 1988. My commission expires: May 20, 1991 Graco Construgtion Corporation ident gnature /1it1e GEORGIE E GRAY RAgY PUBLIC.CAL:FORN1 N BERNARDINO COuiry EXP. MAY 20. 1991 0 • Page 6 TECHNICAL ABILITY AND EXPERIENCE REFERENCES The undersigned submits herewith a statement of the work of similar character to that proposed herein which he has performed and successfully completed. Year Completed For Whom Performed (Detail) Person to Contact Telephone No PLEASE SEE ATTACHED Page 7 NOTICE The following are contract documents which shall be completed and executed by the successful bidder after he receives a letter of award from the City of Newport Beach: PAYMENT BOND (pages 8 & 9) FAITHFUL PERFORMANCE BOND (pages 10 & 11) CERTIFICATE OF INSURANCE & ENDORSEMENTS (pages 12, 13, 14) CONTRACT (pages 15 & 16) The City of Newport Beach will not permit a substitute format for these contract documents. Bidders are advised to review their content with bonding, insuring and legal agents prior to submission of bid. BONDING COMPANIES shall be acceptable as sureties in accordance with the latest revision of Federal Register Circular 570. INSURANCE COMPANIES shall be (1) licensed to conduct business in California, and (2) assigned Policyholders' Rating A (or higher) and Financial Size Category Class VIII (or larger) in accordance with the latest edition of Best's Ke Ratin Guide: Pro ert - Casualt . Coverages shall be prove or all? TYP N URANGE c ec ed on the CERTIFICATE OF INSURANCE. All costs associated with the specifications of these contract documents shall be absorbed in the bid. Such specifications shall include those contained in (1) each contract document and (2) the Standard S ecifications for Public Works Construction (latest edition a opte or use in the City of Newport Beach T; except as supplemented or modified by the Special Provisions for this project. Page 8 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS, That WHEREAS, the City Council of the City of Newport Beach, State of California, by motion adopted September 12, 1988 has awarded to Graco Construction Corporation hereinafter designated as the "Principal ", a contract for Construct Restroom and Other Improvements in Channel Park (C -2664) in the City of Newport Beach, in strict conformity with the Drawings and Specifications and other contract documents on file in the office of the City Clerk of the City of Newport Beach; WHEREAS, said Principal has executed or is about to execute said contract and the terms thereof require the furnishing of a bond with said contract, providing that if said Principal or any of his or its subcontractors, shall fail to pay for any materials, provisions, or other supplies used in, upon, for, or about the performance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth: NOW, THEREFORE, We GRACO CONSTRUCTION CORPORATION as Principal, and CONTINENTAL SURETY COMPANY OF CALIFORNIA, INC., as Surety, are held firmly bound unto the City of Newport Beach, in the sum of nWR HTTNIIRF.D PTVTV- RTC.HT THQUSAND SIX HUNDRED Dollars ($158,632.00 * **, THIRTY -TWO DOLLARS said sum being equal to 100% of the estimated amount payable by the City of Newport Beach under the terms of the contract; for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, 'successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if the above bounden Principal or his subcontractors, fail to pay for any materials, provisions, or other supplies, used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind or for amounts due under the Unemploy- ment Insurance Code with respect to such work or labor, that the Surety or Sureties will pay for the same, in an amount not exceeding the sum specified in the bond, and also, in case suit is brought upon the bond, a reasonable attorney's fee, to be fixed by the Court as required by the provisions of Section 3250 of the Civil Code of the State of California. The bond shall inure to the benefit of any and all persons, companies, and corporations entitled to file claims under Section 3181 of the California Civil Code so as to give a right of action to them or their assigns in any suit brought upon Page 9 Payment Bond (Continued) this bond, as required by the Provisions of Sections 3247 et. seq. of the Civil Code of the State of California. And said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alterations or additions to the terms of the contract or to the work to be performed thereunder or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alterations or additions to the terms of the contract or to the work or to the specifications, In the event that any principal above named executed this bond as an individual, it is agreed that the death of any such principal shall not exonerate the Surety from its obligations under this bond. IN WITNESS WHEREOF, this instrument has been duly executed by the Principal and Surety above named, on the day of , 19 GRACO CONSTWTION CORPORATION (Seal ) e LEONARDO BARRIOS il, PRESIDENT Authorized Signature and Title / CONTINENTAL SURETY COMPANY OF CALIFORNIA,:INC. (Seal) Name of Surety 10822 Edison Cburt Ran CA 91710 nhn (`nc Address of Sure 'S—ign 'Ifid Tftle of ut or gent JOHN GRAY ATTORN EY_j N.r=4 ress of Agent TA714 945 ep one No. of Agent 6 ` .I �w,,�. Page 10 FAITHFUL PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS, That WHEREAS, the City Council of the City of Newport Beach, State of California, by motion adopted September 12, 1988 has awarded to Graco Construction Corporation hereinafter designated as the "Principal ", a contract for Construct Restroom and Other Improvements in Channel Park C -2664 in the City of Newport Beach, in strict conformity with the Drawings and Specifications and other contract documents on file in the office of the City Clerk of the City of Newport Beach; WHEREAS, said Principal has executed or is about to execute said contract and the terms thereof require the furnishing of a bond for the faithful performance of said contract; 1 • CONSTRUCTION CORPORATION as Principal, and CONTINENTAL SURETY COMPANY OF CAT.TFORNIA. IN as Surety, are held and firmly bound unto the City of Newport Beach, in the sum of ONE HUNDRED FIFTY -EIGHT THOUSAND SIX HUNDRED THIRTY - TWO -------------------------------- Dollars ($*15AFC,i2_nn * *)9 said sum being equal to 100% of the estimated amount of the contract, to be paid to the said City or its certain attorney, its successors, and assigns; for which payment well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if the above bounden Principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, con- ditions, and agreements in the said contract and any alteration thereof made as therein provided on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning. and shall indemnify and save harmless the City of Newport Beach, its officers and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall remain in full force and virtue. And.said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alterations or additions to the terms of the contract or to the work to be performed thereunder or to the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice 0 0 Page 11 Faithful Performance Bond (Continued) of any such change, extension of time, alterations or additions to the terms of the contract or to the work -or to the specifications. In the event that any principal above named executed this bond as an individual, it is agreed that the death of any such principal shall not exonerate the Surety from its obligations under this bond. IN WITNESS WHEREOF, this instrument has been duly executed by the Principal and Surety above named, on the day of , 19 GRAC+O CONSTRUCTION CARPOPATinm LEONARDO BARRIOS II, PRESIDENT Authorized Signature and Title ✓CONTINENTAL SLURETY COMPANY OF CALIFORNIA, INC. (Seal) Name of Surety 10822 Edison Court Rancho Cucamonga, CA 91730 SXWature and Title ot A�thorized Agent JOHN GRAY ATTORNEY -IN -FACT Address of Agent (714) 945 -0073 Telephone No. of Agent _Zak r -%,. I. , .1� - , �i� . � CERTIFICATE OF INSURANCE City of Newport Beach 3300 Newport Boulevard Newport Beach, CA 92663 A Tri Star Insurance B NAME AND ADDRESS OF INSURED Letter Safeco Company C Graco Construction Cor oration Letter 10535 F D thi11 Boulevard Letter Company £ Page 12 is is to certify that policies of insurance listed below have been issued to the insured named ove and are in force at this time, including attached endorsement(s). MPANY TTER TYPES OF INSURANCE COVERAGE REQUIRED Policy No. Policy Exp. Date L114ITS OF LIABILITY IN THOU NOS 000 Each Ag.Produc Completed Occurrence Operation GENERAL LIABILITY Comprehensive Form Bodily Injury $ $ x Premises- Operations Property Damage $ $ x Explosion & Collapse Hazard A x Underground Hazard x Products /Completed Operations Hazard 187 187 6/25/89 Bodily Injury and Property x Contractual Insurance Damage Combined $ 1,000, $ 1,000, x Broad Form Property Damage x Independent ContraGtvs x Personal Injury Marine Aviation Personal Injury $ 11000, AUTOMOTIVE LIABILITY B ❑x Comprehensive Form ❑x Owned BA21749 53 6/25/89 Bodily Injury (Each Person $ $ Bodily njury (Each Occurrence ) ❑x Hired Property ama e (] Non -owned Bodily injury and Property Damage Combined $ 1,000, EXCESS LIABILITY ❑ Umbrella Form Bodily Injury ❑ Other than Umbrella Form and Property Damage Combined $ $ WORKERS' COMPENSATION Statutory and EMPLOYER'S LIABILITY ac Accidenty '£: The Comprehensive General Liability and Automotive Liability policies are endorsed with the attached City of Newport Beach Endorsements. ICELLATION: Should any of the above described policies be cancelled or coverage reduced before the expiration date thereof, the•Insurance Company affording coverage shall provide 30 days' advance notice to the City of Newport Beach by registered mail, attention: Public Works Department. j, Agency: Griffith /Sincock Ins. Brokers Authorized Representative :e: 9/15/88 Telephone: 714- 953 -9521 ;cription of operations /locations /Vehicles: All operations performed for the City of Newport Bch by or on behalf of the named insured in connection with the following designated contract: Construct Restroom and Other Improvements in Channel Park C -2664 e "ICE: This certificate or verification of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded by the policies listed herein. Notwith- standing any requirement, term, or condition of any contract or other document with respect to which this certificate or verification of insurance may be issued or may pertain, the insurance afforded by the policies described herein is subject to all the terms, exclusions and conditions of such policies, including attached endorsements. 81 y SEP 22 '88 15:04 It is agreed that: GRACO CONSTRUCTION CORPORATION 0 CITY OF NEWPORT BEACH U 487 P02 AUTOMOTIVE LIABILITY INSURANCE ENDORSEMENT Page 13 With respect to'such insurance as is afforded by the policy for Bodily Injury and Property Damage Liability, the City of Newport Beach, its officers and employees are additional insureds but only with respect to liability for damages arising out of the ownership, maintenance or use of automobiles (or autos) used by or on behalf of the named insured in connection with the contract designated below. The insurance extended by this endorsement to said additional insured does not apply to bodily injury or property damage arising out of automobiles (1) owned by or registered in the name of an additional insured, or (2) leased or rented by an additional insured, or (3) operated by an additional insured, The insurance afforded the additional named insured(s) shall apply as primary insurance and no other insurance maintained by the City of Newport Beach will be called upon to contribute with insurance provided by this policy. 2. The policy includes the following provision: "The insurance afforded by the policy applies separately to each insured who is seeking coverage or against whom a claim is made or suit is brought, except with respect to the limits of the Insurance Company's liability." 3. The limits of liability under this endorsement for the additional insureds named in paragraph 1 of this endorsement shall be the limits indicated below for either Multi- ple Limits or Single Limit, whichever is indicated by the letter X in the appropriate box, ( ) Multiple Limits Bodily Injury Liability $ each occurrence Property Damage Liability $ each occurrence (X ) Single Limit Bodily Injury Liability $ 1,000,000 each occurrence and Property Damage Liability Combined The limits of liability as stated in paragraph 3 of this endorsement shall not in- crease the total liability of the Insurance Company for all damages as the result of any one accident or occurrence in excess of the limits of Liability stated in the policy as applicable to Automobile Liability Insurance. 4. Should the policy be cancelled or coverage reduced before the expiration date thereof, the Insurance Company shall provide 30 days' advance notice to the City of Newport Beach by registered mail, Attention: Public Works Department. 5. Designated Contract: e ana Lon}:ra This endorsement is effective 9 -15 -88 at 12:01 A.M. and forms a part of Policy No. BA2174953 Named Insured Graco Construction, Corp. Endorsement No. Name of Insurance Company Safeco _By d uthorized Representative Page 14 • CITY Of NEWPORT BEACH COMPREHENSIVE GENERAL LIABILITY INSURANCE ENDORSEMENT It is agreed that: With respect to such insurance as is afforded by the policy for Comprehensive General Liability, the City of Newport Beach, its officers and employees are additional in- sureds but only with respect to liability arising out of operations performed by or on behalf of the named insured in connection with the contract designated below or acts and omissions of the City of Newport Beach in connection with its general supervision of such operations. The insurance afforded said additional insured shall apply as primary insurance and no other insurance maintained by the City of Newport Beach will be called upon to contribute with insurance provided by this policy. 2, The policy includes the following provision: "The insurance afforded by the policy applies separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the Insurance Company's liability." 3. The insurance afforded by the policy for Contractual Liability Insurance (subject to the terms, conditions and exclusions applicable to such insurance) includes liability assumed by the named insured under the indemnification or nold harmless provision con- tained in the written contract, designated below, between the named insured and the City of Newport Beach. 4. With respect to such insurance as is afforded by this policy, the exclusions, if any, pertaining to the explosion hazard, collapse hazard and underground property hazard (commonly referred to as "XCU "hazards) are deleted. 5. The limits of liability under this endorsement for the additional insured named in paragraph 1 of this endorsement shall be the limits indicated below for either Multiple Limits or Single Limit, whichever is indicated by the letter X in the appropriate box. ( ) Multiple Limits Bodily Injury Liability $,_-_____-__ each occurrence Property Damage liability $ each occurrence (X) Single Limit Bodily Injury Liability $ 1.000,000 _. each occurrence and Property Damage Liability Combined The applicable limit of the Insurance Company's liability for the insurance afforded for contractual liability shall be reduced by any amount paid as damages under this endorsement in behalf of the additional insureds. The limits of liability as stated in this endorsement shall not increase the total liability of the Insurance Company for all damages as the result of any one occurrence in excess of the limits of liability stated in the policy as applicable to Comprehen- sive General Liability Insurance. 6. Should the policy be cancelled or coverage reduced before the expiration date thereof, the Insurance Company shall provide 30 days' advance notice to the City of Newport Beach by registered mail, Attention:. Public Works Department 7. Designated Contract: ea This endorsement is effective 9/15/$a_ at 12:01 A.M. and forms a part of Policy No. TGL100187 Named Insured Graco Construe tin Qoro. Endorsement No. Name of insurance Company Tr} S ar Tncuranre By__S�Q� —x• ✓' Authorized Representative STATE P.O. BOX 807, SAN FRANCISCO, CA 94101 -0807 COMPENSATION INSURANCE FUND CERTIFICATE OF WORKERS' COMPENSATION INSURANCE SEPT. 15, 1988 POLICY NUMBER: 768858 -88 CERTIFICATE EXPIRES: 10 -13_88 CITY OF NEWPORT BEACH DEPT. OF BUILDING & SAFETY 3300 NEWPORT BLVD. NEWPORT BEACH, CA 92658 -8915 L This is to certify that we have issued a valid Workers' Compensation insurance policy in a form approved by the California Insurance Commissioner to the employer named below for the policy period indicated. This policy is not subject to cancellation by the Fund except upon ten days' advance written notice to the employer. We will also give you TEN days' advance notice should this policy be cancelled prior to its normal expiration. This certificate of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded by the policies listed herein. Notwithstanding any requirement, term, or condition of any contract or other document with respect to which this certificate of insurance may be issued or may pertain, the insurance afforded by the policies described herein is subject to all the terms, exclusions and conditions of such policies. PRESIDENT EMPLOYER I- GRACO CONSTRUCTION CORPORATION 10535 FOOTHILL SUITE 230 RANCHO CUCAMONGA, CA 91730 MG L Page 15 CONTRACT THIS AGREEMENT, entered into :tm s- ay of ` , 19 2(L, by and between the CITY OF NEWPORT BEACH, hereinafter "City, d Graco Construction Corporation hereinafter "Contractor, "is made with reference to the following facts: (a) City has heretofore advertised for bids for the following described public work: in Channel Park 1e 2664 Contract No. (b) Contractor has been determined by City to be the lowest responsi- ble bidder on said public work, and Contractor's bid, and the compensation set forth in this contract, is based upon a careful examination of all plans and specifications by Contractor, NOW, THEREFORE, the parties hereto agree as follows: 1. Contractor shall furnish all materials and perform all of the work for the construction of the following described public work: & other Improvements in Channel Park 2664 le of Project Contract No. which project is more fully described in the contract documents. Contractor shall perform and complete this work in a good and workmanlike manner, and in accordance with all of the contract documents. 2. As full compensation for the performance and completion of this work as prescribed above, City shall pay to Contractor the sum of -Dne_ hundred fiftv_eiaht thousand six hundred thirty two and No/JK$ 158,63 . This compensation includes (1 ) any loss or damage arising the nature of t e work; (2) any loss or damage arising from any unforeseen difficulties or obstruc- tions in the performance of the work; (3) any expense incurred as a result of any suspension or discontinuance of the work; but excludes any loss resulting from earthquakes of a magnitude in excess of 3.5 on the Richter Scale and tidal waves, and which loss or expense occurs prior to acceptance of the work by City. 3. All of the respective rights and obligations of City and Contractor are set forth in the contract documents. The contract documents are incorporated herein by reference as though set out in full and include the following: (a) Notice Inviting Bids (b) Instruction to Bidders and documents referenced therein (c) Payment Bond (d) Faithful Performance.Bond (e) Certificate of Insurance and Endorsement(s) • Page 16 (f) Plans and Special Provisions for Construct Restroom & Other Improvements in Channel Park - Title of Project Contract No. (g) This Contract. 4. Contractor shall assume the defense of, and indemnify and hold harmless, City and its officers, employees and representatives from all claims, loss or damage, except such loss or damage proximately caused by the sole negligence of City or its officers, employees and representatives. IN WITNESS WHEREOF, the parties hereto have caused this contract to be executed the day and year first above written. I' 1 ORACO CONSTRUCTION CORPORATION IEONAMOO BAMM1O511, YM b1UtN I Authorized Signature and Title CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT CONSTRUCT RESTROOM AND OTHER IMPROVEMENTS IN CHANNEL PARK CONTRACT NO. 2664 SPECIAL PROVISIONS INDEX SECTION PAGE I GENERAL CONDITIONS . . . . . . . . . . . . . . . . . . . . . . . . I II. ADMINISTRATION OF THE CONTRACT . . . . . . . . . . . . . . . . . . I III. LOCATION AND SCOPE OR WORK . . . . . . . . . . . . . . . . . . . . I IV. TIME OF CONTRACT . . . . . . . . . . . . . . . . . . . . . . . . . 3 V. PERIOD OF FAITHFUL PERFORMANCE BOND . . . . . . . . . . . . . . . . 3 VI. LIABILITY INSURANCE . . . . . . . . . . . . . . . . . . . . . . . . 4 A. General Liability . . . . . . . . . . . . . . . . . . . . . . . 4 B. Automobile Liability . . . . . . . . . . . . . . . . . . . . . 4 VII. GUARANTEES . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 VIII. SAFETY . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 IX. TEMPORARY FACILITIES . . . . . . . . . . . . . . . . . . . . . . . 5 X. CLEANUP AND DISPOSAL . . . . . . . . . . . . . . . . . . . . . . 5 A. During the Work . . . . . . . . . . . . . . . . . . . . . . . . 5 B. Final Cleanup . . . . . . . . . . . . . . . . . . . . . . . . . 5 C. Disposal . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 XI. PAYMENT . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 A. General. . . . . . . . . . . . . . . . . . . . . . . 5 B. Monthly Progress Payments. . . . . . . . . . . . 6 XII. MATERIALS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 6 XIII. FIELD ENGINEERING . . . . . . . . . . . . . . . . . . . . . . . . . 6 A. General . . . . . . . . . . . . . . . . . . . . . . . . . . . . 6 B. Survey Control Data . . . . . . . . . . . . . . . . . . . . . . 6 XIV. INSPECTION . . . . . . . . . . . . . . . . . . . . . . . . . . . . 6 0- 0 CITY OF NEWPORT BEACH PUBLIC WORKS DEPARTMENT CONSTRUCT RESTROOM AND RENOVATE CHANNEL PARK CONTRACT NO. 2664 SPECIAL PROVISIONS I. GENERAL CONDITIONS SP 1 of 6 The parties to this contract are the City of Newport Beach and the Contractor. The Standard Specifications of the City of Newport Beach shall govern contractual relationships between the parties to this contract. II. ADMINISTRATION OF THE CONTRACT A. The Public Works Director of the City of Newport Beach shall administer this contract for the City. 1. Any change order, change in scope of the work, or change in contract price must be in writing and must be signed by the Public Works Director. B. The architect will be responsible for answering technical and construction questions regarding the restroom and attached shade shelters, and the picnic shelter. C. The landscape architect will be responsible for answering technical questions regarding landscape hardscape construction. III. LOCATION AND SCOPE OF WORK A. The work to be done under this contract consists of constructing a new public restroom with attached shade shelters, a picnic shelter, concrete block walls, portland cement concrete sidewalk, portland cement concrete mow strips, a drinking fountain, bollards, and associated items of work in the existing Channel Park located on Channel Place between River Avenue and Balboa Boulevard in the City of Newport Beach. No planting or additions to the existing irrigation system is included in this contract. The existing turf will remain. B. The work to be done under this contract includes furnishing all labor, materials, vehicles, tools, machines, equipment, transpor- tation and incidentials necessary to complete construction of the project as shown on the plans. SP 2 of 6 C. Items of work to be done by the contractor Contract 2664 include, but are not limited to: 1. Construct restroom building including attached shade shelters and utility connections. 2. Construct picnic shelter. (For the purpose of computing pay- ment, the Portland cement concrete slab under the picnic shelter shall be paid for at the unit price bid for construct- ing 4 inch thick portland cement concrete sidewalk.) 3. Construct utility connections. (The City will pay all required connection fees. 4. Construct masonry walls. 5. Construct portland cement concrete sidewalk and mow strips. 6. Furnish and install drinking fountain. 7. Furnish and install pre -cast concrete bollards. 8. Secure and pay for permits, fees and licenses. 9. Give required notices. 10. Comply with codes, ordinances, rules, regulations, orders and other legal requirements of public authorities which bear on performance of the work 15. Provide construction staking. D. Each bidder must list a price for each and every item on the Proposal. The City specifically reserves the right to delete the followina items from the award of the contract: Bid Item No. 3 Bid Item No. 4 Picnic Structure Drinking Fountain Bid Item No. 6: Sidewalk, more than 25% of the quantity Bid Item No. 10: Precast concrete bollards If the City exercises its right to delete items of work from the award of the contract, the resolution awarding the contract will so state. For the purpose of determining the lowest responsible bid the price bid for every item on the Proposal will be used. E. The contract requires completion of all work in accordance with these Special Provisions, the plans, the City's Standard DrPeE s i cfor Public Works Construction, eftiy cats ion d r tions (Standard eci ications for Public Works Construction, 1985 Edition and 9 6 and 987 Supplements), the architectural specifications, and reference specifications. .. , SP3of 6 1. Copies of the Standard Specifications may be purchased from Building News, Inc., 3055 Overland Avenue, Los Angeles, California 90034, telephone (213) 870 -9871. Copies of the City's Standard Special Provisions and Standard Drawings may be purchased at the Public Works Department for 5 per set. 2. Portland cement concrete slabs on grade outside of the building, site utilities and drainage improvements will be constructed per the City's Standard Specifications and Drawings for Public Works Construction. 3. The plans consist of Drawing No. 85122 -S, consisting of 13 sheets, prepared by Ron Yeo, FAIA Architect; and Drawing No. P- 5130 -S, consisting of 9 sheets, prepared by Eichenberger, Fennell & Associates. The detailed specifications are included on the drawing. F. Included in the scope of the contract is payment of all fees and the securing of all permits normally charged by governing public agencies; payment of all connection charges normally charged by serving utilities; and furnishing all material, labor, and transportation necessary to complete the construction. 1. The following fees normally charged by the City of Newport Beach will be waived: a. Building excise tax fees. b. Building and plan check fees normally charged for the amount of the General Fund, including plumbing, electrical, and mechanical permits. 2. All other fees normally charged the City must be paid by the Contractor. 3. All contractors and subcontractors on the project must have a current City business license. IV. TIME OF CONTRACT The date of the contract is the date contract is awarded by the City Council. The contract shall be completed within 120 consecutive calendar days after award of the contract by the City Council. V. PERIOD OF FAITHFUL PERFORMANCE BOND The faithful performance bond for the contract shall remain in effect for the duration of the one (1) year guarantee period measured from the date of acceptance of the work by the City Council. SP 4 of 6 VI. LIABILITY INSURANCE Upon execution of the contract, the Contractor shall provide cer- tificate of insurance showing that he has liability insurance coverage. At the same time, the Contractor shall provide the insurance endor- sements on the forms provided as part of the contract documents. The liability insurance coverage shall include each of the following types of insurance. A. General Liability 1. Comprehensive Form 2. Premises - Operations 3. Explosion and Collapse Hazard 4. Underground Hazard 5. Products /Completed Operations Hazard 6. Contractual Insurance 7. Broad Form Property Damage 8. Independent Contractors 9. Personal Injury Automobile Liability 1. Comprehensive Form 2. Owned 3. Hired 4. Non -owned VII. GUARANTEES Besides guarantees required elsewhere, the Contractor shall and hereby does guarantee all work for a period of one (1) year after the date of acceptance of the work by the City, and shall repair and replace any and all such work, together with any other work which may be displaced in so doing, that may prove defective in workmanship and /or materials within the one (1) -year period from date of acceptance, without any expense whatsoever to the City is hereby authorized to proceed to have the defects repaired and made good at the expense of the contractor, who hereby agrees to pay the cost and charges therefor immediately on demand. VIII. SAFETY In accordance with generally accepted construction practices, the Contractor shall be solely and completely responsible for conditions of the job site, including safety of all persons and property during per- formance of the work, and the Contractor shall fully comply with all state, federal and other laws, rules, regulations, and orders relating to safety to the public and workers. SP 5 of 6 IX. TEMPORARY FACILITIES The Contractor must make his arrangements and provide for his use of the following facilities: 1. Electricity 2. Telephone 3. Sanitary facilities 4. Security fencing The Contractor may use at no cost City water that is available at the Park site. X. CLEANUP AND DISPOSAL A. During the Work At all times during the project, the site shall be kept clean. All dirt, waste and rubbish shall be removed frequently and not allowed to accumulate. B. Final Cleanup In addition to keeping the building and site clean during construction, the Contractor must thoroughly clean the inside of the building, including fixtures, equipment, hardware, walls, ceilings, and doors. This shall include thorough cleaning of window and opening ledges and sills, horizontal projections, exterior steps and platforms, and other surfaces. Dust, dirt, stains, had marks, paint spots, plaster drop- pings, or other foreign material shall be completely removed from the surfaces. C. Disposal Under no circumstances shall rubbish or waste material of any descrip- tion be disposed of on the site. All debris, rubbish, and water or surplus material shall be disposed of off the site. XI. PAYMENT A. General 1. The work to be done under this contract includes furnishing all labor, equipment, transportation, materials, and services necessary to complete the construction as shown on the plans and described in the Specifications. F SP 6 of 6 2. The lump sum price bid for constructing the c4ass4eem building shall be considered as full compensation for all labor, equipment, materials, services, and all other things necessary to complete the work in place, and no additional allowance will be made therefor. 3. Payment for all items of work Proposal shall be included in work listed in the Proposal. B. Monthly Progress Payments not separately provide for in the the prices bid for other items of The City will make monthly progress payments for work completed per Section 9 of the Standard Specifications. For purposes of making progress payments, the City's estimates of the amount of work completed will be used. XII. MATERIALS A. Materials for the building shall be as specified in the architec- tural specifications. The architectural specificatins are included with the plans. XIII. FIELD ENGINEERING A. General 1. The Contractor shall lay out the work from the drawings, the bench marks and the column lines to be established by City. The Contractor shall establish all additional bench marks, monuments, lines and levels necessary for the construction. 2. To lay out the work and to verify lines and elevations as the work progresses, the Contractor shall employ on experienced and competent Civil Engineer of Land Surveyor registered in the State California. XIV. INSPECTION All work will be inspected. All items covered or all stages of work that are not to remain observable must be inspected and approved before being covered up. The Contractor shall provide timely notice to the City when such inspection is needed. The architect will act as the agent of the City in inspecting the work. 0 Construction it ^3'r „TugC` i'- J%i.G:?aairLaiS Services :, F .0 Ffi� -cf Division r; , is i September 16, 1988 Mr. Kenneth L. Perry Project Manager CITY OF NEWPORT BEACH Public Works Department 3300 West Newport Boulevard Newport Beach, California 92658 -8915 GRAOO C OO MURUCUMM SEP 1 81988 6 NEV;h, ...,,CH � CAS.IF, RE: CONSTRUCTION RESTROOM AND OTHER IMPROVEMENTS IN CHANNEL PARK CONTRACT NO. C -2664 Dear Mr. Perry: Pursuant to your letter of September 13, 1988, enclosed herewith you will find fully executed and in proper format four copies of the following: Payment Bond; Faithful Performance Bond; Certificates of Insurance and Endorsements; Certificate of Worker's Compensation; executed Contract. It is our desire to commence this project at the earliest possible date. Accordingly, we herein respectfully request that a preconstruction meeting be set for Wednesday, September 21, 1988 or as soon thereafter as possible with the Notice to Proceed being issued the day immediately following subject meeting. We look forward to a very successful and expedient project and look forward to working with you throughout its duration. Cordially, GRACO CONSTRUCTION CORPORATION Leonardo Barrios, President By: L J _(n.n,, II 1a:&- , Terri Manuel, E ecutive Secre ry cc: Ron Camarena Continental Surety Company File #0627 Graco Gom�lfu 'tkm Corpo^al;or; 0 TO: ?2) Cup- r (3) CITY CLERK FROM: Public Works Department 0 September 20, 1988 SUBJECT: Construct Restroom and Other Improvements in Channel Park Contract No. 2664 1. 4 copies of Contract Documents ACTION REQUESTED: Mayor a. Sign attached form b. Forward to City Clerk 3. City Clerk a. Attest b. Return to the Public Works Department to Diane Wilkens Diane Wilkens Public Works Department Attachments BY THE CITY COUNCIL CITY OF NEWPORT BEACH S E P 12 1988 • TO: CITY COUNCIL �3� 1 i 1ptember 12, 1988 / . CITY COUNCIL AGENDA ITEM NO. F -14 FROM: Public Works Department, and Parks, Beaches and Recreation Department SUBJECT: CONSTRUCTION OF RESTROOM AND OTHER IMPROVEMENTS AT CHANNEL PARK (CONTRACT 2664) RECOMMENDATIONS: 1. Reject all bids received for Contract 2664 on August 24, 1988. 2. Direct the staff to reduce the scope of the park improvements portion of the project; and authorize the City Clerk to readvertise for bids for the revised project to be opened at 10:00 A.M. on October 13, 1988. DISCUSSION: • The 1988 -89 budget contains funds in the Restroom Replacement Program of the General Fund to construct a restroom in Channel Park; and an appropriation of $50,000 from the Building Excise Tax Fund to construct other park improvements in Channel Park. The location is shown on the attached sketch. On August 24, 1988 the City Clerk opened and read three bids for the subject project: Bidder Restroom Park Total Bid 1. Graco Construction $106,500.00 $50,472.00 $158,632.00* Rancho Cucamonga 2. Steen Construction Co. $109,470.00 $80,031.00 $189,501.00 ** Santa Ana 3. Doyle C. Forth & Co. $136,908.00 $85,959.44 $222,867.44 Costa Mesa Engineer's Estimate $120,000.00 $46,932.00 $166,932.00 • * The bid of the apparent low bidder, Graco Construction, was non - responsive to the call for bids because copies of the two addenda were not included with the bid documents submitted; and the bid was not submitted on the revised Proposal form that was part of Addendum No. 1. Graco did not use the correct quantities and description of work; therefore its bid cannot be determined with certainty from the face of the documents, and its bid cannot be compared directly with the other bids. Graco has submitted the attached letter stating that it desires to take the contract at the price bid. C • • Subject: Construction of restroom and other improvementsat Channel Park (Contract 2664) September 12, 1988 Page 2 ** The bid of Steen Construction Co. contains minor irregularities in that the prices for unit price items were written in words where unit prices are supposed to be written; however, the product of the unit prices and the quantities indicate clearly what prices the contractor intended to bid. The City has at least three options: 1. If the City Council finds that the irregularities in the low bid are minor, the minor irregularities can be waived and the contract awarded to Graco Construction. 2. If the Council finds that the irregularities in the low bid are not minor, the low bid must be rejected, and a. The contract may be awarded to the next lowest responsive bidder. b. All bids may be rejected. The staff is of the opinion that the irregularities in the bid of Graco are not minor in nature because Graco was not bidding on the same basis as the other two bidders; and that therefore the low bid must be rejected. It cannot be said with certainty that the project cannot be constructed by Graco for the total price bid; therefore, the staff does not recommend that the contract be awarded to the second low bidder at a cost of more than $30,000 above the bid of Graco. Among other reasons, the prices bid by Steen exceed the amount of funds appropriated from the Building Excise Tax Fund for the park improvements by approximately $34,500. To award the contract to Steen would require deletion of much of the park improvements; or the appropriation of additional funds. If the scope of the park improvements is reduced, the park improvements in the contract would include the picnic shelter and the seat wall separating the turf from the sand. Bollards, sidewalk, and the low wall along Channel Place would be eliminated. The drinking fountain will be considered a part of the restroom. The remainder of the appropriation for park improvements will be used for work by City forces or by purchase order work. If the contract is awarded as bid the estimated date of completion would be January 15, 1989. If the project is readvertised for bids, the estimated date of completion would be March 15, 1989. • Subject: Construction• rest room and other improvement t Channel Park (Contract 2664) September 12, 1988 Page 3 :7 The plans for the restroom were prepared by Ron Yeo, FAIA Architect, of Corona del Mar. The plans for the park were prepared by Eichenberger, Fennell & Associates of Costa Mesa. Oonebb City Engineer KLP:dw • Ronald A. Whitley Parks, Beaches and Re eation Director • TO: CITY COUNCIL BY THE CITY COUNCIL CITY OF NEWPORT BEACH July 11, 1988 CITY COUNCIL AGENDA ITEM NO. F -12 FROM: Public Works Department and Parks, Beaches & Recreation Department SUBJECT: CONSTRUCT RESTROOM AND OTHER IMPROVEMENTS IN CHANNEL PARK CONTRACT NO. 2664 RECOMMENDATIONS: 1. Approve the plans and specifications. 2. Authorize the City Clerk to advertise for h"tn_ A_nPPnnA t DISCUSSION: •The 1988 -89 budget contains an appropriation of $45,725 from the Building Excise Tax Fund to construct improvements to Channel Park; and an appropriation of $300,375 from the General Fund to replace restrooms at selected beach locations. The restroom in Channel Park is to be financed by the Restroom Replacement Program. The location of Channel Park is shown on the attached sketch. Preparation of plans and specifications was funded in the 1987 -88 budget. The plans for the restroom and the plans for park rehabilitation have been combined into one construction contract. The work included in the contract includes construction of a restroom building similar to the new restroom recently completed in the West Newport Park at Orange Street; a picnic shelter; low masonry walls; sidewalks; a drinking fountain; and pre -cast concrete picnic tables and benches. No planting is included in the contract. The construction budget is as follows: Restroom Construction $125,000 • Testing 2,500 Miscellaneous & contingent costs (10 %) 12,500 Park $ 42,000 Miscellaneous & contingent costs 3,725 Total estimated cost $185,725 The construction contract estimate is: $167,000 r3J) 1] • • • • Subject: Construct Restroom and Other Improvements in Channel Park (C -2664) July 11, 1988 Page 2 The plans for the restroom were prepared by Ron Yeo, FAIA Architect, Inc. of Corona del Mar. Park renovation plans were prepared by Eichenberger, Fennell & Associates, of Costa Mesa. The estimated date of completion is October 31, 1988. A full set of the plans will be on display in the Council's conference room. Benjamin B. Nolan Public Works Director KP:so Attachment Ronald R. Whitley Parks, Beachs & Recreation Director HE l 0 gp l � T i 14 _asap 2( 2 30 -/-PssaA E�Rf /" EI► � ° -sso P e 5� so a? 2 a� 'o p Q peas' e` _ 5y� e h0 ez� AC Iv i l• �. (' JJl,r -. �"gjFS5 //q Quo /9 eo 1 a/ b 7 o� 0 4 9 f i VA FDA /9 V�"�`g I: d7Q ::• �" 3 v` 'PjvEQ 7 .6 S �F 1 \0 ?Z,� 9 on �9C 0 Z / r � � v 30' .00 G C�,QNEQ J ;y gqy QLE 3 z, 0 Aotnonaed to Publish Advertisements of all kinds including public notices by Decree of the Superior Court of Orange County. California. Number A -6214. dated 29 September. 1961, and A- 24831. dated 11 June. 1963. STATE OF CALIFORNIA I County of Orange P.1W IIOIKa .o .n.ne �� • « Of IM Yhtl.M a W .1 ) peMl +IM 10 W& CW X10111 I am a Citizen of the United States and a resident of the County aforesaid; I im over the age of eighteen years, and not a party to or interested in the below entitled matter. I am a principal clerk of the Orange Coast DAILY PILOT, with which is combined the NEWS- PRESS, a newspaper of general circulation, printed and published in the City of Costa Mesa, County of Orange. State of California, and that a Notice of Notice Invitinq.Bids of which copy attached hereto is a true and complete copy, was printed and.published in the Costa Mesa, Newport Beach, Huntington Beach, Fountain Valley, Irvine, the South Coast communities and Laguna Beach issues of said newspaper for two (2 ) consecutive weeks to wit the issue(s) of July 14 8 198 — July 21 g 198 198_ 198_ 198_ I declare, under penalty of perjury, that the foregoing is true and correct. Executed on July 21 ,198 s at Costa Mesa, California. Signature �1 I ­I,/ PROOF OF PUBLICATION 0 U-611 Yib lingCollvems 330 West Bay.Street, Costa Mesa, California 92626 • 714 642 -4321 -Orange Coast Daily Pilot -Huntington Bedch•Fndependent Dear Advertiser: Enclosed please find clipping of your ad from the first publication. If you need to make any changes or corrections, please call me at your earl'i'l-st convenience. The cost of this publication will be' $ / a- t Thanks for your cooperation and patronage. Sincerely, NOTM MVMNG a" t Settled 9dy dotting, Supervisor may 'be calved at the ot9ce or the Legal Advertising Dept. City Clerk. 3308 Boulevard p. O. 111x" 1 88; Nawpart Beath, CA 94888-0815 u,* w a.m: 'Oh the 40m day of AtVita6 4988, at which time such bids Shah ba evened .n , d by it t.>lim em a. atioa t> r�OF UNCONDITIONAL WAIVER AND RELEASE_ UPON FINAL (Ca6lornia Civil Code §3262(d)(4)] par WA The undersigned has been paid in full for all labor, services, equipment or material 'f'ui•rilghed to Graco Construction Co. /City of Newport Beach on the job of Contract No. 2664. (Your cusloma4 (owne4 Channel Place Park located at /in the City of Newnnrt Raarh (JOO OascrielbN and does hereby waive and release any right to a mechanic's lien, stop notice, or any right against a labor and material bond on the job, except for disputed claims for extra work in the amount of 36 Dated:`�q (company Name) By e cc.Jn7Evy (Tills) NOTICE TO PERSONS SIGNING THIS WAIVER: THIS DOCUMENT WAIVES RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL RELEASE FORM. NOTE This form of release complies with the requirements of Civil Code Section 32621dx4). USE REVERSE SIDE AS RELEASE FOR INDIVIDUAL$,PifffaP64816 rno �11GES °s���y���Z Nrim dillF4NY>t62A— UNCONpITi4NAL WAKEN AND RELEASE UPON FINAL R1YNENT —Nay.l e5 � v� �..� !f v X905 WO ;COtii iNG IDrp:s dKt 72t R. e���. w • I UNCONDITIONAL WAIVER AND RELEASE UPON FINAL [California Civil Code 13262(d)(4)] The undersigned has been, paid in full for all labor, services, equipment or to OeAC d C'mu5 u cTr 8>y on the job of Your Customer) l�l aPba.-T QF located at-j( ooy —PRA_ RECEIVED Aw IN . (JOb Description) and does hereby waive and release any right to a mechanic's lien, stop notice, or any right against a labor and material bond on the job, except for disputed claims for extra work in the amount of $ 336 Dated: �� 3 �� 0�0-� )6z n'P -� ���s� ✓9 Company Nardf / NOTICE TO PERSONS SIGNING THIS WAIVER: THIS DOL`W-_ONT WAIVES RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE , 0 - BEEN PAID, USE A CONDITIONAL RELEASE FORM. t.. +cilmen eager NOTE: This form of release complies with the requirements of Civil Code Section 3262)d)(4). 111torney USE REVERSE SIDE AS RELEASE FOR INDIVID � WAGES � -Jg' Dir. .,t1$P.fY Dir. � �m &itDir. °'� �1 7 i'ianrtng Oir. IJV WDLCOTTS UP-2N 3262.4-UNCONDITIONAL WIINEP AND RELEASE UPON FINAL PAYMENT -Rev. t lrziiM�� Iprke Naze 7 -1) it ir tHE "NOERVESIGNED HAVE PE&VED SAVOR FUN WAUFS1,Y4 !Ht PRO*-DESCRIBED ON FACE OF FOAM AND HAVE BEEN PAID iW FULL TO DA Parton �" Lab - Podbm*' q Lab �- rO wawsl (Date) Jk :, 1 i ;at C.-, t " L a b W a,;z Data; iS,g,at.ia Cl, Male) �Sg.atua — 1,d:iOual ',Vage3) ,-W, §MILESFO COMPLETE OTHER SIDE Z;Z g p�'- p.''�'�olPr/Ti� , • ,,mot\ Y s RECEIVED UNCOi�H'ffloo L WAIVER AND RELEASE UPON FINAL` AYIN� [California Civil Code §3262(d)]4)] The undersigned has been paid in full for all labor, services, equipment or mater�J!fliYr�i�hed to Graco Construction Co. /City of Newport Beach on the job of Contract No. 2664, pour cuato"it (Owne,) Channel Place Park located at [in the City of NPwpnrt Rea5, h (JOE lon) and does hereby waive and release any right to a mechanic's lien, stop notice, or any right against a labor and material bond on the job, except for disputed claims for extra work in the amount of g /,i7atr-Ti Dated: - /`- s-- i �%•�,� ( cE�c` i�r�duc�s morn, (company Nama) (Title) NOTICE TO PERSONS SIGNING THIS WAIVER: THIS DD000MENT WAIVES RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL RELEASE FORM. -+ 1%. 9 9 10' CONDITIONAL WAIVER AND RELEASE UPON FINAL P NT� �r yr a Upon receipt by the undersigned of a check fromCITY Of NEWPORT BEACH �\ REKIFit Am (Maker of Check) 13 N of $ 28400 Q payable to GRACD CONSTR. and LEE ROOFING and when the cl)w4w been (Payee or Payees of Check) � properly endorsed and has been paid by the bank upon which it is drawn, this document'�hal 76ftte effective to release any mechanic's lien, stop notice or bond right the undersigned has on the-job of CITY OF NEWPORT BEACH located at CHANNEL PLACE PARK This (Owner) (Job Address) release covers the final payment to the undersigned for all labor, service, equipment or material furnished on the job, except for disputed claims for extra work in the amount of $ Before any recipient of this document relies on it, said party should verify evidence of payment to the undersigned. � B ` ,/ (Compansy�Name) By: c , Ctwa tcl" / ��00000� (R0� sy (Title) BOOKKEEPER G cn n ; c s _ TO BDI: 9 0 r�. CONDITIONAL WAIVER AND RELEASE UPON F Uport receipt by the undersigned of a check from of $ '' payable to (Maker of N (Payee or Payees of Check) paid by the bank upon which it is drawn, this document shall become effective mechanic's lien, stop notice or bond right the undersigned has on the job of located at i the OcAgldst Cr, the (Owner) (Job Address) following extent. This release covers a progress payment for labor, services, equipment or material furnished to through only and does (Your Customer) (Date) not cover any retention in the amount of $ , or items furnished after said date. Before any recipient of this document relies on it, said party should verify evidence of payment to the undersigned. Dated: LE ^4 (Title) (Company Name) F 62 Q 85, 1p LLOYD L. BEAMAN 9 ®� CONCRETE PUMPING SERVICE (213) 864-4125 P. o. sox 664 RECEIVED (714, 7391990 ARTESIA CA 90702 0664 % JUL 13N9 CONDITIONAL WAIVER AND RELEASE UPON FINAL PAYM�, [California Civil Code §3262(d)(3)] Upon receipt by the undersigned of a check from CITY OF NEWPORT BEACH (Maker of Checkl in the sum of $ 716.38 payable to LLOYD L.BEAMAN (Amount of Check) (Payee or Payees of Check) and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice, or bond right the undersigned has on the job of CITY OF NEvjPn'RT nF.anur:._ (owner) located at CHANNEL PLACE PARK - - -- RTVFR & b5 th _ NEWPORT REACH r CA _ 110o Descriytlonl This release covers the final payment to the undersigned for all labor, services, equipment or material furnished on the job, except for disputed claims for additional work in the amount of $ Before any recipient of this document relies on it, the party should verify evidence of payment to the undersigned. Dated: JUNE 14 -1989 LI:OYD L.BEAMAN CONCRETE PUMPING .om any Name) By ( OWNER )xOtl->^-� (fale) NOTE This form of release complies with the requirements of Civil Code Section 3262(d)(3). It is not effective until the check that constitutes final payment has been properly endorsed, and has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WOLCOTTS FORM 3262.3— CONDITIONAL WAIVER AND RELEASE UPON FINAL (Price class 7 -2) 5WOLCOTTS. INC. THE UNDERDESIGNED HAVE P*RMED, LABOR FOR WAGES ON THE PRVT DESCRIBED ON FACE OF FORM AND HAVE BEEN PAID IN FULL TO DATE (SQwk,?pll klicim" Pkm" Labor For Wages) (Dale) (Signirtunt, (X Inclir,"I Performing Labor For Wages) (Date) (Seprialixe Of kOrwrid" Pfirtorrmlig Labor For Wages) Pale) (S.9nisliure 04 kbdm-k%W Perk v Labor Fer Wages) (Date) (Signature Of 4kWdua; Pertonning Labor Fair Wages) (Dale) (Signature 04 Wicimcluai Pwitonnarg Lab" Far Wages) . (Date) (Signature Of tricuindual Performing Labor For Wages) (Date) (Signature Of Inenrioual Pe4orming Labor For Wages) (Date) (Signature Of Ini:lmdual Performing Labor For Wages) (Date) (Signature Of Inchvidual Performing Labor For Wages) (Date) (Signature of Inclondual Perkrining Lab, For Wages) (Dale) (S.Preartun. Of W P.d. labor For Wages) (Dal.) (Signature Of Inclodual Performing Labor For Wages) (Date) (S,gnatwe Of Individual Performing Labor For Wages) (Date) (Signature (N Individual Performing Labor For Wages) (Date) (Signature Of Individual Performing Labor For Wages) (Date) (Signature (211 Individual Performing Labor For Wages) (Date) (Signature 01 IndMdual Performing Labor For Wages) (Date) (Signabare Of Individual Performing Labor For Wages) (Dam) (Signature Of Individual Performing Labor For Wages) (Date) (Signature 0findividuaIP109gnygLabnF � ffVURft) . 4 - t�, (Signafure 01 Indwiridual Performing Labor For Wages) (Date) dEjAjjlRE TO COMPLETE OTHER SIDE RECEIVED i �CONBI flJ1MA� AIVER AND RELEASE UPON FINAL PAYA*IT4V 9 [California Civil Code §32621d1141j nor NEWPORT BEACH The undersigned has been paid in full for all labor, services, equipment or material furnished to Graco Construction Co. /City of Newport Beach on the job of Contract No. 2664. (Your Cuatornar) IOrnel Channel Place Park located at /in the City of Npwnnla a acri0 R Dep%C (JO11on) and does hereby waive and release any right to a mechanic's lien, stop notice, or any right against a labor and material bond on the job, except for disputed claims for extra work in the amount of $ Dated: •] NOTICE TO PERSONS SIGNING THIS WAIVER: THIS DOCUMENT WAIVES RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL RELEASE FORM. NOTE This form of release complies with the reouirements of Civil Code Section IlMdN41. �v ta6a FORM 110 -UFO UNCONDITIONAL WAIVER AND RELEASE UPON FINA ADD t.C)dn Code §3262(d)(4)) - JUL 13 1989 aaK N ro r gam, The undersigned has been paid in full for all labor, services, equipment or material furnished tOr?Arn rnNGT_.Tnc. onthejobof City of Newport Beach (your customer) (Owrmr) located at 4400 River Ave. Newport Beach, CA. and does hereby waive and (J Desvipl.) release any right`to a mechanic's lien, stop notice, or any right against a labor and material bond on the job, except for disputed claims for extra work in the amount of . * *n** % NOTICE: THIS DOCUMENT WAIVES RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE CONDITIONAL RELEASE FORM. Do Rw �► ~ NOTE: This form of release complies with the requirements of Civil Code Section 3262(d)(4 91 k\ 3O, T '\,, USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES §484(b) OF THE CALIFORNIA PENAL CODE PROVIDES IN PART AS FOLLOWS: "Any person who receives money for the purpose of obtaining or paying for services, labor, materials or equipment and willfully fails to apply such money for such purpose by either willfully failing to complete the improvements for which funds were provided or willfully failing to pay for services, labor, materials or equipment provided incident to such con- struction, and wrongfully diverts the funds to a use other than that for which the funds were received, shall be guilty of a public offense and punishable by a fine not exceeding five thousand dollars ($5,000), or by imprisonment in the state prison not exceeding five years, or in the county jail not exceeding one year, or by both such fine and such imprisonment." §484(e) OF THE CALIFORNIA PENAL CODE PROVIDES AS FOLLOWS: "Any person who submits a false voucher to obtain construction loan funds and does not use the funds for the purpose for which the claim was submitted is guilty of embezzlement." §206.5 OF THE CALIFORNIA LABOR CODE PROVIDES: "No employer shall require the execution of any release of any claim or right on account of wages due, or to become due, or made as an advance on wages to be earned, unless payment of such wages has been made. Any release required or executed In violation of the provisions of this section shall be null and void as between the employer and the employee and the violation of the provisions of this section shall be a misdemeanor." §532(e) OF THE CALIFORNIA PENAL CODE PROVIDES AS FOLLOWS: "Any person who receives money for the purpose of obtaining or paying for services, labor, materials or equipment incident to constructing improvements on real property and willfully rebates any pan of the money to of on behalf of anyone contracting with such person, for provision of the services, labor materials or equipment for which the money was given, shall be guilty of a misdemeanor; provided, however, that normal trade discount for prompt payment shall not be considered a violation of this section." FORM 110- UF— PUBLISHED BY 10 APdVk r#00%Jm 3055 OVERLAND AVENUE, LOS ANGELES, CALIFORNIA 90034— (213)202.777501585 Y 5 r 301S H3N10 3131dMO3 013uns 39 (elea) (sa&M 10j xOW1 6UIWJ011ed lenpAVul 10 am1eu &S) (oleo) (s86eM mjx el 6wuueped IMPrA:Wl b aiMRuErS1 (81901 (sa6eM 44 m4el 6wueof," lenpArpul 10 am1eu6,S) (alga) (sa6eM mj x)qel 6urwmyad lenpA,ml0 eNeuil S) (alma)'' jSe&mM lOj lopel&illux of R4.Ml 10 � +61EP &Sl lal9al (sa6eM mjrOgel 6ul -m00d lem,,,pul lo amleu6,S) (eleak ":: Isa6eM loj ro4el 6uluuOpad lenpmpul l0 anleu &S) (alga) 'ISa6eM mj�Oggl timwmyed RnpArpul k7 ainlcu6isl ) (81e0) (Sa6eM JOj Mcel 6u- u pgd lenPlATul b 9^0)6S) Iowa) (sa6eM mj mVel&xuuWed RnpAaall 10 amleu61g) (alga) Is46eM JOj mael 60"WOed lent) r lb 0^eubr,) (aB01 __ Isa6eMmj xgel6unumpad RnOrArpull0 amlru &ql „_., _. (oleo) (sOBeM mj JO l&Iwmyed tenprnrPOl pemleu&S) IaleO) _.._..__ ISa6eM ioj xx7816uxumyed Rr+PrAR>t+l_b fur4tv65) `__ IeleO) Isa6eM mjmcel6wuuoped lenPIAVIN 10 eNgu&SI. laleal (S.'meM mi+POel&ewioind lenpnrpul 108+n1eu6rg) . (0e0) .lsa6P.M mj -oq l&ou p&drNw4pufl0 wn1 b&s) hied (1e6PM nj 9q 16u- -".Md Rnp 0410 a ftl ✓`) (alga) (soften mj m49l 6wuo4IBd Myw4 I10 o^ru6rsl (e1r0) (986eM mj JO 9l 6urWg0d RMPAW 108Neub!S) (alga) (Seftm MA mpel lkxwe Rrywr st 108n4095,S) ,..(Blew Isg6em KWAiwllkm -d 10 1 31YO 01 lin:j NI OIYd N330 3AYH ONY WH03 30 33Y3 NO 038183S30 133POHd 3H1 NO S30VM 804 808Y1 03WH03H3d 3AYH MASI 0830Nn 31R! 0 0 0 RELEASE OF STOP NOTICE TO: City of Newport Beach 3300 Newport Blvd. Newport Beach, CA. 92663 OWNERS: City of Newport Beach The undersigned hereby withdraws the S t $ 4,335.62 for equipment and /or materi with that certain work of improvement Park, 4398 Channel Place, Ne::rort Beach, releases you from any further duty to response to the Stop Notice, and waives you that might accrue thereunder. Dated this 13th day of June, 1989, at Van Nuys, California Stan Rubin, General Credit Mgr. and Authorized Agent on behalf of FAMILIAN CORP dba Familian Pipe & Supply 13704 Saticoy Street Van Nuys, CA. 91402 STATE OF CALIFORNIA COUNTY OF LOS ANGELES RECEIVED JUL 13 1989 ary c� N�� BE1CH op Notice in the amount of al furnished in connection located at Channel Place Ca. 92663. The undersigned withhold money or bonds in any right of action against Date —7—/ 3 CORES SFMTO_ ❑ Mayor * Ci)Urxilmen 'CN IAanager Z f,I torney Q Mdg. Dir. [ GanSery Dir., • i- & R Dir. • Planning Dir., • Police Chief El P . Dir PJ Dther �CGLl�a,1c� Stan Rubin being first duly sworn deposes and says that he is the General Credit Manager of Familian Pipe & Supply, the corporation that executed the foregoing claim; that he makes this verification on behalf of said corporation; that he has read said claim and knows the contents thereof; and that the facts therein stated are true. Subscribed and sworn to before me this 13th day of June, 1989 Notary Public in and for said County and State Stan Rubin Graco Construction 0 0 0 CONDITIONAL WAIVER AND RELEASE PAYMENT UPON 9 '® y � . py RECEIVED F 1 3L]989 HEW"T BEACH Upon receipt by the undersigned of a check from City of Newport Beach (Maker of Check) in the sum of $ $5949.55 payable to (Amount of Check) Graco Construction & Terry Lumber Co. and when the check has been (Payee or Payees of Check) `' properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice, or bond right the undersigned has on the job of City of Newport Beach located at (Owner) 4398 Channel Pl., Newport Beach, CA This release covers the final payment to the undersigned for all Fa r,- services, equipment or material furnished on the job, except for disputed claims for additional work in the amount of $ -NONE - Before any recipient of this document relies on it, the party should verify evidence of payment to the undersigned. Dated: 5 -2 -89 Date 7 —11 COPIES SM70: • Mayor • Councilmen o Manager crAttorney ❑ Gen &en ry o DM. dFu &RDir. • Planning DM. • Police Chid o P.W. Dir ,e(0aw '?u ze,&Of- eICA FOAM 6.01 REV. 1.851 Lumber Co. of Glendale (Company Name) By �v Vice PresiderOtme) Finance RECEIVE6 JUL '13 1989 "EwPOai er n CONDITIONAL WAIVER AND RELEASE UPON FINAL PAYMENT Upon receipt by the undersigned of a check from rgam crigm- exmrcxa in the sum (Maker of Check) of $ 2,400.00 payable to LEE ROOFING OF OOSTA MESA, 1W. and when the check has been (Payee or Payees of Check) properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice or bond right the undersigned has on the job of CITY OF NEWPORT BEACH located at CAAMM PLACE PARK _. This (Owner) (Job Address) release covers the final payment to the undersigned for all labor, service, equipment or material furnished on the job, except for disputed claims for extra work in the amount of $ . Before any recipient of this document relies on it, said party should verify evidence of payment to the undersigned. Dated: 6 -5 -89 FIND OF COSTA MESA, INC. kS(Company Name) By: BOOKKEEPER (Title) Date 7 _..!3 O PIES SEAITW, • Mayor • Councilmen ' 43'Manager , 42f Att off:. ❑ GrnSery Dir. o f'I 3 R Dir. o F1 nni Dk. U Police Ghlet OrP.W.. Dir ' GYt)ther �u i�,k� � d RECEIVED CONDITIONAL WAIVER AND RELEASE LIPON� FINALI3 1989 PAYMENT This release is expressly limited to the claims which arise from the materials furnished by Familian Corp to this project. Nothing in this release shall be construed to impair Familian Corp claims against Grayco Const Corp or it's principals. FAMIk1AN CORD dto FamSisn Pip • Sueyly Co., sed /a, any Upon receipt by F' uiuANCORPP�ll Fmoomlen ^I of a check from City of Newport Beach (Maker of Check) in the sum of $ 4,335.62 payable to (Amount of Check) E Familian Pipe & Supply and when toe check has been (Payee or Payees of Check) properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice, or bond right the undersigned has City of Newport Beach on the job of located at (owner) Channel Place Park, 4398 Channel Place, Newport Beach, CA. 92663 (.lob Description) FAMCO FORM 2 (Rev. 2/85) This release covers the final payment to the undersigned for all labor, services, equipment or !3 material furnished on the job, except for disputed claims for additional work in the amount Cate .7 WES SENT7 � o Mayor of $ n Councilmen tf Manager zzf Attorney C, Bldg OW. , C.! Gen5ery Dir. Before any recipient of this document relies on it, the party should verify evidence of payment i:3 f`Rle & H Dir. to the undersigned. F1 Plannin0 Ok. 7 Police Chat :? gel P.W. Dir da'OTher R.d6y ' pltZ6 4 Dated: June 16, 1989 FA IAN pa N.7 FAMCO FORM 2 (Rev. 2/85) Release of Stop Notice TO: City of Newport Beach Construction Lender (or party with whom Stop Notice was filed) 3300 Newport Boulevard, Newport Beach, CA 92658 You are hereby notified that the undersigned claimant releases that certain Stop Notice dated 3/1/89 , in the amount of $9,338.59 RECEIVED JUL 13 1989 CM«mot Carr or NEWORf VW against City of Newport Beach as owner or public body and Graco Construction as prime contractor in connection with the work of improvement known as Balboa & Channel Place in the City of Newport Beach , County of Orange State of California. Date Name of Claimant United Premix Concrete, Inc. 'Fi Name) By(Signatnre) VERIFICATION Credit M¢r. (Official Capacity) I, the undersigned, state: I am the Credit Manager ( "Agent of "President of" "A Partner of "Owner of ", etc.) the claimant named in the foregoing Release; I have read said Release of Stop Notice and know the contents thereof, and I certify that the same is true of my own knowledge. I certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed on 6/8/89 State of California RICA FORM 5 (REV. 2/87) 19 , at Irwindale 6 Credit Mgr. (Signature of Claimant or Authorized Agent) Date t �: O ❑ Mayor [7 Councilmen \d Manager \td'Attorney Ci Mg. Dir. o C mSm Dir. o &RMr. • rlanning Dir. • Police Chid Z P.W. Dir 0 11 Release of Stop Notice ECEivED JUL 13 1989 TO: City of Newport Beach Construction Lender (or party with whom Stop Notice was filed) 3300 Newport Boulevard, Newport Beach, CA 92658 (Address) You are hereby notified that the undersigned claimant releases that certain Stop Notice dated 12/17/88 , in the amount of $ 1,894.78 against City of Newport Beach as owner or public body and Graco Construction (prime) Upland Masonry, Inc. (sub) as prime contractor in connection with the work of improvement known as 4400 River Avenue in the City of Newport Beach , County of Orange State of California. Date 6/8/89 Name of Claimant United Premix Concrete, Inc. L,e�e • irm Name) R Credit Mgr. By (Signature) VERIFICATION (Official Capacity) I, the undersigned, state: I am the Credit Manager ( "Agent of', "Presi ent of ", "A Partner of', caner of", etc. the claimant named in the foregoing Release; I have read said Release of Stop Notice and know the contents thereof, and I certify that the same is true of my own knowledge. I certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed on State of California BICA FORM 5(REV. 2/87) 19 , at Irwindale a4�fd/.y�f�n Credit Mgr. (Signature of Claimant or Authorized Agent) r_> 7 13 {`f' =';1_ SfNTT(k • °hayor • G(wncllmen tanager ,Attorneyy i BI t Qg. Dlr. r ; C?nSery Dir. ;]I"d &RDir. Cl Planning Dir. 0 Police Chief P.W. Dh 00Utar�i /ct , lstr. 0 CONDITIONAL WAIVER AND RELEASE UPON FINAL PA) [CalifornkCivil Code §3262(d)(3)j Upon receipt by the undersigned of a chec from 98S � {Mek t Check) in the sum of $ payable to (Amount of Check) (Payee or Payees of Check) and when the check has been properly endorsed and has been paid by the bank drawn, this document shall become effective to rplease any mechclnic's lien, stop KOMT EI Ipdh Which It IS notice, or bond right the undersigned has on the job of C4-644/%, r a A-f- / caner) located at q3 IS, ��� ,�° z°,j, . /T (Job Description) This release covers the final payment to the undersigned for all labor, services, equipment or material furnished on the job, except for disputed claims for additional work in the amount of $ . Before any recipient of this document relies on it, the party should verify evidence of payment to the undersigned. Dated: 6 -7 dr `a �p / (Company Rachel By ! 4c (Title) NOTE This form of release complies with the requirements of Civil Code Section 3262(d)(3). It is not effective until the check that constitutes final payment has been properly endorsed, and has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WOLCOTTS FORM 3262.3 — CONDITIONAL WAIVER AND RELEASE UPON FINAL PAYMENT —Rev, 185 1985 WOLCOTIS. INC. (price Gass I -2) Gas TH+DERDESIGNED HAVE PER&EDLABOR FOR WAGES ON THE PROJ*bESCRIBED ON FACE OF FORM AND HAVE BEEN PAID IN FULL TO DATE 'FLat" ()I jr4l'W4A pe(jo"'j"at k ataer For Wages) (Date) p (S nan m Os hal W-K i at P W tp ,ng I abor For Wart s) (Daa-) ,.--q 101WO Of 0 llanrrort Later f;+ Wages) (Crate! ('Dam) Wages) u '0'rv\ee 04 PerlOr"I'll., LatK:; Far wag".!. ;DaloV (Cyndare 0i14.JioUa!Pertmning Labor FIX - WaW) — ----- — TOM;; (Date) (Cwgnaaur. Of 1,4,,dual Part.,,," Labor For Wage.,) (Oat.) (Sqnature Of imwtival Pumcr,ratwi i. atzr For wages) (Data) Wages) jData.) {Slq,,alw,o CA ild"a!Vai Pedommm[,l ava iu Wages) (Date) (Syrtwos a cl lldl•ldual Fredo,rnlng Laaaz For wrmes) (Dale) —'--TSagnat'.1 nd.;NJu IFo �,r�qTai;T TO' Wages) ([,late) ts 10 1 at., ro, Wages) (Date) ,�Z, i, 7Pe BE SURE TO COMPLETE OTHER SIDE LJ CONDITIONAL WAIVER AND RELEASE UPON (California Civilt.6de §3262(d)(1)) 4r ,a i!. Upon receipt bey ^the�un/de signed of a check from 1 yy�� yy�� nt in the sum ofd payable to G,�AGD C.rG['V k cA G1 (Amount of Checki (Payee or Payees of Check, and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to reell�ea a pro tan o. % mechani s len top notice or bond right the undersigned has o the job of CJ ?4~ .4/7 (Owner) located at (Job Description) to the following extent. %6 �?' it). b-74S This release covers a prog�rj ss pa ment for labor, services, equipment or material furnished to C3'�CLG tJ' 6!) d<'C'X Lr - through ` 1_e (Your Customer) (Date, only and does not cover any retention or items furnished after said date. Before any recipient of this document relies on it, said party should verify evidence of aymmeAn't to the ®undersigne . Dated: !� 6 �V 001, �a � (Co ny Nam By al Tt1e) �vxrti� For so much; for as much as may be; as far as it goes. NOTE: This form of release complies with the requirements of Civil Code Section 3262(dxl). it is to be used by a party who applies for a progress payment when the progress payment check has not yet cleared the bank. This release only becomes effective when the check, properly endorsed, has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WOLCOTTS FORM 3262. 1— CONDITIONAL WAIVER AND RELEASE UPON PROGRESS PAYMENT —Rev 485 C 1985 WOLCOTTS. INC. (price Class 7 2) THE UNDff DESIGNED HAVE PERMED LABOR FOR WAGES ON THE PROJIO DESCRIBED ON FACE OF FORA AND HAVE BEEN PAID IN FULL TO DATE l (' PBrlanlwig Labor For Wages) (Oaea) (Sg-ao" Of Wdmd of PwOmm Labor ry Wages) (Date) (3'9aa 0fkliiJvW6 F8r$— "LaborF«Wagae) (DMe) (Signature 0I Wtdvidual Padorrrung Labor Far Wages) (Date) (Signature Of InOvldual.PerMMWV Labor For Wages) — toot,) (Signature 01 hidnduaf Perforating Labor For Wages) (Date) (Signature Of tndmn" Perfonni g Labor For Wages) (Date) (Signatore(>IlndvMual PerfWTOg Labs For Wages)" . (Date) SSgnatwe01 lMrv3dual Performing Labor For Wages) (Date) (Signature Of Lrdrvidual Performing Labor For Wages) (Date) (SgroWre Of Wideadual Perfarmrtg Labor For Wag") (Date) (Signature Of Individual Performing Labor For Wages) (Date) (Svptabae Of Individual PeAptnng Labor For Wages) (Date) (Signature ot fndvo" Pertornwrg Labor For Wage) (Date) (S"twe Of kxkvidral Performing Labor For Wages) (Date) (Signature Of lndrMual Performing Labor For Wages) (Date) (Signature Of Intandual Pedormng Labor For Wages) (Date) (Signature Of lndrvidlal Performing Labor For Wages)' (Date) (Signature Of Irividual Performing Labor For Wages) (Date) ( Signature Of Mclivrdual Per#xmmg Labor For Wages) (Date) (Signature Of Individual Performing Labor For Wages) (Date) (Signature Ol inarvidual Performing Labor For Wages) {Cate) BE SURE TO COMPLETE OTHER SIDE 11 0 CONDITIONAL WAIVER AND RELEASE UPON FI PAYMENT Upon receipt by the undersigned of a check Y ww- 4,110.00 (FOUR THOUSAND. ONE HUNDRED AND TEN) in the sum of $ payable to (Amount of Check) 6 GLU -LAM SALES CO., INC /GRACO CONSTRUCTION CO. and when the check has been (Payee or Payees of Check) properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice, or bond right the undersigned has on the job of CITY OF NEWPORT BEACH located at (Owner) CHANNEL PLACE PARK, CHANNEL PLACE, NEWPORT BEACH, CALIFORNIA (Job Description) This release covers the final payment to the undersigned for all labor, services, equipment or material furnished on the job, except for disputed claims for additional work in the amount of $ NONE Before any recipient of this document relies on it, the party should verity evidence of payment to the undersigned. Dated: JUNE 5. 1989 eu ra+w"(REV. 1-06) GLU -L (Company Name) By (Title) TIER 0 0 CONDITIONAL WAIVER AND RELEASE UPON FINAL [California Civil Code §3262(d((3)] y 4 own- Ekff. 7. L! � Upon receipt by the undersigned of a check from City of Nera�ort Beads o- nq {Maher of Check) in the sum of $ 6,553.00 payable to A & C Electric (Amount of Check) {Payee or Payees of CnecN and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice, or bond right the undersigned has on the job of City of Newport Beach {owned located at C hanrnl Place Park, 9398 Qlamel Place, Newport Beads, CA {Job Desuip)ion) This release covers the final payment to the undersigned for all labor, services, equipment or material furnished on the job, except for disputed claims for additional work in the amount of $ . Before any recipient of this document reties on it, the party should verify evidence of payment to the undersigned. 7 ..., Dated: June 5, 1989 A CC Electric 0 Mile) NOTE: This form of release complies with the requirements of Civil Code Section 3262(d)(3). It is not effective until the check that constitutes final payment has been properly endorsed, and has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WOLCOTTS FORM 32623— CONDITIO NAL WAIVER AND RELEASE UPON FINAL PAYMENT —Rev 1 85 IP,,Ce Class 7 $I —C 1985WOLCOITS INC THEEpU�RDESIGNED HAVE PERMED LABOR FOR WAGES ON THE PROAS DESCRIBED ON FACE OF FORM 03t133N AND HAVE BEEN PAID IN FULL TO DATE IN � I rti�g r�o kwb" ai Perbrtrwtg Labor Fw wages) Palo) (S e Of ki5mWal Parlonmrg tabor Far Wages) (Date) (Sigrawm of kdivfdusl PnAdnig tabor FOr Wajea) (Date) .� (Sgnabse a ktdvi" Pe W-V tabor Fn Wages) JLL�IDate) �(^ylpaNre 01 tn&"duat PWfonn'eg Labor FIX Wages) (Rate) (Sgvature Of Individuai Partonnkg Labor For Wages) Pale) _..v._ (S,"tuxe Of Wfvdual Palo"" Labor For Wages) (Date) (SgnaNre Ol Uchvdual PerfMrrtg Labs FOr Wages) V� (Date)�� (Sigru,use0fkdrvi lPerarming Labor For Wages) (Date) (Signature Of indrodual ParformiN Labor For Wages) (Date) ISaymhov 01 lydividual Pedormurg Labor Fa Wages) (Date/ {Signature Ot 1Mivdual Perormng Labor For Wages) (Date) (Sgnahse d irdivdual Perorming Labor For Wages! (Date) (5 case Of kdividW Performing Labor For Wages) (Date) (S ""a Of froydual Perfonrrcg La For Wages) (Date) (Signature OI lrekvdual Podorming Labor For Wages) V (Date) (Signature a Indivduel Palo rN Labor For Wages) (Date) (Sgnature OflMwidual Perorming Lat»r For Wages) (Date) i89namre 011Mividual Pgdarmmg Labor Fa Wages) Owe) (Synature 01 Ind,wtual Perlomeg Labs For Wages) (Date) twatweOl lnd+v"l Part ng Labor For Wages) (Date) (SSa a Of brdriduai Pedarmrg labor For Wages) �toale) BE SURE TO COMPLETE OTHER SIDE Wpeand lWadoweg, vile. 809 N. TURNER AVENUE ONTARIO, CALIFORNIA 91761 (714) 987 -2868 quo CONDITIONAL WAIVER AND RELEASE UPON FINAL PAYMENT 7 r Cc' -.s-47 Upon receipt by the undersigned of a check from CTTV OF NEWPORT BEACH in the sum of 37,220.00 payable to UPLAND MASONRY, INC., and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release protanto, and mechanic's lien, stop notice or bond rights the undersigned has on the job of CHANNEL PARK PLACE located at 4400 River Ave., Newport Beach, CA , to the following extent. This release covers a final payment for the labor, services, equipment or material furnished to City Of Newport Beacl through June 5, 1989, BYaP1 PRESIDENT UPLAND MASONRY, INC. 9 - 2_x'1 CONDITIONAL WAIVER AND RELEASE UPON FINAL PAYMENT [California Civil Code 13262(d)(3)1 Upon receipt by the undersigned of a check from r /L�, � In the sum of �'� payable to ��,FeD P_o✓s �. ,Je r}✓aQ 04 1 ne.✓ p /M6 ✓c 1 Nn' o cMe[q a47rr D, igen of CMCU and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release any mechanic's lien, stop notice, or bond right the undersigned has on the job of C� e � / f located at 2 is /o 0 W7 s .¢ I r ✓✓t / �A �z {lot orsmvi*h) This release covers the final payment to the undersigned for all labor, services, equipment or material furnished on the jbb, except for disputed claims for additional work in the amount of $ Before any recipient of this document relies on It, the party should verify evidence of payment to the undersigned. /J Dated: _ — 2 2� Q% L c�a < (�li �_ > {Canprr.i Mar* By - (TtlN!) NOTE This form of release complies with the requirements of Civil Code Section 3262(4)(3). It Is not effective until the check that constitutes final payment has been properly endorsed, and has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WDLC0r757DR11 8673— CONDITIDMAL WU.rERAMD RELEASE UNN MALWUEMt —Ekr 1-85 Cwswo:corrs WC Epst twis 7.21 y1 - ZG6 y t � CONDITIONAL WAIVER AND RELEASE UP PA S MENT [California Civil Code §3262[d[(t)) Upon receipt by the undersigned of a check from in the sum of $ S YOo -- payable to i11K557 !/W.OIAT. 4 X4,as" Ys,2 (Amount of Check) (Payee or Payees of Check) and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release pro tanto' any mechanic's lien, stop notice or bond right the undersigned has on the job of located at L 14-%4JvN.E c-6 PL '&& 1WR7e;Jt to the following extent. (Job Description) This release covers a progress payment for labor, services, equipment or material furnished to 64ae0 Co tls-;, , through 6 ,Z - X_q (Your Customer) (Dale) only and does not cover any retention or items furnished after said date. Before any recipient of this document relies on it, said party should verify evidence of payment to the undersigned. - Dated: AI*!s #V? ICompanY c y '\ By /p ✓ V - J (Title) For so much; for as much as may be; as far as it goes. NOTE: This form of release complies with the requirements of Civil Code Section 3262(d)(1). It is to be used by a party who applies for a progress payment when the progress payment check has not yet cleared the bank. This release only becomes effective when the check, properly endorsed, has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WOLCOTTS FORM 3262.1 — CONDITIONAL WAIVER AND RELEASE UPON PROGRESS PAYMENT —Rev. 185 ©1985 WOLCOTTS. INC. links class 7 2) THE UNDEROESIGNED HAVE PEROMED LABOR FOR WAGES ON THE PROJD DESCRIBED ON FACE OF FORM T _ AND HAVE BEEN PAID IN FULL TO DATE Q3`yS g off " ':'r (SgnaaaeIXYdrnOrel Palwn�ry" ) made) (SiptaaaeIX k16vidual Perform" labor FVr Wages) (Date) INA Y,. (SigsaaeOf Individual Palo"" labor For Wages) (Date) Migiraiee IX FdvidW Perfam" tabor FrIr Wages) (Date) (Signature Of Individual PMo "" Labor For Wages) (Date) ,(Signature Of hdividual Per homang Labor For Wages) (Date) (Signature Of adividtal Pedonneg Labor For Wages) (Date) (Signature Of Individual Pertormng Labor For Wages) (Date) (Signature Of Individual Performing Labor For Wages) (Date) (Signature Of Individual Performing Labor For Wages) (Dare) (Signature Of Individual Performing labor For Wages) (Date) (Signature 0 Individual Perforating Labor For Wages) (Date) (Signature Of Individual Periorrnarg labor For Wages) (Date) (Signature IX Individual Petlomrvrg Labor For Wages) (Date) (Signature IX Individual Pefoming Labor For Wages) (Date) (Signature Of Individual Perfomrg Labor For Wages) (Date) (Signature IX Individual Perlommung Labor For Wages) (Date) (Signature Of Individual Perlonnirg Labor For Wages) (Date) (Signature Of individual Performing Labor For Wages) (Date) (Signature a intlrvduai Performing Labor For Wages) (Dale) (Signature a Individual Performing Labor For Wages) (Date) (Sgrabxe (Y Individual Performing Labor For Wages) (Date) BE SURE TO COMPLETE OTHER SIDE 0 CONDITIONAL WAIVER AND RELEASE UPON [California CIO Code §3262(d)(1)f L2- z66y 5m 7 /1� ENT Upon receipt by the undersigned of a check from &1rr I' n�� � a er of CN k in the sum of $� Q_ payable to t7HYV�id%r5 # UL .Ul; � aac> 0 (Amount d CNeck) (Payee of Payees of Check) and when the check has been properly endorsed and has been paid by the bank upon which it is drawn, this document shall become effective to release pro tanto' any mechanic's lien, stop notice or bond right the undersigned has on the job of -CeZ, A�Ak A %CF 9/7VI(_1 (Owner) yT —' located at 4yc/)o z /U Z✓ 0 f%` to the following extent. This release covers a progress payment for labor, services, equipment or material furnished to 6 ;C� �IJA%ST.�°l�G /OTC/ through 2 d� (Your Customer) (Dale) only and does not cover any retention or items furnished after said date. Before any recipient of this document elies on it, said party should verify evidence of p yment to the unders' ed. Dated: 2 (DOm n Name) By (rue) 'For so much; for as much as may be; as far as it goes. NOTE: This form of release complies with the requirements of Civil Code Section 3262(d)(1). It is to be used by a party who applies for a progress payment when the progress payment check has not yet cleared the bank. This release only becomes effective when the check, properly endorsed, has cleared the bank. USE REVERSE SIDE AS RELEASE FOR INDIVIDUALS PERFORMING LABOR FOR WAGES WDLCOTTS FORM 3262.1 — CONDITIONAL WAIVER AND RELEASE UPON PROGRESS PAYMENT —Rev. 1 -85 ©1985 WOLCOTTS. INC. (price class 7 2) THE UNDERDESIGNED HIJE PERMED LABOR FOR WAGES ON THE PROJI10DESCRIBED ON FACE OF FORM ti M yio AND HAVE BEEN PAID IN FULL TO DATE Z MV,ftse0l YrdvA* FvWages) (base). .(Sow.ft" Of lrtdM" Perbmug Labor For wages) (Date) NOW ( Signals" Df Indmkitial PallommiIg Labor For Wages) (Date) (Sgraare OfaldsidW PorAxrtxg tabor For wages) fbatu) ( Signature Of tndvidual Pertomtetg Labor Fd Wages) (Date) (Signature Of Inclmdual Padanvg Labor For Wages) (Date) (Signature Of kldvrdual Perfannog Labor For Wages) (Date) (Signature Of Individual Pedonnrg Labor For Wages) (Date) (Signature Of kndnMngl Palaming Labor For Wages) " (Date) (Signature Of Individual PetormN Labor For Wages) (Date) (Signahue OI Indmdual Pedomting Labor For Wages) (Date) (Signature Dl Individual Pafonong Labor For Wages) (Date) (Signature Of edividial Performing Labor For wages) (Date) (Squ a Of ardividaat Perlo -ang Labor For Wages) (Date) (Signature Of kndnidal Perfuming g Labor For Wages) (Date) (Sgnahae Of Indvidual Pedam.g Labor For Wages) (Date) (Signature Of Individual Perbrmirtg Labor For Wages) (Date) (Signature OI IMn10ual Pedouring Labor For Wages) (Date) (Signature Of Individual Perlorming tabor For Wages) (Date) (Sgrtafure Of Individual PerfomYrg Labor For Wages) - (Date) (Signature Of Individual Perfor n ng Labor For Wages) (Date) (Signature 01 Individual Perorreing Labor For Wages) (Date) BE SURE TO COMPLETE OTHER SIDE STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS too CT ski it City Of Newport Beach 3300 Newport, Newport owner, construction lender public officer) 92663 HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, Quick Crete Products Corporation -P.O. Box 639 Norco CA 91760 (Name and address) has furnished or has agreed to furnish CONCRETE SITE FURNISHINGS (labor, services, equipment, materials) of the following kind 2 QTY' QCPS -7 CONCRETE PICNIC TABLE SETS (general description of labor, services, equipment or materials) to or for GRACO CONSTRUCTION , for the work improvement, located at, or known as: CHANNEL PARK am- a4Re9rs8n CHANINEL (PLACE /PARK, NEWPORT BEACH, CA 92663 (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 1172.36 The amount in value of that already done or furnished by claimant is Claimant has been paid the sum of $ NONE and there remains due and unpaid the sum of $ 1172.36 24 APRIL 17 89 plus interest thereon at the rate of per cent per annum from 19 —. YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. MAY 12, 1989 QUICK CRETE PRODUCTS CORP. STATE OF CALIFORNIA COUNTY OF ss. D+za -t�Ge 1 Name of Claimant P.O. BOX 639, NORCO, CA 91760 Address of imant ps 1 aCr t �I �d r3 er C any.. ,.. lt�•.... eL_L.3.� �/ /� c. _... L-; t 5 L; � dJ � :_;�ji�j7 Cw' eiL, Jo /Shiro L- reoo k _ , being duly sworn, deposes and says: That the is the person(s) who signed the foregoing Stop Notice; that the has read the same and knows the contents thereof to be true of h&=s--own knowledge, except as to any matters or things that may therein be stated on has information and belief and as to those matters and things ?he believes them to be true. OFFICIAL SEAL Subscribed and sworn to before me DONNAL PAIfERSON �a M 9 Nor acol "NN this day of 'Ly 19 atycmm. fapinxyli3,tia3 Notary Public and in and for said State This .tmda,d form coven watt usaal pamlemt In We field ludk:.ted. Eefove ym aiv read ft, fill in .6 hl.nka, STOP NOTICE and make changes pop" W yu r trw.cdm. Co ult .lawyer if you dmbt the forms fimen for your aMrpeae. WOLCOTTS FORM Bit —Rgv. 2.73 (pricocla,53) 6 O Z 1 z w o in Y w ¢ d v rn O i iw- 2 C N U r- p 1 I u d w O 1 1 Z w d 1 1 1 q 1 j O O O 1 1 N 1 u W L u 1 w d 1 fJ A Iy I IL b 1 q N 1 iw C y 1 I q 1 N 1 y 1 1 d 1 d I w I■ 1 p N_ q 10 tll N VI q I N Vi o w I n I 1 _Ivy IN�,w 1 d 1 VVVVVVI O'1 d w IC 1 IL � M I w I A 1^ N d ti w�yla w a 7 �1 , � O d d 16M C 6 O Z 1 z w o in Y w ¢ d v rn O i iw- 2 C N U r- IST Tvn—r�— -Vyjo k- ;Pursuant W ':'ornia CA 'w-,, (-do Section 31811 10 le 61 PC off`.* :� 11, �Isbursing officer or controUer,-,rlaody wnO 'n ,he cole%at: Y Alec 4�24 3egel, , C&&X, 9;�* .a vicar, etsy cov., ty-.-z -t sea, etc., an ae.d-ress TT TFTED that — �s 16T, C) � A'?__ 77 Er ?y *, ` name, -address of --ergon-' C C;`Q6 7f has furnished meat or ?xaten 2 _e t .nt,or, n, ^-s, . r1syne of contractor for a work of improvement on the prem-,--,es located at OAANW- -Plece OfiWe- street ad.�xdsf-, or F X13 X18' C�AAIIVEC descrintion 'he value of t'-e labor, services, equipment or materia! `•:: -fished is the value of the whole agr4ed to ',e fiurni*shed is 9 and there re=-qjms c._+.e and owing .he a m ou 7, t S ?0 plus interest at the rate of Y Percent from TO'h -,-count became qr•err. DEMA7D IS 71-7�77'Z MADE Tn. 77777�-7--nl D �,,T T7 - T 7 TPT*7'. �D�7, TO I . 71C.7-12N T - IN MTS777 771S CLAI-MIWITT-T I -N-T,7,E 77' 77 3T. =21 in �7, cc -S 2 5 m, 6j .6 '=S!L, Pr Q/ ON 013000 T, -=d-ers*,-.med, say: '- I rtm the— (1C1)/VCVZ- ane or other caym^ V claim&r.° -' 11-,e fornerc.` 7 NoF• - have roc 7aie. claim or Stop -T\Tot,.--e anc' know t:ae cortents t'-1a same is true 0: -7 , -m �--Y Ory'r—' 071riedge. - nem!'jty 04 it r regrc.�,,-- Z, APE' TAT r, at California. A e pacity (owner, partner) yms. NOTICE TO Stop Notice City of Newport Beach (Name of Public Body or Lender) 3300 Newport Beach, Newport Beach, CA 92263 (Address) Cootoc( IGG 4 (If Public Job — file with office of controller, auditor, or other public disbursing officer whose duty it is to make payments under provisions of the contract.) (If Private Job — file with responsible officer or person at office or branch of construction lender administering the construction funds.) — Prime Contractor. Graco Construction Sub Contractor (I f Any) Upland Masonr Owner or Public Body: Improvement known Inc. ofprojecl or Beach in the City of Newport Beach County of Orange State of California. United Premix Concrete, Inc. claimant, corporation (claimant) (CorporationjPartnership /Sole Proprietorship) furnished certain labor, service, equipment or materials used in the above described work of improvement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment or materials is Upland Maanurg, Tnr (Name of Subcontractor /Contractor /Owner - Builder) The kind of labor, service, equipment or materials furnished or agreed to be furnished by claimant was ready mixed concrete /related items (describe in detail) Total value of labor, service, equipment or materials agreed to be furnished .............$ 1.894.78 Total value of labor, service, equipment or materials actually furnished is ...............$ 1.894.78 Credit for materials returned, if any ................ ..............................$ –0– –0– Amount paid on account, if any .................... ..............................$ Amount due after deducting all just credits and offsets . ..............................S 1,894.78 YOU ARE HEREBY NOTIFIED to withhold sufficient monies held by you on the above described project to satisfy claimant's demand in the amount of $ 2.368.48 as provided in Sections 3156 through 3214 of the Civil Code, and in addition thereto sums sufficient to cover interest, court costs and reasonable costs of litigation, as provided by law. A bond i s not attached. (Bond required on private jobs— not on public jobs.) (is /is not) C"' S ❑ iAaye.r uncilmen United Premix Concrete, Inc. Name of Claimant L'3 a aloger ; N e) n�,t:sney By [3'rrtg. Dir. I Dif Credit Mgr. 0 1:= $, i Dir. (DjTcialCapacity) ® Planning Dir. ❑ LDCG chief VERIFICATION (ffpA Dir Credit Manager 01Oihef 1, the undersigned, state: I am the ( "agent of f' f' "president o "a partner o "owner of etc.) the claiAant named in the foregoing Stop Notice; I have read said claim of Stop Notice and know the contents thereof, and I certify that the same is true of my own knowledge. 1 certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed on 12/17/88 California. e._,fXA FORM (REV. 3 -83) eM 19_,at Irwindale (Signature of Claimant or Authorized Agent) • a lei 13 C - ZEES STOP NOTICE RECEIVED NOTICE TO WITHHOLD TO HOLDER OF FUNDS A I is an Tn. .City of Newport Beach (Name of owner, construction lender or public officer) 3300 Newport Blvd., Newport Beach, Calif. 92663 HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, Martin G. Eckmann /General Contractor P.O. Box 2852 Costa Mesa, Ca. (Name and address) 92628 has furnished or has agreed to furnish labor and materials (labor, services, equipment, materials) of the following kind for rough electrical installation and underground plumbing. (general description of labor, services, equipment or materials) to or for Graco Construction Corporation for the work improvement, located at, or known as: (name of person to or for whom furnished) Channel Place Park 4398 Channel Place, Newport Beach, Calif. (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 36,770.20 60% electrical $ 6,755.70 The amount in value of that already done or furnished by claimant is $ 40% plumbing S 7,496.20 Claimant has been paid the sum of $ • 00 and there remains due and unpaid the sum of $ 14 , 251 . 90 plus interest thereon at the rate of per cent per annum from October 10, 19BB 19� YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: December 19, 1988 STATE OF CALIFS IA / } ss. COUNTY OF 11) 0 Martin G. Eckmann /General Contractor Name of Claimant P.O. Box 2852 Costa Mesa, Calif. 92628 Address of Claimant 00 m p 5 V�N) i d x „/ ( �C�C ri m _, being duly sworn, deposes and says: That _he is the persolds) who signed the foregoing Stop Notice; that _he has read the same and knows the contents thereof to be true of hLS_ own knowledge, except as to any matters or things that may therein be stated on h-LL. information and belief and as to those matters and things —he believes them to be true. Subscribed and sworn to before me 192_'2' M J L UFORNIA TY . 19, 1991 This studerd form coven mat aural problem, to the Sekr brdleated. Defoe yon s read k an In an bten6. STOP NOTICE and make cbaa11N proper m ram tli➢/actlan. Con ult alawyer if you dmbt fbe forma tlmen fm y r tmgyaa. WOLCOTTS FORM 1194 —Ray. 3 -73 (prke GNe3) V R C- Z6� U PUULIC k':'" S RE�E'� STOP NOTICE Z MAR 0 31989 •`: °" NOTICE TO WITHHOLD TO HOLDER OF FUNDS tip. r0: �i� 1 ar �/tLVp .� QCrhCi� P4'r (Name of owner, construction lender or public officer) -3390 C� q a 6 G'--) , HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, <�r. &R -A r.t-r L `,15 LahS`;G--?'J (4 �f 7oS (Name and address) has furnished or has agreed to furnish I d ho r , (labor, services, equipment, materials) of the following kind -(ate fy ✓�G f F ve (general description of labdr, services, equipment or materials) to or for &rmi i (2 eA n G¢) T`rSTCUCTei t� for the work improvement, located at, or known as: (name of person to or for whom furnished) ��>> C1ri ,,., -I P1 r.� Rorr N�'-Wr")CT U is3CG¢ Cii description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 3200 -2 The amount in value of that already done or furnished by claimant is $�� Claimant has been paid the sum of $ and there remains due and unpaid the sum of $ plus interest thereon at the rate of15per cent per annum from 0C;Tz ° -- I C11- 199s, . YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: De-c, 17, 1g1 n STATE OF CALIFORNIA COUNTY OF (jRA AXIS t� ss. V<C' 6.1 . CS'C'A N r Name of Claimant r t�.r[� -`-d jl�,vtYa- Address of C aimant a > n 4) O ci 1 `� �. rp 'J CIS ,von 1(_71:.. Ci cr G1.. CJ /Z®wa(d . C. /3ra�n/-f:v °L�c�ccclL�i ,being duly sworn, deposes and says: That —he is the person(e) who signed the foregoing Stop Notice; that =he has read the same and knows the contents thereof to be true of hli own knowledge, except as to any matters or things that 19aynstated on h� information and belief and as to those matters and things =-he believes them to be tru . —7� // J� Subscribed and sworn to before me this day of d—'>,l , 19 Nolary Public-and in and for said State Q..N /L(.C—All, OFFICIAL SEAL D R MILLER NOTARY PUBLIC - CALIFORNIA ORANGE COUNTY AM Comm. expires OCT 14, 1989 `�y7oS Tbk standard foam eovesa mat usual Problems to tee Sold hullkata& Before 7ou . teal 4 9B in an bt.a,, STOP NOTICE and make champ paper m year transaction. Convutt a IawYer 9 you doubt tee f i imat for Your psapaa. WOLCOTTS FORM SS�ay. Y•7M (nricecess3) i STOP NOTICE Public Works To City of Newport Beach, Attention: Wanda E. Ra, • RECEIVED io, City Cie NAYp �,ry;,1� 0 3300 Newport Blvd., Newport Beach, CA 92663 1NN ,- YOU ARE HEREBY NOTIFIED that the undersigned claimant, s Terry Lumber Co. of Glendale furnished lumber and building materials to .Greco Construction pursuant to that certain contract made between Graco Construction and Terry Lumber Co. of Glendale for that certain public work of improvement consisting of the construction at 4398 Channel PI., Newport Beach, CA 92663 and which is and was the whole of said materials agreed to be furnished by claimant; The contract price of said materials was and is the sum of $ 6.665.62 , and said sum was and is the reasonable value thereof; nothing has been paid or credited on said amount; and there is now due and owing to claimant, for and on account hereof, the sum of $6,665.62 in lawful money of the United States, after deducting all just credits and offsets, and the same has not been paid. WHEREFORE, the undersigned claims and benefit of the law given to laborers, materialmen and others under and by virtue of the provisions of Division.3, Title 15, Section 3103 and Sections 3181 and 3214 of the Civil Code of the State of California, and prays that you withhold from said original contractor, Graco Construction sufficient money that may be due it or that may become d'ue it for said work to answer and pay the amount of this claim, to wit, $ 6,665.62 Dated: May 2, 1989 `F w G _5Z c > �•�, u�tl�Cr. ij �;CtAJY CTC 4'% CUB , Ctl C4 ❑ ❑P ®bert Terry Lumber Co. of Glendale VERIFICATION declare that I am the Vice PrPCidPnt Finance of Terry Lumber Co. of Glendale , the claimant named in the foregoing claim, and am authorized to make this verification for and on behalf of said claimant, and I make this verification for that reason. I have read said claim and know the contents thereof and the same is true and contains among other things, a correct statement of claimant's demands after deducting all just credits and offsets. I declare under penalty of perjury that the foregoing is true. Executed on May 2, 1989 —at/ Tarzanap California A G OSRSr�o STOP NOTICE ✓RECEIVED NOTICE TO WITHHOLD i0 HOLDER Of FUNDS = MAY 1 1989 H aF City of Newport Beach Public Works Dept. (Name of owner, construction lender or public officer) P.O. BOX 1768 Newport Beach, CA 92658 -8915 , HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, Far West Specialties 2950 W. Central #6 Santa Ana, CA 92704 (Name and address) has furnished or has agreed to furnish Labor (labor, services, equipment, materials) of the following kind Toilet Compartments & Accessories (general description of labor, services, equipment or materials) to or for Graco Construction for the work improvement, located at, or known as: (name of person to or for whom furnished) Channel Place Park 4400 River Ave. Newport Beach (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 3,950.00.. The amount in value of that already done or furnished by claimant is $ 3,950.00 Claimant has been paid the sum of $ —0— , and there remains due and unpaid the sum of plus interest thereon at the rate of 6 per cent per annum 3,950.00 19_E _9. YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: April 26, 1989 STATE OF CALIFORNIA COUNTY DF Orange ss. William C. Kermode, Jr. Name of Claimant 2950 W Central 46 Santa Ana C.A 92704 Address.of Claimant . Q\ 00 {� 2 G r sii i d'LSJiiCI'L "1�i1 William C. Kermode , Jr. , being duly sworn, deposes and says: That _he is the person(s) who signed the foregoing Stop Notice; that _he has read the same and knows the contents thereof to be true of his own knowledge, except as to any matters or things that may therein be stated on h_i.s informs . and belief and as to those matters and things _he believes them to be true. Subscribed and sworn to before me thi day of 19 89- OFFICIAL SEAL PHYLLIS ANN PALMER m NOTARY PUBLIC • CALIFORNIA lotary nand in and r said State My comm aaplres DEC 10, 1990 7116 standard foam coven mast umd Dmb6me to She lord IndleNed. Halos 1w el{e( and R an to an hLnfa, STOP NOTICE and ate ehwan ym➢es to ywa tsaneaetfon. Comelt a lawym if yw dwbt the fmm a Moen im Yom 3mspeee. WOLCOTTS PORM 994 Rev. 2.71 (prim cW53) FAR WEST SPECIAMMES 295i W. caww- faaft Aa& Ch 93704 (714) 341-0101 SOLD TO: SO Greco Construction Corn. 10525 Foothill Blvd. Rancho Cucamonqzi,. CA 141730 Taru 2/28/8.9 SHIPPED TO: 10 oe. #w SOLD TOP t-%ak: Channel. Place Psrk 0 M ION Wsh, 54 THE BUSINESS BOOK, 03h WI 906 ORREORDER CALL, 1-800668 4)220 ------------- - SmOsm MILE, 4 o z5 o setri r-1-s 'lm i I t Po r r iL Y, icms & I, o4:, a L�c`irS. d4 dI% 11,C)i 1('t Ti Di MQ11 Siqj1 Total Amount due $3,950.00 0 M ION Wsh, 54 THE BUSINESS BOOK, 03h WI 906 ORREORDER CALL, 1-800668 4)220 ------------- - STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS TO: /T `v' OF W6&0POrzz� 6 �A C H (Name of owner, construction lender or public officer) 3 3 00 N6w PJ ei 33taA/ NE 1A) ?00== aF lende If (A 9 2 6 6 3 HOLDER OF FUNDS. (Address of owner or construction r) ' YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, G-3 (Name and address) has furnished or has agreed to furnish (A 3 u2 4,4 D i l/fa 7—E 2 4 c S (labor, services, equipment, materials) of the following description of labor, services, equipment or materials) W to or for Lj 2 A c o C'O N 5 7-4u e -r/ 0 N for the work improvement, located at, or known as: (name of person to or for whom furnished) ' 926ZL C0RNNiL PLAtX_ PaeK PZt')0VA',0A)r CON — ipgCT4d'266y, 11 40 o 2r ✓e2 Aar, AlewPv? -.7 ee"cr'� (address, legal description, description of site or project identification) C,o, The amount in value of the whole agreed to be done or furnished by claimant is $ / `/, 660. O D The amount in value of that already done or furnished by claimant is $ a o DO 00 Claimant has been paid the sum of $ and there remains due and unpaid the sum of $ `jr U 00, 0 , plus interest thereon at the rate of per cent per annum from 19 —. YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. 4/�2(' B STATE OF CALIFORNIA COUNTY OF (09,4,v (09,4,v Ss. C?Z ) and says: That _he is the person(s) who signed the foregoing S to be true of h i3 own knowledge, except as to any matters or as to those matters and things —he believes them to be true. CA.e� r, Mmo� ,��A (bH17vi�w P�c,HQ,ay Name of Claimant 23 bluo Kvr Address of Claimant Gg-'iES uENTTO p Mayor R Councilmen dManae(jer zi�A­arney a Bldg. Dir. ❑ (:ertSery Dir. OF`u &RMr. 0 Planning Dir. being duly sworn, deposes has read the same and knows the contents thereof n be stated on It information and belief and A %'�Y �LC Subscribed and sworn to before me t .s_day OFF:KOOYUmjlAN 70OUIM.1 NOTARY NOTARY Nq ar is andAe a d for said State OIV MN oom z nh standard fmm tovm mat usual psnblems m We field tndkmmL Befom = afget rod R fin In an btankh STOP NOTICE and make changes Wopes m your tranuctien. Consult •lawyer if you doubt the forms fitness for Your purport. WOLCOTTG FORM 094 —RSV. 2.73 (prke Class3) STOP NOTICE a, RECEIVED NOTICE TO WITHHOLD TO HOLDER OF FUNDS APR 24 � CITY OF NEWPORT BEACH (Name of owner, construction lender or public officer) 3300 NEWPORT BL`,'D. NEWPORT BEACH, CA. 92663 HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, T:I.OYD L. BEAMAN P.O.BOX664 ARTESIA, CA. 90701 (Name and address) has furnished or has agreed to furnish CONCRFTF PUMPING (labor, services, equipment, materials) of the following kind CONCRETE PUMP & OPERATOR (general description of labor, services, equipment or materials) to or for GRACO CONSTRUCTION CORPORATION for the work improvement, located at, or known as: (name of person to or for whom furnished) 45th & RIVER, NEWPORT BEACH, CA. (CHANNEL PLACE PARK) (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 71 6.38 The amount in value of that already done or furnished by claimant is $ 71 6.38 Claimant has been paid the sum of $ —0— , and there remains due and unpaid the sum of $ 71 F _ 38 plus interest thereon at the rate of per cent per annum from DECEMBER 1 19 88 YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. STATE OF CALIFORNIA COUNTY OF Ios Angeles ss. TTOYT T. RPAMAN Name of Claimant P.O. BOX 664 ARTESIA, CA. 90701 Address of Claim ant y . a3 r- �V S O E COW 0 cn v rn N co ...: vcLl GG a. i.. O. 'n: th Lloyd L. Beaman , being duly sworn, deposes and says: That _he is the person(II who signed the foregoing Stop Notice; that _he has read the same and knows the contents thereof to be true of hir, own knowledge, except as to any matters or things that may therein be stated on hit,- information and belief and as to those matters and things —Ile believes them to be true. Subscribed and sworn to before me this 19th day of April 19 89 FICTAL SEAL ONNE YRINEO Yvonne Yrineo California [974MV PUSUC - CAl ' OBNIA Nota Public and in and for said State S ANGELES WUNTY 7 ,. expires OCT 16, 1492 I This standard form ouvers mat pad problama as the field Indicated. Devon DTOF NOTICE and make chamas paper a your transaction. Consult a lavryer if you donbt folrm a fiiaas for rD hears u WOLCOTTD FOAM 1111104—Nay. 2.73 Wicecluea) STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS CITY OF NEWPORT BEACH (Name of owner, construction lender or public officer) 3300 NEWPORT, NEWPORT BEACH, CA 92663 (Address of owner or construction lender) HOLDER OF FUNDS. YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, GRACO CONSTRUCTION — 10535 FOOTHILL BLVD. SUITE 230, RANCHO CUCAMONGA, CA 91730 (Name and address) has furnished or has agreed to furnish CONCRETE SITE FURNISHINGS (labor, services, equipment, materials) of the following kind 2 QTY QCPS -7 CONCRETE PICNIC TABLE SETS , (general description of labor, services, equipment or materials) to or for CITY OF NEWPORT BEACH , for the work improvement, located at, or known as: (name of person to or for whom furnished) CHANNEL PARK — 4398 CHANNEL PLACE /PARK, NEWPORT BEACH, CA 92663 (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 1172,36 The amount in value of that already done or furnished by claimant is Claimant has been paid the sum of $ NONE and there remains due and unpaid the sum of $1172.36 24 APRIL 17 89 plus interest thereon at the rate of per cent per annum from 19 —. YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. PRIL 19, 1989 QUICK CRETE PRODUCTS CORP. Name of Claimant P "0. BOX 639, NORCO, CA 91760 Address of Claimant sx O `'t STATE OF CALIFORNIA t� d is 4 Q,•,i COUNTY OF O�°g/✓CxFt ss. � E c n c ID C3 acs❑ ❑mbi ❑ ❑❑❑oy�T :1001,'7 '` ; 1,1;'S., ttiIC's C'_t.;TE 111'OX t3 CCaP_, being duly sworn, deposes and says: That She is the persoMs) who signed the foregoing Stop Notice; that -he has read the same and knows the contents thereof to be true of IT er own knowledge, except as to any matters or things that may therein be stated on IT er information and belief and as to those matters and things —she believes them to be true. tit +7? .D11C t': (,Xii '. Subscribed and sworn to before me this Otrr day of .4 +,.11_ , 19-8-9L. OFFICIALS- - �� IQ PATYPUBUCSULLJFOR NOTARY PUBLIC - GIFOaNA ORANGE COUNTY Notary Public and in and for said State sb conun, Ewo-,s TC�, v. Taal nh standard Form coven mart u,uaa probtarm, in the geld Indicated. Befom yoo ,tp, read R 9a In an blao6, STOP NOTICE and make ehan {m proper to ynur to cROn. Cmndt a lawyer if you dwbt the form, ataeva for your yumm. WOLCOTTB FORM 494 —Nay. 3 -70 (pricedass3) STOP NOTICE *11 if 00 0 C NOTICE TO WITHHOLD TO HOLDER OF FUNDS�t TO: City of Newport Beach (Name of owner, construction lender or public officer) 3300 Newport Blvd., Newport Beach, California HOLDER OF FUNDS, (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, A & C Electric, 1210 N. Jefferson St. "L" (Name and address) has furnished or has agreed to furnish electrical work per plans and specifications (labor, services, equipment, materials) of the following kind conduit wire lighting fixtures and telephone Conduit (general description of labor, services, equipment or materials) to or for Gram Constcvc.-tion Corporation for the work improvement, located at, or known as: (name of person to or for whom furnished) Channel Place Park, 9398 Channel Place, Newport Beach, CA (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 6 533.00 The amount in value of that already done or furnished by claimant is $ 6.533.00 Claimant has been paid the sum of $ —0— , and there remains due and unpaid the sum of $6,533.00 plus interest thereon at the rate of — per cent per annum from 19 —. YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: April 20, 1989 A 6 C Electric Name of Claimant 1210 N. Jefferson St. "L", Anaheim, CA 92807 Address of Claimant STATE OF CALIFORNIA n d > COUNTY OF ss.r) E la = a� nuOt7)1 'N 000t313'Q ,being duly sworn, deposes and says: That _he is the person(e) who signed the foregoing Stop Notice; that —he has read the same and knows the contents thereof to be true of hj-:)— own knowledge, except as to any matters or things that may therel be stated on his information and belief and as to those matters and things _he believes them to be true. �,.-__7 Z-7 Subscribed and sworn to before me this day ofd 19 OFFICIAL 01AAR �Z�N _� aWIfiE 00b111fY � Notary Public and in and for said State Yjpylrin ft Am29. 1900 211a6 standard form covers mmt amid Broblema in 0e Beal Indicated. Before you riph read B. Btl ro ,11 bleak[, /TOP NOTICE and make changes poper t0 your transaction. Consult • lawyer B you doubt doe forms anneal for Yomr puryoae. WOLCOTTY FORM "YA —pnv. 2.73 (Priceclaw3) 0 `yam A 0 N STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS of owner, construction lender or public of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, has furnished or has agreed to of the following (Name and address) equipment, materials) services, equipment or materials) RECEIVED In 17 is HOLDER OF FUNDS. to or for GR ACO C o A,5gur ff o A( for the work improvement, located at, or known as: (name of person•to or for whom furnished) (address, legal description, description of site or The amount in value of the whole agreed to be done or furnished by claimant is $ 56)0 00 The amount in value of that already done or furnished by claimant is $ 5 20 b O 6 Claimant has been paid the sum of $ N/A , and there remains due and unpaid the sum of $ 5166 O 0 plus interest thereon at the rate of (0 per cent per annum from EQRUA -R` , 19E . YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: 4�i7J0�1 t.\nN ANCoN/ P-ANSon15 NAJ(l Nam of Claimant 1063 'Po5TRoAD e0sTp.ytrMQ5A`f2626 Address of Claimant STATE OF CALIFORNIA c �o m COUNTY OF�f4i1 f7P ss. r as 7A1 h/ P1Q% fao»rJ.iS1�O�Ot71J�IID ti! _p being duly sworn, deposes and says: That —he is the person(s) who signed the foregoing Stop Notice; that —he has read the same and knows the contents thereof to be true of h.i..-2- own knowledge, except as to any matters or things that may therein be stated on hi5i information and belief and as to those matters and things —he believes them to be true. Subscribed and sworn to before me thi day of 19 o L WAL /l M. DAWN RAfSOR NOTARY PUBLIC- CALIFORNIA IN Notary Public and n and for sai State ,�,� o �: PR OF ORRANAN AI GE COUNTY My Commission Em Aug. la. 1999 :.NY�tifk 1M 136 rbndard foam eovma moat aaual Ptob4eas IS the Read Ind"ted. Before 5Z .Mw lead R ® in aR baaub, STOP NOTICE and make chaalaM vnww to your tnuniactlan. ('ioveult a Iawym if yea dmbt the [o m e Rmeu for ywe yury WOI.COTTS FORM 89a_nay. 2-7. (Pneeclass3) STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS OOQ��.'A � I TO:CityNewport Beach — Parks and Recreation (Cit, (Name of owner, construction lender or public officer) 3300 Newport Blvd., Newport Beach, Ca 92658 (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, Advanced Mechanical Contractors — 575 Van C -z« �/ Clerk HOLDER OF FUNDS. (Name and address) has furnished or has agreed to furnish Labor, Service and Materials — (Sewer Tie —in) (labor, services, equipment, materials) of the following kind 6" Sewer Pipe, Excavation, and Repair of Pavement. (general description of labor, services, equipment or materials) to or for Graco Construction , for the work improvement, located at, or known as: (name of person to or for whom furnished) Channel Park, River ave., Newport Beach, CA., Lots 1 &2 , Block 145 —Canal Section, (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 3,200• eto The amount in value of that already done or furnished by claimant is $ 3, 200. Claimant has been paid the sum of $ NIL and there remains due and unpaid the sum of $ 3,200. th plus interest thereon at the rate of 13% per cent per annum from Feb 20 1989 YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated:APril 11 th , 1989 STATE OF CALIFORNIA a ss. COUNTY OF Oran g Karl Boham (Owner) Nano of Claimant 575 VanBibber St., Orange CA 92666 Address of Claimant 4: Karl Bonham , being dbli and says: That x—he is the person(s) who signed the foregoing Stop Notice; that X—he has read the same and knows the contents thereof to be true of his own knowledge, except as to any matters or things that may therein be stated on h18 information and belief and as to those matters and things xlle believes them to be true. / Karl Bon am Subscribed and sworn to before me �...... t f-fL day o k I L 19� CON F E L RC ER aaawntvaac- cw+val IIOICM11LalRiCtN tary ub amd in and for said State ayelawra fapmJtw.x t1r 7Lh famdaad form covara zed mad problems as Wo Sold rndkated. Before yon wy real R So fa dl tladt7. STOP NOTICE and make &&new pope[ to yom tramacdon. Ce1aWt alawyer if ym dmbt tha forma AtimM fm your amrgo WOLCOTTS FORM 31�ay. 1.73 • Stop Notice r / c *. CALIFORNIA CIVIL CODE SECTION 3103 Certified # 1039669 Pho� NOTIC Cit of Newport Beach APR 1 2198 ►� (Name of construction Lender, Public Body or Owner) 3300 Newport Blvd., Newport Beach, CA. 92663 (Address) t(Pf Privat — file with responsible officer on at office or branch of construction lender administering ton funds or with the owner — CIV M.CODE SECTIONS 3156 - 3175) Job — file with office of controller, auditor, or other public disbursing officer whose duty it is to make der provisions of the contract — CIVIL CODE SECTIONS 3179 - 3214) R Con r: Graco Construction Corp. ntract If Any) Graco Construction Corp. u Body: City of Newport Beach emen own as Channel Place Park, 4398 Channel Palace, Newport Beach, CA. 92663 /Name and address of project or work of improvement) `a{.34-)C't`ty of Newport Beach County of State of California. FAMILIAN CORP dba Familian Pipe & Supply Claimant,a Corporation (Claimant) (Corporation /Partnership /Sole Proprietorship) furnished certain labor, service, equipment or materials used in the above described work of improvement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment, or materials is _- Graco Construction Corp. The kind of labor, service, equipment, or materials furnished or agreed to be furnished by claimant was pipe, plumbing materials, appliances & related plumbing, heating, air conditioning and building materials Total value of labor, service, equipment, or materials agreed to be furnished......... $ 4,335.62 Total value of labor, service, equipment, or materials actually furnished is............ $ 4,335.62 Credit for materials returned, if any ............................... ............................... $ -0- Amount paid on account, if any .................................... ............................... $ -0- Amount due after deducting all just credits and offsets ..... ............................... $ 4,335.62 YOU ARE HEREBY NOTIFIED to withhold sufficient monies held by you on the above described project to satisfy claimant's demand in the amount of $ 4,335.62 and in addition thereto sums sufficient to cover interest, court costs and reasonable costs of litigation, as provided by law. A bond (CIVIL CODE SECTION 3083) is attached. (Bond required with Stop (is/is not) - Notice served on constructions lender on private jobs —bond not required on public jobs or on Stop Notice served on owner on private jobs). 2/April 7. 1989 Name of Claimant FAMILIAN CORP dab Familian Pipe & Supply .? p- /Firm Name) P.O. Box 945 - (Moiling Address) Arleta . 91331 i'n-Ien ✓ er B 3$V y n � (sig ure) Stan Rubin. General Credit Manager (011ictal Capacity) '-rry DIG VERIFICATION t1c :54Dir. Dirthe undersigned, state: t am the General Credit Manager ❑ fl, -Rice vh fet ; - :; /'Agent of; "President of , 'A Partner or: "Owner of; etc.) 1 ' V Dithe claiiiiant named in the foregoing Stop Notice; I have read said claim of Stop Notice and know the contents r t thcr t(tereofi :3itd I certify that the same is true of my own - knowledge. �.&7d r,•%� certify (or delcare) under penalty of perjury under the laws of the State of California that the foregoing i5 true and correct. / 3 Executed on April 7 19 89 L s n ales State of California r 7(stfitature of Claimant or uthorized Agent) REQUEST FOR NOTICE OF ELECTION (Private Works Only) If an election is made not to withhold funds pursuant to this stop notice by reason of a payment bond having been recorded in accordance with Sections 3235 or 3162, please send notice of such election and a copy of the bond within 30 days of such election in the enclosed preaddressed stamped envelope to the address of the claimant shown above. This information must be provided by you under Civil Code Sections 3159, 3161 or 3162. Signed: (Claimant must enclose se(j addressed stamped envelope) - RICA FORM 41FSNOq 111189 `' ` go STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS (Name of owner, construction lender or public (Address of owner or YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, has furnished or has agreed to of the following (Name and address) services, materials) (general description of labor, services, equipment or materials) rtt 112 0 aw a NEMRDR'r BPACN HOLDER OF FUNDS. �o, 6ckx 6sz- to or for &Oqt p�d(JhrS�pi t T /07e% , for the work improvement, located at, or known as: (name of person to or for whom furnished) legal description, description of site or The amount in value of the whole agreed to be done or furnished by claimant is $ 1!�-13 .2- The amount in value of that already done or furnished by claimant is $ /t13 �2 s— Claimant has been paid the sum of $ and there remains due and unpaid the sum of $ /4/3:.Z S ADO plus interest thereon at the rate of lv S per cent perA01,11n from a �i1 19 `f- ,Oo V0T4-9y FEE, YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. �Z)Plr .6�i Mcra c Dated: all 9 QP &.n AwC.ki rt PUMP ZA j Name of Claimant S-r*v7a�ro, von S d Address of Claimant K STATE OF CALIFORNIA COUNTY OF% ifs /�ll ss. � y E ; >CC qtr _. C� 1 C.�_.� r- Co os 1. ��G �Q��E r:u r O❑ �I O 0 C❑ R y sworn, deposes and says: That Ae is the person(s) who signed the foregoing Stop Notice; that L6e has read the same and knows the contents thereof to be true of hA—S own knowledge, except as to any matters or things that may therein be on h1_,5 information and belief and as to those matters and things Ile believes them to be true. Subscribed /and /s orn to before me this day of lg =.SAI ICIAL SEAL W STANGE 4/1 L•CL:C CALIFORNIA G.— RNARDINO COUNii Notary Pu blic and in and f, said State . expires FEB 22, 1992 7Lis dmdard form mvm meat areal problem Io the Said lndimaed. Mere Ye¢ a12a, Bad lt, fill In all 61edo, STOP NOTICE and male ehanEaa PmPar to Your baauaNm. Cmault alawyer If year doubt the forma dtneu for Your surypa. WOLCOTTS FORM 611 - Rai 2.73 (p.ceelassal STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS "LLcftcL) PUPS W:illMS ITY OF NEW PORT BEACH . (Name of owner, construction lender or public officer) rJe'vr, =trfit BEANO I ew Port Blvd, New Port Beach, X\/ (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, r 4 RECEIVED APR 10 10 WIL HOLDER OF FUNDS. HANK'S MAINTENANCE & REPAIR — 12592 Tours Ave, Garden Grove, Ca (Name and address) has furnished or has agreed to furnish LABOR AND MATERIALS (labor, services, equipment, materials) of the following kind STEEL FABRICATION AS PER PLANS AND SPECS (general description of labor, services, equipment or materials) to or for GRACO CONSTRUCTION for the work improvement, located at, or known as: (name of person to or for whom furnished) 4400 River Aave, New Port Beach Ca 92663 (Channel Place Park ) (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 5 , 800 .00 The amount in value of that already done or furnished by claimant is $ 5 . 800 .00 Claimant has been paid the sum of $ 0 and there remains due and unpaid the sum of $5 , 800 .00 plus interest thereon at the rate of 12 per cent per annum from January 14 , 1989 YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: HANK'S MAINT & REPAIR Name of Claimant 12592 Tours Ave, Garden Grove, Ca Address of Claimant STATE OF CALIFORNIA ss COUNTY OF Oro n5 f E c eft Try �•� z„OE ` �, ncs�W c!�ial ,being duly sworn, deposes and says: That _he is the persons) who signed the foregoing Stop Notice; that _he has read the same and knows the contents thereof to be true of h_ own knowledge, except as to any matters or things that may therein be stated on hl,_S_ information and belief and as to those matters and things —he believes them to be true. /7t (-Owner \ Subscribed and sworn to before me OFFICIAL SEAL j� R `r DOUGLAS B. WARD this ray of— 1 19 —L. NOTARY PUBLIC CALIFORNIA 2, 198 r ORANGECOUNTY / My Comm. E+pi,e. Sep, 2, 1989 Notary Public and in and for said State '� b 72ab standard Form cover, mast mnsl peobbms to the field l dlceetcd, Before fee rlQrl and R ®m e➢ bleu, tTOP NOTICi sod m� rR.^p to Your CsonaUw. Copsult • lsveyer V yqr dwbt [Lp Eorm s abxu for > purpose. WOLCOM FORM IyHRlrv. a. -Tfi (nrlceclan3l STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS (Name of owner, construction lender or public officer) (Address of owner or construction lender) YOU ARE HE Y NOTIFIED THAT the undersigned claimant, (Name and address) has furnished or has agreed to equipment, r wat 0 , 0 HOLDER OF FUNDS. M of the following kind_ y��A�� (general description of labor, services, /equipment or materials} to or for n O—Ld � X Lr it �-# , for the work improvement, located at, or known as: (name of person to or for whom furnished) _ , (address, legal description, description of site or project The amount in value of the whole agreed to be done or furnished by claimant is $ 6,2: 9B J O r The amount in value of that already done or furnished by claimant is $ y S °J p Claimant has been paid the sum of $ 0, and there remains due and unpaid the sum of plus interest thereon at the rate of Oper cent per annum from I/ ^ 3 19�a 1 YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: `7 Name of Claimant l 9 6 O,ai den& Date �� dress Claimant ceh . W-KES SENT TO: ❑ Mayor STATE OF CALIFORNIA ❑ Councilmen ss. Whanager COUNTY j2 A p#� i!0,! -,rney 0 E?dg. Dir. 0 GeaiSery Dir. ❑F'4 &RDir. O Plannirtg Dir. being duly sworn, deposes and says: That _he is the persorKs) who signed the foregoing Stop Nogg' Ce If8 read the same and knows the contents thereof to be true of hr� own knowledge, except as to any matters ar things 4ein be stated on h" information and belief and as to those matters and things —he believes them to be true. Subscribed and sworn to before me ���,,``//�� �+.a.aaa.aaaaaajaM, this�day of r 19 q MAP,R.yNN 1 FULLER NoTf -,V PUBLIC - MIFGRNLA o PRINCIPAL OFFICE IN Notary Public and in and for said State ORANGE COUNTY MY Coau Beim Exp. Dec. 4, IM,. This alaadard form oovaa mat usual Probama to the Bdd IndiabmL Befom Too at� red R. 6a to d bland. STOP NOTICE and make ehaoaaa Vmpw m you tranaartlm. Comfit a lawyer If you doubt the forma EtoeM for Yaw Purpose, WOLCOTT{ FORM 11,04 —Ray. Y -T. (pnuc=53) STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS Beach— Att: Mr. Ken Pe (Name of owner, construction lender or public officer) V Public Works Department 3300 Newport Blvd., HOLDER OF FUNDS. Newport Beach, CA (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, Lee Roofing of Costa Mesa, Inc. (Name and address) has furnished or has agreed to furnish tabor and materials (labor, services, equipment, materials) of the following kind Roofing of Channel Plata park (Contract No C -2664) (general description of labor, services, equipment or materials) to or for Graco Contruction Corp. for the work improvement, located at, or known as: (name of person to or for whom furnished) Channpt Plata park— Channel Plare Newport Beach CA (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ 2 . 4 n 0 _ 0 n The amount in value of that already done or furnished by claimant is $2 , 400.00 Claimant has been paid the sum of $ - 0 - , and there remains due and unpaid the sum of $2 , 400. 00 plus interest thereon at the rate of 18 per cent per annum from March 31, 1989 YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: April 0.3, 19gd Tae Roofing of Costa Mpca, Tnr_ Name of Claimant STATE OF CALIFORNIA COUNTY OF ORANGE SS. 1653 Superior Ave., Costa Mesa, CA 92627 Neville D. Graaff ©c�t7fJ57t�DIJLi1_113 P being duly sworn, deposes and says: That —he is the person(s) who signed the foregoing Stop Notice; that —he has read the same and knows the contents thereof to be true of hi-r.- own knowledge, except as to any matters or things that may therein be stated on h_ information and belief and as to those matters and things _he believes them to be true. / Subscribed and sw to before me OFFICIAL SEAL day of 19� CAROL R. JOSE: e NOTARY PUBLIC -cALIFORN .1 Notary Public and in arM ORANGE COUNTY (ors d Sta a -------- Ma Commission Exp. April 20. 1990 'f This slandaad form Coven muI =A poblelu m the Bold Indkated. Beim ==am d R ®ta an blaab, STOP NOTICE and make chansm propm m Tour banmetle, Con"t a lawycr rr Too doubt ataen [or Tour waeaw. TYOLGOTTS FORM *V44 R[v. 2.71 IDlice CIa5571 STOP NOTICE Public Works OD a66� City of Newport Beach: Attention, Irene Butler, City Clerk Of �pR c�+R`ecntN 3300 Newport ElIVEI., Newport eac , HpO YOU ARE HEREBY NOTIFIED that the undersigned claimant, Terry Lumber Co. of Glendale furnished lumber and building materials to Graco Construction pursuant.to that certain contract made between Graco Construction and Terry Lumber Co. of Glendale for that certain public work of improvement consisting of the construction at 4398 Channel PI., Newport Beach, CA 92663 and which is and was the whole of said materials agreed to be furnished by claimant; The contract price of said materials was and is the sum of $ 6,665.62 and said sum was and is the reasonable value thereof; nothing has been paid or credited on said amount; and there is now due and owing to claimant, for and on account hereof, the sum of $ 6,665.62 in lawful money of the United States, after deducting all just credits and offsets, and the same has not been paid. WHEREFORE, the undersigned claims and benefit of the law given to laborers, materiaimen and others under and by virtue of the provisions of Division,"3, Title 15, Section 3103 and Sections 3181 and 3214 of the Civil Code of the State of California, and prays that you withhold from said original contractor, Graco Construction sufficient money that may be due it or that may become due it for said work to answer and pay the amount of this claim, to wit, $ 6,665.62 Dated: March 24, 1989 } >o�nvS Cn .� NCO NG• a> :P � �(i W ; O. oo 000 I Terry Lumber Co. of Glendale VERIFICATION declare that I am the vice PrPCident Finance of Terry Lumber Co. of Glendale the claimant named in the foregoing claim, and am authorized to make this verification for and on behalf of said claimant, and I make this verification for that reason. I have read said claim and know the contents thereof and the same is true and contains among other things, a correct statement of claimant's demands after deducting all just credits and offsets. I declare under penalty of perjury that the foregoing is true. Executed on March 24, 1989 at Tarzana , California Stop Notice CALIFORNIA CIVIL CODE SECTION 3103 PUSl1': NOTICE TO City of NPWpOrt Raarh 89 41, ( ame, of Construction Lender, Public Body or Owner) I 3300 Npwpnrt Reach C (Address) + f Bea (If Private Job — file with responsible officer or perat office or branch of construction leW r ., is 6 the construction funds or with the owner — CIVIL CODE SECTIONS 3156 - 3175) (If Public Job — file with office of controller, auditor, or other public disbursing officer whose duty it is to make payments under provisions of the contract — CIVIL CODE SECTIONS 3179 - 3214) Prime Contractor: Graco Construction Sub Contractor (If Any) Owner or Public Body: City of Newport Beau Improvement known as Channel Park (Name and address of oroiect or work of imoroyemert0 in the City of Newport Beach County of State of California. United Premix Concrete, Inc. Claimant,a _. corporation (Claimant) _ (Corporation /Porfiership /Sole Proprietorship) furnished certain labor, service, equipment or materials used in the above described work of improvement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment, or materials is (Name of Subcontractor /Contractor /Owner - Builder) Graco Construction The kind of labor, service, equipment, or materials furnished or agreed to be furnished by claimant was ready mixed concrete & related items Total value of labor, service, equipment, or materials agreed to be furnished......... $ 13,403.14 Total value of labor, service, equipment, or materials actually furnished is............ $ 13,403.14 Credit for materials returned, if any ............................... ............................... $ Amount paid on account, if any .................................... ...I........................... $ 4,064-55 Amount due after deducting all just credits and offsets ...... ............................... $ 9- 339.59 YOU ARE HEREBY NOTIFIED to withhold sufficient monies held by you on the above described project to satisfy claimant's demand in the amount of $ 11.673.24 and in addition thereto sums sufficient to cover interest, court costs and reasonable costs of litigation, as provided by law. A bond (CIVIL CODE SECTION 3083) is not attached. (Bond required with Stop (is/is not) Notice served on constructions lender on private jobs —bond not required on public jobs or on Stop Notice served on owner on private jobs). Date Name of Claimant P 0 Box 1608 (Mailing Address) aldwin Pak CA 91706 t el ^ (Signature) C (O fi a! Capacity) _ cu, VERIFICATION I, the undersigned, state: I am the Credit Manager ('Agent of; "President of; 'A Partner of'; "Owner of; etc.) - the claimant named in the foregoing Stop Notice; I have read said claim of Stop Notice and know the contents thereof, and I certify that the same is true of my own knowledge. I certify (or delcare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed on 3/1/89 State of fal ifnrnin 19 _ t Irwindale (Signature of Claimant onAulhori¢ed Agent) REQUEST FOR NOTICE OF ELECTION (Private Works Only) If an election is made not to withhold funds pursuant to this stop notice by reason of a payment bond having been recorded in accordance with Sections 3235 or 3162, please send notice of such election and a copy of the bond within 30 days of such election in the enclosed preaddressed stamped envelope to the address of the claimant shown above. This information must be provided by you under Civil Code Sections 3159, 3161 or 3162. i; 7 e Signed: BICA FORM 4 (FSNOI) 111189 0 0 W-Lam Sales Co., Iig. March 1, 1989 v ✓Ep City of Newport Beach 3300 Newport Blvd. "x Newport Beach, CA 92658 3Etgy ATTN: Geroge Pappas, Finance Dept. re: Channel Place Park Renovation Project Newport Beach Graco Construction Corporation Dear Mr. Pappas: Enclosed please find a Stop Notice form regarding the above referenced project. Pursuant to California Civil Code Section 3185, we are enclosing a check in the amount of $2.00 (Two Dollars) for notification of the filing of the Notice of Completion or Acceptance of Completion. Thank you for your attention to this matter. If you should have any questions regarding the enclosed, please do not hesitate to call me at the telephone number shown below. Gregg,,Mc�Farland Vice President Date GM /jt U'11� ;`-SS"ATM ❑ ,Y ayar encl. ❑ Courr . ° non �,garttk�ar ' woe Bey 3 ❑ naafi Dir. ❑ POce G f1iet r rd mv. Di[ ra O;rier�� Zcn 4741 E. Hunter Ave., Ste. B • Anaheim, CA 92807 • (714) 777 -8322 • FAX (714) 777 -8325 Stop Notice CALIFORNIA CIVIL CODE SECTION 3103 NOTICE TO The City of Newport Beach (Name of Construction Lender, Public Body or Owner) 3300 Newport Blvd., Newport Beach, CA 92658 (Address) (If Private job — file with responsible officer or person at office or branch of construction lender administering the construction funds or with the owner — CIVIL CODE SECTIONS 3156 - 3175) (If Public job — file with office of controller, auditor, or other public disbursing officer whose duty it is to make payments under provisions of the contract — CIVIL CODE ffiS�I€?oNA117,R- Bllvd. , Ste 230 Prime Contractor: Graco Construction Company Rancho Cucamonga, CA 91730 Sub Contractor (If Any) Owner or Public Body: Improvement known as Channel Place Park Renovation (Name and address of project or work of impr Balboa Boulevard RECEIVED I" W in the City of Newport Beach County of Orange \� State of California. Glu -Lam Sales Co., Inc. Corporation ,Claimant, a (Claimant) (Corporation /Partnership /Sole Proprietorship) furnished certain labor, service, equipment or materials used in the above described work of improvement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment, or materials is Graco Construction Lxompany (Name of Subcontractor /Contractor /Owner- Builder) 10535 Foothill Boulevard Suite 230, Rancho Cucamonga, California 91730 The kind of labor, service, equipment, or materials furnished or agreed to be furnished by claimant was Ten Glued Laminated Beams (Describe in detail) Total value of labor, service, equipment, or materials agreed to be furnished ....... $ 4,110.00 Total value of labor, service, equipment, or materials actually furnished is .......... $ -0- Credit for materials returned, if any ............... ..............................$ -0- Amount paid on account, if any ................... ..............................$ -0- Amount due after deducting all just credits and offsets ............................ $ 4,110.00 YOU ARE HEREBY NOTIFIED to withhold sufficient monies held by you on the above described project to satisfy claimant's demand in the amount of $ 4,110.00 and in addition thereto sums sufficient to cover interest, court costs and reasonable costs of litigation, as provided by law. A bond (CIVIL CODE SECTION 3083) is not attached. (Bond required with Stop (is /is not) Notice served on construction lender on private jobs — bond not required on public jobs or on Stop Notice served on owner on private jobs). Date March 1 , 1 Name of Claimant MM VERIFICATION I, the undersigned, state: I am the President of ( "Agent of ", "President of", `A Partner of", "Owner of ", etc.) the claimant named in the foregoing Stop Notice; I have read said claim of Stop Notice and know the contents thereof, and I certify that the same is true of my own knowledge. I certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed on March 1st lg 89 , at Anaheim, State of California (Signature of Claimant or Authorized Agent) RICA FORM 4 (REV. 2/87) • • - 4 • ' 0 Stop. Notice • CALIFORNIA CIVIL CODE SECTION 3103 NOTICE TO The City of Newport Beach (Name of Construction Lender, Public Body or Owner) 3300 Newport Blvd., Newport Beach, CA 92658 (Address) (If Private Job — file with responsible officer or person at office or branch of construction lender administering the construction funds or with the owner — CIVIL CODE SECTIONS 3156 - 3175) (If Public Job — file with office of controller, auditor, or other public disbursing g2offgsii2cerlwhose duty it is to make payments under provisions of the contract — CIVIL CODE,(SEglpo0thi11 B71v�. , Ste 230 Prime Contractor: Graco Construction Company Rancho Cucamonga, CA 91730 Sub Contractor (If Any) Owner or Public Body: The City of Newport Beach Improvement known as Channel Place Park Renovation (Name and address of project or work of improvement) On Channel Place Between River Avenue and Balboa Boulevard in the City of Newport Beach County of Orange State of California. Glu -Lam Sales Co., Inc. Corporation ,Claimant, a (Claimant) (Corporation /Partnership /Sole Proprietorship) furnished certain labor, service, equipment or materials used in the above described work of improvement. The name of the person or company by whom claimant was employed or to whom claimant furnished labor, service, equipment, or materials is Graco Construction Company 10535 Foothill Boulevard Suite 230, Rancho Cucamonga, California 91730 The kind of labor, service, equipment, or materials furnished or agreed to be furnished by claimant was Ten Glued Laminated Beams (Describe in derail) Total value of labor, service, equipment, or materials agreed to be furnished ....... $ 4,110.00 Total value of labor, service, equipment, or materials actually furnished is .......... $ -0- Credit for materials returned, if any ............... ..............................$ -0- Amount paid on account, if any ................... ..............................$ -0- Amount due after deducting all just credits and offsets ............................ $ 4,110.00 YOU ARE HEREBY NOTIFIED to withhold sufficient monies held by you on the above described project to satisfy claimant's demand in the amount of $ 41110.00 and in addition thereto sums sufficient to cover interest, court costs and reasonable costs of litigation, as provided by law. A bond (CIVIL CODE SECTION 3083) is not attached. (Bond required with Stop (is /is rot) Notice served on construction lender on private jobs — bond not required on public jobs or on Stop Notice served on owner on private jobs). Date March 1, 1989 Name of Claimant By VERIFICATION I, the undersigned, state: I am the President of ( "Agent of', "President of ", "A Partner of ", "Owner of ", etc.) the claimant named in the foregoing Stop Notice; I have read said claim of Stop Notice and know the contents thereof, and I certify that the same is true of my own knowledge. I certify (or declare) under penalty of perjury under the laws of the State of California that the foregoing is true and correct. Executed on March 1st 19 89 at Anaheim, State of California Signature of Claims or Aut d Agent) RICA FORM 4 (REV. 2/871 TO: STOP NOTICE NOTICE TO WITHHOLD TO HOLDER OF FUNDS C'-zEC� PUB ric IVFD KS FE 8 2 7 Cfr.�F1989 NE6va�47 ReaCH (Name of owner, construction lender or public officer) ' ! 3300 NEWPORT BOULEVARD, NEWPORT BEACH, CA 92663 HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, UPLAND MASONRY, INC., 809 NORTH TURNER AVENUE, ONTARIO, CA (Name and address) has furnished or has agreed to furnish LABOR AND MATERIALS (labor, services, equipment, materials) of the following kind MASONRY (general description of labor, services, equipment or materials) to or for GRACO CONSTRUCTION COMPANY for the work improvement, located at, or known as: (name of person to or for whom furnished) CHANNEL PLACE PARK, 4400 RIVER AVENUE, NEWPORT BEACH, CA 92663 (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ -471,220-00 The amount in value of that already done or furnished by claimant is $ 37 .22(1 _ nf) Claimant has been paid the sum of $ 00 , and there remains due and unpaid the sum of $ 17 92U DO plus interest thereon at the rate of 7 per cent per annum from FEBRUARY 24 1989 YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. Dated: FEBRUARY 24, 1989 :2 UPLAND MASONRY, INC. 809 NORTH UeF2oNER nAVENUE ONTARIO, CALIFORNIA 91761 rit3 Address of Claimant Fv l(5 r. Rp STATE OF CALIFORNIA 11 `11 nir COUNTY OF SAN BIItNADINO l - MANUEL M. LUNA -y8 bein and says: That —he is the person(s) who signed the foregoing Stop Notice; that _he has read the same and knows the cc act to be true of h1S_ own knowledge, except as to any matters or things that may therein be stated on hLi information and belief and as to those matters and things —he believes them to be true. Subscribed and sworn to before me this day of Fe l>. 89 Notary Public and in and for said State MARTHA T. QUIROZ 71uh stenderd roan wo m mart oroel poblemr in the field Indtoted. Wow, =,,, laer rwd N. 611 b all blAab, STOP NOTICE rnd mike ohenne+ poVm b year Rwaelton. Ceoault r lavryer if yon dwbt onar foe for Yevr prrepe. WOLCOTTN FORM !PA —Ray. 2.73 Ipricecuw3l OFFICIAL SEAL fiAFTtiA T OU19OZ NOTFF.Y r':;ciLn: CALIFORNIA PAINCIRAL OFFWL IN SAN eEFINAFWANO COUNTY MV COMM. ExP SEp 7. 1990 71uh stenderd roan wo m mart oroel poblemr in the field Indtoted. Wow, =,,, laer rwd N. 611 b all blAab, STOP NOTICE rnd mike ohenne+ poVm b year Rwaelton. Ceoault r lavryer if yon dwbt onar foe for Yevr prrepe. WOLCOTTN FORM !PA —Ray. 2.73 Ipricecuw3l STOP NOTICE �L NOTICE TO WITHHOLD TO HOLDER OF FUNDS t' DEC 2 2 1988 . Cs;,,;. TD: O NEb11rr' : r✓f_r1ric 4 i 1 T (Name of owner, construction lender or public officer) 33G G N r!u p. 4L..vD Wc. p A Oew.Q.L ' C '9 a 6 3 , HOLDER OF FUNDS. (Address of owner or construction lender) YOU ARE HEREBY NOTIFIED THAT the undersigned claimant, E r1J 11 (Name slid address) has furnished or has agreed to furnish 1 R. k0 f (labor, services, equipment, materials) of the following to or (general or materials) :vafl-J L ( %mgnCO LQNSlC x:7rin! for the work improvement, located at, or known as: (name of person to or for whom furnished) n ('� _.%ClN l i�l.ar. Re)c - "ewf'oC-t (address, legal description, description of site or project identification) The amount in value of the whole agreed to be done or furnished by claimant is $ A'200 0.. ' The amount in value of that already done or furnished by claimant is E Claimant has been paid the sum of $ C and there remains due and unpaid the sum of plus interest thereon at the rate of16per cent per annum from Oc"r� > �`+L 10—, YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST, Dated: Ot-c 17, lCli STATE OF CALIFORNIA COUNTY OFRAn�tS -1� ss. Rorvct-t,r) (".6j 0 • 11„ STOP NOTICE Notice to Withhold to Holder of Funds CITY OF NEWPORT BEACH 3300 Newport Boulevard Newport Beach, California 92663 C -Z66�Z YOU ARE HEREBY NOTIFIED THAT the undersigned Claimant, UPLAND MASONRY, INC., who resides at 809 North Turner Avenue, Ontario, California 91761, has furnished or has agreed to furnish GRACO CONSTRUCTION CORPORATION, for the work improvement, located at, or known as: CHANNEL PLACE PARK RENOVATION, 4400 River Avenue, Newport Beach, California. The amount in value of the whole agreed to be done or furnished by Claimant is $37, 910.00. The amount in value of that already done or furnished by Claimant is $37,910.00. Claimant has been paid the sum of $ 0 and there remains due the sum of $37,910.00, plus interest thereon at the rate of ten per cent (10 %) per annum from November 7, 1988. YOU ARE HEREBY NOTIFIED TO WITHHOLD SUFFICIENT FUNDS TO SATISFY THIS CLAIM WITH INTEREST. DA D?ovanber- l4, -.cl\ ai m `6: is, IS O �'a'-'❑�a S1 C ° ri) " 0 D o _ V)a 4 cn °t,r tc o o ❑ao❑ ❑V 0�113 STATE OF CALIFORNIA ) COUNTY OF SAN BERNARDINO ) ss. UPLAND MASONRY, INC. BY i Li�a,✓�� • MA L LUNA V� President MANUEL LUNA, being duly sworn, deposes and says: That he is the person who signed the foregoing Stop Notice; that he has read the same and knows the contents thereof to be true of his own knowledge, except as to any matters or things that may therein be stated on his information and belief and as to those matters and things he believes them to be true. �- )�� NUEL LUNA Subscribed and sworn to before me this 14th day of November 19 88 OFFICIAL SEAL NOTARY PUBLI PAT L. METZGER Notary Pik- CclifOmis SAN BERNARDINO COUNTY My Comm. E>m. Lhy 17, 1991 i • ,,.. ,. ti,. � . ,: 4 *t,,.,,r i .< \ .