Loading...
HomeMy WebLinkAboutC-3673(F) - PSA for On-Call Archeological ServicesPROFESSIONAL SERVICES AGREEMENT WITH LSA ASSOCIATES, INC. FOR ON -CALL ARCHAEOLOGICAL SERVICES AGREEMENT is made and entered into as of this a?_ day of , 2005, by and between the CITY OF NEWPORT BEACH, a municipal corporation ( "City "), and LSA ASSOCIATES, INC., a California corporation whose address is 20 Executive Park, Suite 200, Irvine, CA 92614 ( "Consultant "), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City has a need for on -call assistance for archaeological services in regards to City construction projects. C. City desires to engage Consultant to perform on -call archaeological services in various locations and for various City construction projects ( "Project"). D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal member[s] of Consultant for purposes of Project, shall be Deborah McLean. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned Parties as follows: TERM The term of this Agreement shall commence on the above written date, and shall terminate on the 30th day of June 2007, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall provide "On -Call" archaeological services as described in the Statement of Qualifications attached as Exhibit "A." Upon verbal or written request from the Project Administrator, Consultant shall provide a letter proposal 0 0 for services requested by the City (hereinafter referred to as the "Letter Proposal "). The Letter Proposal shall include only the following: (a) A detailed description of the services to be provided; (b) The position of each person to be assigned to perform the services, and the name of the individuals to be assigned, if available; (c) The estimated number of hours and cost to complete the services; (d) The time needed to finish the project. No services shall be provided until the Project Administrator has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE Time is of the essence in the performance of services under this Agreement and the services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the services on a time and expense not -to- exceed basis, in accordance with the provisions of this Section and the Schedule of Billing rates attached hereto as Exhibit `B" and incorporated herein by reference. No rate changes shall be made during the term of this Agreement without the prior written approval of the City. Consultant's compensation for services performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed the fees identified in the Letter Proposal, as approved by the Public Works Department. Any Letter Proposal that sets forth fees in excess of Thirty Thousand Dollars and No Cents ($30,000,00) shall require a separate Professional Service Agreement approved by City Council per Council Policy F -14. 2 4.1 Consultant shall submit monthly invoices to City describing the work performed the preceding month. Consultant's bills shall include the name of the person and /or classification of employee who performed the work, a brief description of the services performed and/or the specific task in the letter proposal to which it relates, the date the services were performed, the number of hours spent on all work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in the Letter Proposal. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: A. The actual costs of subconsultants for performance of any of the services that Consultant agrees to render pursuant to this Agreement and the Letter Proposal, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and/or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work without the prior written authorization of City. As used herein, "Extra Work" means any work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Letter Proposal and which the parties did not reasonably anticipate would be necessary. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Deborah McLean to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 3 7 Fl 41 ADMINISTRATION 0 This Agreement will be administered by the Public Works Department. Robert Gunther shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his /her authorized representative shall represent City in all matters pertaining to the services to be rendered pursuant to this Agreement. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's work schedule. B. Provide blueprinting and other services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. STANDARD OF CARE 8.1 All of the services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the services required by this Agreement, and that it will perform all services in a manner commensurate with community professional standards. All services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. 8.2 Consultant represents and warrants to City that it has or shall obtain all licenses, permits, qualifications, insurance and approvals of whatsoever nature that are legally required of Consultant to practice its profession. Consultant further represents and warrants to City that Consultant shall, at its sole cost and expense, keep in effect or obtain at all times during the term of this Agreement, any and all licenses, permits, insurance and other approvals that are legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's 51 work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 8.4 The term Construction Management or Construction Manager does not imply that Consultant is engaged in any aspect of the physical work of construction contracting. Consultant shall not have control over or be in charge of and shall not be responsible for the project's design, City's project contractor ( "Contractor'), construction means, methods, techniques, sequences or procedures, or for any health or safety precautions and programs in connection with the work. These duties are and shall remain the sole responsibility of the Contractor. Consultant shall not be responsible for the Contractors' schedules or failure to carry out the work in accordance with the contract documents. Consultant shall not have control over or be responsible for acts or omissions of City, Design Engineer, Contractor, Subcontractors, or their Agents or employees, or of any other persons performing portions of the work. 9. HOLD HARMLESS To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents and employees (collectively, the "Indemnified Parties) from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any work negligently performed or services provided under this Agreement (including, without limitation, defects in workmanship or materials and /or design defects [if the design originated with Consultant]) or Consultant's presence or activities conducted on the Project (including the negligent and /or willful acts, errors and/or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of 5 conducting the work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator and /or his/her duly authorized designee informed on a regular basis regarding the status and progress of the work, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of work. Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, a policy or policies of liability insurance of the type and amounts described below and in a form satisfactory to City. A. Certificates of Insurance. Consultant shall provide certificates of insurance with original endorsements to City as evidence of the insurance coverage required herein. Insurance certificates must be approved by City's Risk Manager prior to commencement of performance or issuance of any permit. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. B. Signature. A person authorized by the insurer to bind coverage on its behalf shall sign certification of all required policies. 2 9 C. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. D. Coverage Requirements. Workers' Compensation Coverage. Consultant shall maintain Workers' Compensation Insurance and Employer's Liability Insurance for his or her employees in accordance with the laws of the State of California. In addition, Consultant shall require each subcontractor to similarly maintain Workers' Compensation Insurance and Employer's Liability Insurance in accordance with the laws of the State of California for all of the subcontractor's employees. Any notice of cancellation or non - renewal of all Workers' Compensation policies must be received by City at least thirty (30) days prior to such change. The insurer shall agree to waive all rights of subrogation against City, its officers, agents, employees and volunteers for losses arising from work performed by Consultant for City. 2. General Liability Coverage. Consultant shall maintain commercial general liability insurance in an amount not less than One Million Dollars ($1,000,000) per occurrence for bodily injury, personal injury, and property damage, including without limitation, contractual liability. If commercial general liability insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply separately to the work to be performed under this Agreement, or the general aggregate limit shall be at least twice the required occurrence limit. 3. Automobile Liability Coverage. Consultant shall maintain automobile insurance covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than One Million Dollars ($1,000,000) combined single limit for each occurrence. 4. Professional Errors and Omissions Insurance. Consultant shall maintain professional errors and omissions insurance, which covers the services to be performed in connection with this Agreement in the minimum amount of One Million Dollars ($1,000,000). D. Endorsements. Each general liability and automobile liability insurance policy shall be endorsed with the following specific language: 7 • The City, its elected or appointed officers, officials, employees, agents and volunteers are to be covered as additional insureds with respect to liability arising out of work performed by or on behalf of the Consultant. ii. This policy shall be considered primary insurance as respects to City, its elected or appointed officers, officials, employees, agents and volunteers as respects to all claims, losses, or liability arising directly or indirectly from the Consultant's operations or services provided to City. Any insurance maintained by City, including any self - insured retention City may have, shall be considered excess insurance only and not contributory with the insurance provided hereunder. iii. This insurance shall act for each insured and additional insured as though a separate policy had been written for each, except with respect to the limits of liability of the insuring company. iv. The insurer waives all rights of subrogation against City, its elected or appointed officers, officials, employees, agents and volunteers. V. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to City, its elected or appointed officers, officials, employees, agents or volunteers. vi. The insurance provided by this policy shall not be suspended, voided, canceled, or reduced in coverage or in limits, by either party except after thirty (30) days written notice has been received by City. A. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claim made or suit instituted arising out of or resulting from Consultant's performance under this Agreement. B. Additional Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the work. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty I percent (50 %) or more of the voting power, or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 16. SUBCONTRACTING The parties recognize that a substantial inducement to City for entering into this Agreement is the professional reputation, experience and competence of Consultant. Assignments of any or all rights, duties or obligations of the Consultant under this Agreement will be permitted only with the express written consent of City. Consultant shall not subcontract any portion of the work to be performed under this Agreement without the written authorization of City. 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed documents for other projects and any use of incomplete documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 18. COMPUTER DELIVERABLES CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by City in ".dwg" file format on a CD, and should comply with the City's digital submission requirements for Improvement Plans. The City will provide AutoCAD file of City Title Sheets. All written documents shall be 0 0 transmitted to City in the City's latest adopted version of Microsoft Word and Excel. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the services in this Agreement, shall be kept confidential unless City authorizes the release of information. 20. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents his judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to City. 21. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against liability, including costs, for infringement of any United States' letters patent, trademark, or copyright infringement, including costs, contained in Consultant's drawings and specifications provided under this Agreement. 22. RECORDS Consultant shall keep records and invoices in connection with the work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant to this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records during regular business hours. Consultant shall allow inspection of all work, data, documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement. 23. WITHHOLDINGS City may withhold payment of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or his designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 10 0 0 24. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under any other sections of this Agreement. 25. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 26. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act'), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 27. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Robert Gunther Public Works Department City of Newport Beach 3300 Newport Boulevard Newport Beach, CA, 92658 -8915 Phone: 949- 644 -3311 Fax: 949 - 644 -3318 11 0 0 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Deborah McLean LSA Associates, Inc. 20 Executive Park, Suite 200 Irvine, Ca 92614 Phone: 949 - 553 -0555 Fax: 949 - 553 -8076 28. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provision, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all work prepared by Consultant shall conform to applicable City, county, state and federal laws, regulations and permit requirements and be subject to approval of the Project Administrator and City. 30. WAIVER A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 12 0 0 31. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the Parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 32. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 33. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 34. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 35. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 36. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. 13 IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: Aaron C. Harp, Assistant City Attorney for the City of Newport Beach ATTEST: By LaVonne Harkless, City Clerk CITY OF NEWPORT BEACH A Municipal Corpo�gon Ste�-eurIre Public Works for the City of Newport Beach LSA ASSOCIATES, INC.: By: //� ? (C%porate Officer) Title: Pke's �'� Print Name: /% /M C-� WA inancial Officer) e: G'�O Print Name: �IJ9�stU Attachments: Exhibit A - Statement of Qualifications Exhibit B - Schedule of Billing Rates f:\users\pbw\shared\agreements\fy 04-05\on-call agreements\lsa-archaeological.doc 14 June 21, 2005 Robert Gunther, Construction Engineer City of Newport Beach 3300 Newport Blvd. Newport Beach, CA 92658 -8915 Subject: Statement of Qualifications to Provide On -Call Archaeological Services for the City of Newport Beach, Orange County, California Dear Mr. Gunther: LSA Associates, Inc. (LSA) is pleased to respond to your request to provide a Statement of Qualifications (SOQ) for on -call archaeological services for the Capital Improvement Program of the City of Newport Beach, Orange County, California. LSA is a full- service environmental planning and impact assessment firm with nearly three decades of experience in cultural resource management throughout Southern Califomia. The Archaeology/Paleontology Group of LSA is composed of highly qualified professionals that will provide the City of Newport Beach with proactive, responsive, and expert services for the tasks requested. The LSA team will be led by Deborah McLean, M.A., RPA, with 21 years of professional experience in archaeology including 11 years in environmental impact analysis. LSA understands that this potential contract is for on -call archaeological services. The LSA Archaeology/Paleontology Group provides archaeological, historical, and paleontological consulting services that fulfill CEQA, NEPA, and local cultural resource requirements. LSA's staff archaeologists, project historians, and paleontologists have extensive experience and capabilities in archival and field research, as well as report preparation, having completed numerous public and private projects throughout California. Our personnel are accredited by the Society of Professional Archaeologists (RPA), as well as by various governmental agencies. All LSA field . monitors have extensive experience, averaging more than 7 years, in southern California Cultural Resource Management. x LSA looks forward to providing a full compliment of professional staff to meet the needs of the City of Newport Beach. We appreciate the opportunity to submit this SOQ. Please feel free to contact me at (949) 553 -0666 with any questions you may have, or email me at debbie.mclean@lsa- assoc.com. I look forward to hearing from you. 6/ 21 /05 <L:\PROPOSAL\=1035a11cover letw.wpd> PLANNING I ENVIRONMENTAL SCIENCES I DESIGN LEA ASSOC110, INC. BERRELO FORT COLLINS RIVERSIDE LJ 10 EXECUTIVE PARK. SUITE 200 949 553 0666 TEL CARLSBAD PALM SPRINGS ROCKLIN IRVINE, CALIFORNIA 92614 949 553.8076 FAX COLMA POINT RICHMOND SAN LUIS OBISPO EXHIBIT A June 21, 2005 Robert Gunther, Construction Engineer City of Newport Beach 3300 Newport Blvd. Newport Beach, CA 92658 -8915 Subject: Statement of Qualifications to Provide On -Call Archaeological Services for the City of Newport Beach, Orange County, California Dear Mr. Gunther: LSA Associates, Inc. (LSA) is pleased to respond to your request to provide a Statement of Qualifications (SOQ) for on -call archaeological services for the Capital Improvement Program of the City of Newport Beach, Orange County, California. LSA is a full- service environmental planning and impact assessment firm with nearly three decades of experience in cultural resource management throughout Southern Califomia. The Archaeology/Paleontology Group of LSA is composed of highly qualified professionals that will provide the City of Newport Beach with proactive, responsive, and expert services for the tasks requested. The LSA team will be led by Deborah McLean, M.A., RPA, with 21 years of professional experience in archaeology including 11 years in environmental impact analysis. LSA understands that this potential contract is for on -call archaeological services. The LSA Archaeology/Paleontology Group provides archaeological, historical, and paleontological consulting services that fulfill CEQA, NEPA, and local cultural resource requirements. LSA's staff archaeologists, project historians, and paleontologists have extensive experience and capabilities in archival and field research, as well as report preparation, having completed numerous public and private projects throughout California. Our personnel are accredited by the Society of Professional Archaeologists (RPA), as well as by various governmental agencies. All LSA field . monitors have extensive experience, averaging more than 7 years, in southern California Cultural Resource Management. x LSA looks forward to providing a full compliment of professional staff to meet the needs of the City of Newport Beach. We appreciate the opportunity to submit this SOQ. Please feel free to contact me at (949) 553 -0666 with any questions you may have, or email me at debbie.mclean@lsa- assoc.com. I look forward to hearing from you. 6/ 21 /05 <L:\PROPOSAL\=1035a11cover letw.wpd> PLANNING I ENVIRONMENTAL SCIENCES I DESIGN a5A AasoelATaS. In C. HOURLY BILLING RATES EFFECTIVE AUGUST 2005 The hourly tote for Nmrk involving actual expenses in court, giving depositions or similar expert testimony, will he billed at S ?50 per hour regardless of joh classifications_ L TORPkunoacl.dec OAV2005n • n U1 Job Classification Hourly Rate Planning Environmentol Trans orta0on Air/Nobe Cultural Resources Ellology 618 Range Principal Principal Principal Principal Principal Principal Principal $120 -225 Associate Associate Associate Associate Associate Associate Associate S75--175 Senior Planner Senior Senior Transportation Senior Air Senior Cultural Senior Biologist/ Hotanisv Senior GIs 575 -160 ' Environmental Plamser Planoer/Engincer Qaabtyl?loise Resource Manager Wildlife BiologeN Specialist Specialist Ecologisi/ Soil Scienlist/ HewevilogEsiLlArburid Planner EuvironmentalPlanner Transportation Air Quality/ Noise Cultural Resource I Biologist/ Botanist/ Wildlife 013 Specialist S 50.125 Piarmer/Engineer Specialist Alanager Biologist / Ecologis l Soil scimiLqU Herpetologist ArWdst Assistant Plammr _ Assistant Assistant Transperiation .Air Quality/ Noise Cultural Resource Assistant Biologist/ Assistant GIS S40-85 EnvironmentPlanner P]anner/Enginoer Analyst Analyst Bolmist/ Wildlife Biologist/ Speciaist Fcologisy Soil scientist/ He ecologist /Arberist Field Services Fidel Directur S50-100 SentorField Crow/Field Crew S35-75 Omee Services Research Assistawarrecnnielan S 21-50 Graphics S 70-100 Office Assistant S 40-75 Word ProcessingfFechnical Editing S fi0-90 The hourly tote for Nmrk involving actual expenses in court, giving depositions or similar expert testimony, will he billed at S ?50 per hour regardless of joh classifications_ L TORPkunoacl.dec OAV2005n • n U1 URA AAROCIATRA, INC, 0 LSA IN -HOUSE DIRECT EXPENSES 1.:ICoKKC0=CI.da Unit Cost Reproduction $0.10 per page Color Reproduction (8.5x11) $1.00 per page Color Reproduction (11x17) $3.00 por page Mileage Road $0.405 per milt Off road $0.555 per mile Facsimile $1.00 per page Plotting $5.00 per linear ft. Diazo Printing $0.20 per sq. ft. Film (developing billed separately as a direct cost) $5.00 per roll Disposable camera and fibu (developing billed separately as a direct cost) $10.00 per camera Search of Spccializcd Data Bases $100.00 per inquiry Pen map /QPS Unit $200.00 per day Arc map /GPS Unit $150.00 per day Aerial Photos $200.00 per photo 1.:ICoKKC0=CI.da &Mi ht/d: sllffil LSiSsoell ACORDN CERTIFIGA E OF LIABILITY INBU CE nr7ns °"" " PRODUCER Dealey, Renton & Associates P. O. Box 12675 Oakland, CA 94604 -2875 510 465 -3090 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THE CER17FICAV DOES NOTAMBNO. EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIL P 11111VESI) LsA Associates, Inc. 20 Executive Park, Suite 200, Wine, CA 92614 INSURER A' Greenwich Insurance Company INSURERS: Hartford Fire Ins, Co. INSURER c: American Automobile fns. Co, GECO019404 6eneralLiab Excludes Claims Arising Out Of The Performance of Professional Services wsURSaD: 31,040,1100 INSURER E: Sa00006 COVERAGES THE POUCIES OF INSURANCE LISTED BELOW RAVE SEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. TYPE DP WSURANCE POLICY NUMBER POUCYEFFECIWE 09130105 POUCTEXPBUTION 09/30/06 LIMAS A SRNERALLIAOIJrc X COMMERCIGLCENERALR.ABRITY CLAIMS MADE OCCUR GECO019404 6eneralLiab Excludes Claims Arising Out Of The Performance of Professional Services EACH OCCURRENCE 31,040,1100 DAMAOF TD RENTED MEDtXP ("IP n) Sa00006 ss.000 PERSONAL 6 A INJURY 21,000,000 G2NERP1.AGCREOATE 4$ 00 000 GENL AGGREGATE LIMB APPLIES PEI: X POLICY m 7111; LDC PRODUCTS- WMPfOp ACC ;200 000 B AU70MORILELIAGUM X X A AUTO ALL OWNED MR08 SCHEDULED AUTDS 14REDAVMS NON -OWNED AUTO$ 57UUNIF148a 0913OMS 09130/06 COMBINED SMLELMrr (Ed P &Frq $1,000,000 ' BODILYKXw R"er IrornM) 5 SOD -ZAIRY tPROPEPiV 5 X DAMAGE (fwwrxlenU S GARAOELIABIUW ANYAVTO AUTOONLY•EAAOOIDENT 5 OTHER THAN SJ, ACC. AUTO ONLY: AM 9 ; A P%CESSAIMSRELLA ArTILITY OCCUR LT1.IM9 MADE DECUCTIBLE RMWNON 5 UECO019403 09/30/05 09/30/06 EACHOCOURRENCE $1,000.0m AGGREGATE $1.800.001) S C WORIUM COMPENSATION AND EMPLOYERS' UMILRY ANY PROPRMTOR)PARTN0WXEOUTVE OFROERMEMBEREXCLUDEDT Ire gr YnBR WZP80933036 09!30105 09130!06 X wo rnru. 0TH• SJ -EACH ACCIDEM 0,900,000 E.L.DI$EASE- EAEMPLOYEE $1,000,000 E.I_DISEASE •Pd.IDY Lwn ;1000006 A CTHEn Professional Liability PECO0127003 09130/05 09130106 $2,000,000 per Claim $4,000,000 anrll aggr. OE$ORPTION OF OPERATIONS I LOCATIONS I VEHICLES ITDTOLUS.IOE8 ADDED SY ENDORSEMENT I SPECIAL PROWSIONS INSURAMCE AP U At RISK I A ""'"" SPECIMEN "xinY4k ANY OFTHE ABOVE DESCRIBED POUCIBS BE CANCELLED BEFORE THE EXPIRATION IERraTP,mEISSuwau wmm WTLLomrAYORmmAL _30_ DAY$WRTrw TO THE DERTIPMATE HOLOERNAMSO TO THE LEFT, BOTFAILURB TO POGO SMALL NO OBLIGATION OR LIABILITY OF ANY HIND UPON THE ENSURER, RS AGENTS OR 25 (2001108) 1 of t UNII IIaE31 "$ �""""' CCCt a ACORD CORPORATION 1986 CITY OF NEWPORT BEACH CITY COUNCIL STAFF REPORT Agenda Item No. 16 June 28, 2005 TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: Public Works Department Robert Gunther, P.E. 949 - 644 -3311 rgunther@city.newport-beach.ca.us SUBJECT: GEOTECHNICAL, SURVEYING AND MAPPING, ARCHEOLOGICAL, INSPECTION, AND ENVIRONMENTAL PLANNING /PERMITTING ON- CALL SERVICES - APPROVAL OF PROFESSIONAL SERVICES AGREEMENTS RECOMMENDATIONS: 1. Approve Professional Services Agreements with Harrington Geotechnical and Leighton and Associates for on -call geotechnical services and authorize the Mayor and City Clerk to execute the Agreements. 2. Approve Professional Services Agreements with Coast Surveying, Advance Survey Concepts, and Walden & Associates for on -call professional surveying and mapping services and authorize the Mayor and City Clerk to execute the Agreements. 3. Approve a Professional Services Agreement with LSA and Associates for on -call archeological services and authorize the Mayor and City Clerk to execute the Agreement. 4. Approve a Professional Services Agreement with Project Partners for on -call supplemental public works inspection services and authorize the Mayor and City Clerk to execute the Agreements. 5. Approve a Professional Services Agreement with J.H. Douglas & Associates for on- call environmental planning and permitting assistance and authorize the Mayor and City Clerk to execute the Agreements. DISCUSSION: Prior to the City Council meeting of November 26, 2002, geotechnical, survey, archeological, and supplemental inspection services were regularly required for many Capital Improvement Program (CIP) projects and a great number of small but time - consuming Professional Services Agreements (PSA's) were executed between the City SUBJECT: Geotechnical, Surveying And Mapping, Archeological, And Inspection On -Call Services - Approval Of Professional Services Agreements June 28, 2005 Page 2 and selected consultants to accomplish these on -going tasks. On November 26, 2002, City Council approved the use of on -call PSA's with one soils firm and with three surveying firms. Then on December 9, 2003, Council approved on -call PSA's for the use of eight firms, (two soils, three survey, one archeological and two inspection firms). These PSA's all expire on June 30, 2005. Over the last few years, these on -call PSA's have proven to be very effective and efficient. A request for qualifications was mailed to twelve firms to submit proposals and eight firms responded. Staff now recommends executing new PSA's with these eight firms as listed in the above recommendations, that is - two geotechnical firms, three surveying and mapping firms, one archeological firm, one supplemental public works inspection firm, and one environmental planning /permitting firm. To reduce time in preparing individual PSA's for each CIP project, staff is recommending negotiating with these select consultants to provide "as needed" services. Any other firms that may be used would have individual PSA's prepared for their work and if greater than $30,000 they would be brought to City Council for approval per Council Policy F -14. The City Council approved a Fiscal Year 2005/06 Citywide CIP, which totals over $30,000,000. More than 100 projects within the CIP will require some sort of geotechnical and survey services as well as occasional archeological, supplemental public works inspection services, or environmental permitting service. These services are funded for from the individual project budgets. On -Call Geotechnical Firms Harrington Geotechnical and Leighton and Associates have performed geotechnical services for more than 20 projects for the City over the past two years. The fee for their services is typically under $5,000 to perform either soil and base compaction or asphalt testing for a particular project. The firms have provided quality services to the City in the past. On -Call Surveying and Mappinq Firms: Similar on -call Professional Services PSA's are recommended for surveying and mapping services. The three recommended firms provide unique specialized services that can be tailored to the City's individual projects, and have provided the City with excellent services on previous projects. The City currently employs only one licensed surveyor who utilizes other City staff to complete survey requests. The City Surveyor is also involved with mapping, GIS coordination, and parcel map reviews, as well as other duties. With the renewal of the on -call survey services PSA's many of these services will be contracted with one of the above survey companies. On -Call Archeological Services: Archeological inspection and reports are required on a number of projects involving excavation, particularly on projects in coordination with Caltrans. LSA has provided timely inspections and reports on previous projects with the City. SUBJECT: Geotechnical, Surveying And Mapping, Archeological, And Inspection On -Call Services - Approval Of Professional Services Agreements June 28, 2005 Page 3 On -Call Supplemental Public Works Inspection Firms: Over the last four years staff has had to use two supplemental inspectors due to the heavy project loads on our three full -time staff inspectors. Project Partners has provided inspection services to the City for four years. Although the City's proposed new budget includes an additional staff Inspector, it will take some time to hire the new inspector and occasional use of a contract inspector may still be required. On -Call Environmental Planning and Permitting Service: Environmental permitting and planning assistance are often required in conjunction with the CIP because the City must comply with land use and environmental laws such as CEQA, and may be required to obtain permits from other public agencies. J.H. Douglas & Associates has provided timely services and assistance on previous projects with the City. Standard On -Call Professional Services Agreement: Attached is the standard PSA that was recently updated by the City Attorney's Office. The On -Call PSA with the geotechnical, survey, archeological, inspection, and environmental services firms is identical to the new standardized PSA's with the exception of Section 2 (Services to be Provided) and Section 4 (Compensation to the Consultant). These sections have been drafted to allow the consultant to provide services for multiple projects. The proposed On -Call PSA's would be effective through June 30, 2007. Funding Availability: Funds for these services are available in each of the specific project accounts within the City Council approved Capital Improvement Programs. Environmental Review: Environmental clearances will be completed for each Capital Improvement Project. Prepared by: ,a. Z" RGunther, P.E. Construction Engineer Submitted Stephen G. Badum Public Works Director Attachment: Draft On -Call Professional Services Agreement PROFESSIONAL SERVICES AGREEMENT WITH [INSERT NAME OF PERSON /COMPANY] FOR ON -CALL SERVICES FOR [INSERT PROJECT NAME] THIS AGREEMENT is made and entered into as of this day of , 2005, by and between the CITY OF NEWPORT BEACH, a municipal corporation ( "City "), and [INSERT COMPANY NAME], a [insert type of business, i.e., an individual, a partnership, a joint venture, a corporation or some other business entity] whose address is [insert address], California ( "Consultant "), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City is planning to [insert description of what is being planned]. C. City desires to engage Consultant to perform on -call [insert type of service Consultant provides i.e., geotechnical, engineering, etc.] services in various locations and for various City construction projects ( "Project'). D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal members] of Consultant for purposes of Project, shall be [insert name of Consultant]. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned Parties as follows: 1. TERM The term of this Agreement shall commence on the above written date, and shall terminate on the June day of 30th, 2007, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall provide "On -Call" [insert type of services] as described in the Statement of Qualifications attached as Exhibit "A." Upon verbal request from the Project Administrator, Consultant shall provide a letter proposal for services requested by the City (hereinafter referred to as the "Letter Proposal "). The Letter Proposal shall include a detailed description of services to be provided, the estimated cost and the time to complete the services, the estimated number of hours and the position of each person to be assigned to perform the services. No services shall be provided until the Public Works Department Director has provided written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall diligently perform the duties in the approved Letter Proposal. 3. TIME OF PERFORMANCE Time is of the essence in the performance of services under this Agreement and the services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the services on a time and expense not -to- exceed basis, in accordance with the provisions of this Section and the Schedule of Billing rates attached hereto as Exhibit "B" and incorporated herein by reference. No rate changes shall be made during the term of this Agreement without the prior written approval of the City. Consultant's compensation for services performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed the fees identified in the Letter E Proposal, as approved by the Public Works Department. A Letter Proposal fee shall not exceed $30,000 without City Council approval. 4.1 Consultant shall submit monthly invoices to City describing the work performed the preceding month. Consultant's bills shall include the name of the person and /or classification of employee who performed the work, a brief description of the services performed and /or the specific task in the letter proposal to which it relates, the date the services were performed, the number of hours spent on all work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in the Letter Proposal. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: A. The actual costs of subconsultants for performance of any of the services that Consultant agrees to render pursuant to this Agreement and the Letter Proposal, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and /or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work without the prior written authorization of City. As used herein, "Extra Work" means any work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Letter Proposal and which the parties did not reasonably anticipate would be necessary. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated [Insert Contact Name] to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 3 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. [Optional Provision] If Consultant is performing inspection or construction management services for City, the Project Manager and any other assigned staff shall be equipped with a Nextel Plus type cellular /direct connect unit to communicate with City staff. Consultant's Nextel Direct Connect I.D. number will be provided to City to be programmed into City Nextel units, and vice versa. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. [Insert Staff Person] shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his /her authorized representative shall represent City in all matters pertaining to the services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's work schedule. B. Provide blueprinting and other services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. 8. STANDARD OF CARE 8.1 All of the services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the services required by this Agreement, and that it will perform all services in a manner commensurate with community professional standards. All services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. 11 8.2 Consultant represents and warrants to City that it has or shall obtain all licenses, permits, qualifications, insurance and approvals of whatsoever nature that are legally required of Consultant to practice its profession. Consultant further represents and warrants to City that Consultant shall, at its sole cost and expense, keep in effect or obtain at all times during the term of this Agreement, any and all licenses, permits, insurance and other approvals that are legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 8.4 [Optional Provision] The term Construction Management or Construction Manager does not imply that Consultant is engaged in any aspect of the physical work of construction contracting. Consultant shall not have control over or be in charge of and shall not be responsible for the project's design, City's project contractor ( "Contractor"), construction means, methods, techniques, sequences or procedures, or for any health or safety precautions and programs in connection with the work. These duties are and shall remain the sole responsibility of the Contractor. Consultant shall not be responsible for the Contractors' schedules or failure to carry out the work in accordance with the contract documents. Consultant shall not have control over or be responsible for acts or omissions of City, Design Engineer, Contractor, Subcontractors, or their Agents or employees, or of any other persons performing portions of the work. 9. HOLD HARMLESS [OPTION A: For Use In All Contracts Except Those With Architects, Engineers And Surveyors] To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents and employees (collectively, the "Indemnified Parties ") from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any work performed or services provided under this Agreement (including, without limitation, defects in workmanship or materials and /or design defects [if the design originated with Consultant]) or Consultant's presence or activities conducted on the Project (including the negligent and /or willful acts, errors and /or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. [OPTION B: For Use With Design Professionals (Engineers, Surveyors And Architects)] To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents and employees (collectively, the "Indemnified Parties) from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims'), which may arise from or in any manner relate (directly or indirectly) to any work negligently performed or services provided under this Agreement (including, without limitation, defects in workmanship or materials and /or design defects [if the design originated with Consultant]) or Consultant's presence or activities conducted on the Project (including the negligent and /or willful acts, errors and /or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 11 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a mariner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator and /or his /her duly authorized designee informed on a regular basis regarding the status and progress of the work, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, a policy or policies of liability insurance of the type and amounts described below and in a form satisfactory to City. A. Certificates of Insurance. Consultant shall provide certificates of insurance with original endorsements to City as evidence of the insurance coverage required herein. Insurance certificates must be approved by City's Risk Manager prior to commencement of performance or issuance 7 of any permit. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. B. Signature. A person authorized by the insurer to bind coverage on its behalf shall sign certification of all required policies. C. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. D. Coverage Requirements. 1. Workers' Compensation Coverage. Consultant shall maintain Workers' Compensation Insurance and Employer's Liability Insurance for his or her employees in accordance with the laws of the State of California. In addition, Consultant shall require each subcontractor to similarly maintain Workers' Compensation Insurance and Employer's Liability Insurance in accordance with the laws of the State of California for all of the subcontractor's employees. Any notice of cancellation or non - renewal of all Workers' Compensation policies must be received by City at least thirty (30) days prior to such change. The insurer shall agree to waive all rights of subrogation against City, its officers, agents, employees and volunteers for losses arising from work performed by Consultant for City. 2. General Liability Coverage. Consultant shall maintain commercial general liability insurance in an amount not less than Two Million Dollars ($2,000,000) per occurrence for bodily injury, personal injury, and property damage, including without limitation, contractual liability. If commercial general liability insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply separately to the work to be performed under this Agreement, or the general aggregate limit shall be at least twice the required occurrence limit. 3. Automobile Liability Coverage. Consultant shall maintain automobile insurance covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than One Million Dollars ($1,000,000) combined single limit for each occurrence. 4. Professional Errors and Omissions Insurance. Consultant shall maintain professional errors and omissions insurance, which covers the services to be performed in connection with this Agreement in the minimum amount of One Million Dollars ($1,000,000). D. Endorsements. Each general liability and automobile liability insurance policy shall be endorsed with the following specific language: i. The City, its elected or appointed officers, officials, employees, agents and volunteers are to be covered as additional insureds with respect to liability arising out of work performed by or on behalf of the Consultant. ii. This policy shall be considered primary insurance as respects to City, its elected or appointed officers, officials, employees, agents and volunteers as respects to all claims, losses, or liability arising directly or indirectly from the Consultant's operations or services provided to City. Any insurance maintained by City, including any self- insured retention City may have, shall be considered excess insurance only and not contributory with the insurance provided hereunder. iii. This insurance shall act for each insured and additional insured as though a separate policy had been written for each, except with respect to the limits of liability of the insuring company. iv. The insurer waives all rights of subrogation against City, its elected or appointed officers, officials, employees, agents and volunteers. V. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to City, its elected or appointed officers, officials, employees, agents or volunteers. vi. The insurance provided by this policy shall not be suspended, voided, canceled, or reduced in coverage or in limits, by either party except after thirty (30) days written notice has been received by City. A. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claim made or suit instituted arising out of or resulting from Consultant's performance under this Agreement. B. Additional Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the work. 0 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint-venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint-venture. 16. SUBCONTRACTING The parties recognize that a substantial inducement to City for entering into this Agreement is the professional reputation, experience and competence of Consultant. Assignments of any or all rights, duties or obligations of the Consultant under this Agreement will be permitted only with the express written consent of City. Consultant shall not subcontract any portion of the work to be performed under this Agreement without the written authorization of City. 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed documents for other projects and any use of incomplete documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 19. COMPUTER DELIVERABLES CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with 10 (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by City in ".dwg" file format on a CD, and should comply with the City's digital submission requirements for Improvement Plans. The City will provide AutoCAD file of City Title Sheets. All written documents shall be transmitted to City in the City's latest adopted version of Microsoft Word and Excel. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the services in this Agreement, shall be kept confidential unless City authorizes the release of information. 20. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents his judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to City. 21. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against liability, including costs, for infringement of any United States' letters patent, trademark, or copyright infringement, including costs, contained in Consultant's drawings and specifications provided under this Agreement. 22. RECORDS Consultant shall keep records and invoices in connection with the work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant to this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records during regular business hours. Consultant shall allow inspection of all work, data, documents, 11 proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement. 23. WITHHOLDINGS City may withhold payment of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or his designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 24. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under any other sections of this Agreement. 25. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 26. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 27. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as 12 hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: R. Gunther Public Works Department City of Newport Beach 3300 Newport Boulevard Newport Beach, CA, 92658 -8915 Phone: 949 - 644 -3311 Fax: 949 - 644 -3318 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: [Insert Name of Consultant] [Insert Address] [City and Zip Code] Phone: Fax: 28. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provision, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all work prepared by Consultant shall conform to applicable City, county, state and federal laws, regulations and permit requirements and be subject to approval of the Project Administrator and City. 13 30. WAIVER A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 31. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the Parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 32. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 33. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 34. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 35. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 36. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. &I IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: By: Aaron C. Harp, Assistant City Attorney for the City of Newport Beach ATTEST: in LaVonne Harkless City Clerk CITY OF NEWPORT BEACH A Municipal Corporation Stephen G. Badum, Public Works Director for the City of Newport Beach [Name of Consultant] la Attachments: Exhibit A — Statement of Qualifications Exhibit B — Schedule of Billing Rates f:\ users \CAnshared%agreement \on -call agreement template.doc 15 PROFESSIONAL SERVICES AGREEMENT WITH LSA ASSOCIATES, INC. FOR ON -CALL ARCHEOLOGICAL SERVICES THIS AGREEMENT is made and entered into as of this ql�__ day of 2004, by and between the CITY OF NEWPORT BEACH, a municipal corporation City "), and LSA ASSOCIATES, INC., an Environmental Firm whose address is 20 Executive Park, Suite 200, Irvine, California, 92614 -4731 ( "Consultant'), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to cant' on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City is planning to implement an approximate 30 Million Dollar ($30,000,000.00) capital improvement program. C. City desires to engage Consultant to perform on -call archeological services in various locations and for various City construction projects ('Project'). D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal member[s] of Consultant for purposes of Project, shall be Steve Conkling. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned Parties as follows: 1. TERM The term of this Agreement shall commence on the day of , 2004, and shall terminate on the 30th day of June, 2005, unless terminated earlier as set forth herein. 2. SERVICES TO BE Consultant shall provide "On -Call' Archeological Services as described in the Statement of Qualifications attached as Exhibit °A ". Upon verbal request from the Project Administrator, Consultant shall provide a letter proposal for services requested by the City. The letter proposal shall include a detailed description of 0 0 services to be provided, the estimated cost and the time to complete the services, the estimated number of hours and the position of each person to be assigned to perform the services contained in the letter proposal. No services shall be provided until the City has provided written acceptance of the letter proposal. Consultant shall diligently perform the duties in the approved letter. 3. TIME OF PERFORMANCE Time is of the essence in the performance of services under this Agreement and the services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by either telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the services in accordance with the provisions of this Section and the scheduled billing rates set forth in Exhibit "B" attached hereto and incorporated herein by reference. No rate changes shall be made during the term of this Agreement without prior written approval of the City. Consultant's compensation for services performed in accordance with this Agreement shall not exceed the approved fees identified in the letter proposals. A letter proposal fee shall not exceed $30,000 without City Council Approval. 4.1 Consultant shall submit monthly invoices to City describing the work performed the preceding month. Consultant's bills shall include the name of the person and/or classification of employee who performed the work, a brief description of the services performed and /or the specific task in the Letter Proposal to which it relates, the date the services were performed, the number of hours spent on all work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in this Agreement, or specifically approved in advance by City. 2 E Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: A. The actual costs of subconsultants for performance of any of the services that Consultant agrees to render pursuant to this Agreement, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and/or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work without the prior written authorization of City. As used herein, "Extra Work" means any work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Letter Proposal and which the parties did not reasonably anticipate would be necessary. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Steve Conkling to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. Robert Gunther shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his /her authorized representative shall represent City in all matters pertaining to the services to be rendered pursuant to this Agreement. 3 • 7. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's work schedule. B. Provide blueprinting and other services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. 8. STANDARD OF CARE 8.1 All of the services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the services required by this Agreement, and that it will perform all services in a manner commensurate with community professional standards. All services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. 8.2 Consultant represents and warrants to City that it has or shall obtain all licenses, permits, qualifications, insurance and approvals of whatsoever nature that are legally required of Consultant to practice its profession. Consultant further represents and warrants to City that Consultant shall, at its sole cost and expense, keep in effect or obtain at all times during the term of this Agreement, any and all licenses, permits, insurance and other approvals that are legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents and employees (collectively, the "Indemnified Parties ") from and against any and all ll 0 claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any work negligently performed or services provided under this Agreement (including, without limitation, defects in workmanship or materials and/or design defects [if the design originated with Consultant]) or Consultant's presence or activities conducted on the Project (including the negligent and /or willful acts, errors and /or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and project direction with City's Project Administrator in advance of all critical decision points in I.7 i order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator and /or his/her duly authorized designee informed on a regular basis regarding the status and progress of the work, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of work. Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, a policy or policies of liability insurance of the type and amounts described below and in a form satisfactory to City. A. Certificates of Insurance. Consultant shall provide certificates of insurance with original endorsements to City as evidence of the insurance coverage required herein. Insurance certificates must be approved by City's Risk Manager prior to commencement of performance or issuance of any permit. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. B. Signature. A person authorized by the insurer to bind coverage on its behalf shall sign certification of all required policies. C. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of Califomia, with an assigned policyholders' Rating of A (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. D. Coverage Requirements. Workers' Compensation Coverage. Consultant shall maintain Workers' Compensation Insurance and Employer's Liability Insurance for his or her employees in accordance with the laws of the State of California. In addition, Consultant shall require each subcontractor to similarly maintain Workers' Compensation Insurance and Employers Liability Insurance in accordance with the laws of the State of California for all of the subcontractors employees. Any notice of cancellation or non - renewal of all Workers' Compensation policies must be received by City at least thirty (30) days prior to such change. The insurer shall agree to waive all rights of subrogation against City, its officers, agents, employees and volunteers for losses arising from work performed by Consultant for City. 2 • 2. General Liability Coverage. Consultant shall maintain commercial general liability insurance in an amount not less than Two Million Dollars ($2,000,000) per occurrence for bodily injury, personal injury, and property damage, including without limitation, contractual liability. If commercial general liability insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply separately to the work to be performed under this Agreement, or the general aggregate limit shall be at least twice the required occurrence limit. 3. Automobile Liability Coverage. Consultant shall maintain automobile insurance covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than One Million Dollars ($1,000,000) combined single limit for each occurrence. 4. Professional Errors and Omissions Insurance. Consultant shall maintain professional errors and omissions insurance, which covers the services to be performed in connection with this Agreement in the minimum amount of One Million Dollars ($1,000,000). D. Endorsements. Each general liability and automobile liability insurance policy shall be endorsed with the following specific language: The City, its elected or appointed officers, officials, employees, agents and volunteers are to be covered as additional insureds with respect to liability arising out of work performed by or on behalf of the Consultant. This policy shall be considered primary insurance as respects to City, its elected or appointed officers, officials, employees, agents and volunteers as respects to all claims, losses, or liability arising directly or indirectly from the Consultant's operations or services provided to City. Any insurance maintained by City, including any self- insured retention City may have, shall be considered excess insurance only and not contributory with the insurance provided hereunder. iii. This insurance shall act for each insured and additional insured as though a separate policy had been written for each, except with respect to the limits of liability of the insuring company. iv. The insurer waives all rights of subrogation against City, its elected or appointed officers, officials, employees, agents and volunteers. V. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to City, its elected or appointed officers, officials, employees, agents or volunteers. 7 • L, vi. The insurance provided by this policy shall not be suspended, voided, canceled, or reduced in coverage or in limits, by either party except after thirty (30) days written notice has been received by City. A. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claim made or suit instituted arising out of or resulting from Consultant's performance under this Agreement. B. Additional Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the work. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint-venture. 16. SUBCONTRACTING The parties recognize that a substantial inducement to City for entering into this Agreement is the professional reputation, experience and competence of Consultant. Assignments of any or all rights, duties or obligations of the Consultant under this Agreement will be permitted only with the express written consent of City. Consultant shall not subcontract any portion of the work to be performed under this Agreement without the written authorization of City. 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed documents for other projects and any use of incomplete documents without specific written authorization 0 0 from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 18. COMPUTER DELIVERABLES CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by City in ".dwg" file format on a CD, and should comply with the City's digital submission requirements for Improvement Plans. The City will provide AutoCAD file of City Title Sheets. All written documents shall be transmitted to City in the City's latest adopted version of Microsoft Word and Excel. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the services in this Agreement, shall be kept confidential unless City authorizes the release of information. 20. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents his judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to City. 21. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against liability, including costs, for infringement of any United States' letters patent, trademark, or copyright infringement, including costs, contained in Consultant's drawings and specifications provided under this Agreement. 0 22. RECORDS 0 Consultant shall keep records and invoices in connection with the work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant to this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records during regular business hours. Consultant shall allow inspection of all work, data, documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement. 23. WITHHOLDINGS City may withhold payment of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or his designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 24. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under any other sections of this Agreement. 25. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 26. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for termination of this 10 0 0 Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 27. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Robert Gunther Public Works Department City of Newport Beach 3300 Newport Boulevard Newport Beach, CA, 92658 -8915 Phone: 949- 644 -3311 Fax: 949 - 644 -3318 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Steve Conkling LSA Associates, Inc. 20 Executive Park, Suite 200 Irvine, CA 92614 -4731 Phone: 949 - 553 -0666 Fax: 949 - 553 -8076 28. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provision, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 11 • 29. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all work prepared by Consultant shall conform to applicable City, county, state and federal laws, regulations and permit requirements and be subject to approval of the Project Administrator and City. 30. WAIVER A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 31. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the Parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 32. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 33. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 34. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 35. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 36. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. 12 IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: 7W. 64) Robin Clauson, Assistant City Attorney for the City of Newport Beach ATTEST: BvZ LaVonne Har less CITY Clerk CITY OF NEWPORT BEACH A Municipal Corporation By: �'` } Tod W. Ridgeway Mayor for the City of Newport Beach LSA ASSOCIATES, INC. By: c. tri Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates f:\users\pbw\shared\agreements\fy 03-04\on-call agreements\lsa-on call archeological.doc 13 LSA November 24, 2003 LIPASSOCIATES, INC. 20 EXECUTIVE PARE, SUITE 200 IRVINE, CALIFORNIA 92614 -4731 Robert Gunther City of Newport Beach 3300 Newport Boulevard, P. O. Box 1768 Newport Beach, California 92660 • 949.553.0666 TEL 949.553$076 PAZ OTHER OFFICES: FT. COLLINS EERRELIV RIVERSIDE PT. RICHMOND ROCKLIN Exhibit "A" Subject: Statement of Qualifications for Capital Improvement Projects in the City of Newport Beach, California Dear Mr. Gunther: LSA Associates, Inc. (LSA) is pleased to submit this Statement of Qualifications to the City of Newport Beach (City) to provide On -Call Archaeological Services for various Capital Improvement Projects. LSA was founded by Larry Seeman in 1976, and has an extensive history providing environmental compliance for clients throughout California. LSA is a diversified environmental, transportation, and community planning firm that employs experts in cultural and paleontological resources compliance, environmental analysis, transportation planning and engineering, biology and wetlands, habitat restoration, geographical information systems (GIS), community and land planning, and noise and air quality. LSA's Archaeology/Paleontology Division staff of 60 individuals have extensive experience in management of southern California cultural and paleontological resources. Our staff has direct expertise helping municipalities develop and implement ordinances and standard conditions as they relate to cultural and paleontological resources. Our archaeologists, historians and architectural historians are accredited by the Register of Professional Archaeologists, and other professional societies. LSA also has Orange County Certified Archaeologists and Paleontologists on staff. The Archaeology/Paleontology Division provides archaeological, historical, and paleontological consulting services that fulfill the requirements of the California Environmental Quality Act (CEQA), the National Environmental Policy Act (NEPA), the National Historic Preservation Act (as promulgated in Section 106), and the cultural resource requirements of the City of Newport Beach. Broadly speaking, we identify cultural resources and evaluate their significance during a project's planning and environmental phases, then develop implementable procedures to protect or mitigate any adverse effects to cultural resources. 11120103(LAPROPOSAL \CNB On -Call Archaeompd) PLANNING I ENVIRONMENTAL SCIENCES I DESIGN i • LEA ASSOCIATES, INC. Typical services include: • Archaeological archival reviews • Historical archival studies • Reconnaissance Cultural Resource Surveys • Intensive Assessment Surveys • Cultural resource inventories • Historic properties surveys • Historical overviews • Architectural recording • Evaluation and Nomination of resources for the National Register of Historic Places • Historical cultural resources testing • Implement prehistorical cultural resource evaluation investigations • Implement historical data recovery excavations • Implement prehistorical data recovery excavations • Paleontological surveys • Paleontological salvage • Grading monitoring for archaeological resources • Grading monitoring for paleontological resources • Preservation plans • Interpretive displays for cultural and paleontological resources • Education programs for cultural and paleontological resources • Cultural resource policy and procedure programs LSA Cultural and Paleontological Resources staff are supplied with Nextel Cellular Phones and alpha - numeric pagers to ensure rapid response to the needs of our clients. LSA will provide archaeologists (or other appropriate specialists) to any need of the City within one hour of notification during the regular work week (Monday through Friday, 7:30 AM to 5:30 PM). For weekend, evening, or holiday call -outs (if prior notification has not been given), LSA will respond with qualified staff within 4 hours of notification by the City. For notification purposes, email or voice mail to (949) 553- 1566 x274 or steve.conkling @lsa- assoc.com will immediately page we to activate our response. I aOioa(L:\rROPOSAL\CNS On -Cali Arcnaeo.wpd) • LSA ASSOCIAT85, INC. • If we can be of any further questions about our Statement of Qualifications, please contact me at (949) 553 -0666 or via e-mail at steve.conkling @lsa- assoc.com. Sincerely, LSA ASSOCIATES, INC. e Conkl' g, Principal Cultural an aleontological Resources Group Attachments: Tab 1 - Local Staffing List (Organizational Chart) Tab 2 - List of Public Agency Work performed in the Last Five Years Tab 3 - Advance Notice Requirements Tab 4 - Resumes of Key Personnel Tab 5 - References Tab 6 - Fee Schedule 1120 /03(L:TROPOSAL \CNB On -Cal] Archwo.wpin Exhibit "B" LSA AS S OCIATES.INC. CULTURAL AND PALEONTOLOGICAL RESOURCES RATE SHEET NOVEMBER 2008 HOURLY BILLING RATES EFFECTIVE AUGUST 2003 Job Classification Cultural Resources Hourly Rate Range Principal $120 -225 Associate $ 75 -160 Senior Cultural Resource Manager $ 75 -160 Cultural Resource Manager $ 50-125 Cultural Resource Analyst $ 40-85 Field Director $ 50 -100 Senior Field Crew/Field $ 35 -75 Research Assistant/Technician $ 25 -50 Graphics $ 70-100 Office Assistant $ 40-75 Word Processing $60—SS The hourly rate for work involving actual expenses in court, giving depositions or similar expert testimony, will be billed at $250 per hour regardless ofjob classifications. LEA ASSOCIATES. INC. • LSA IN-HOUSE DIRECT EXPENSES LACORP \Cull Rate Shectdoc a] 124/03» 7 Unit Cost Reproduction $0.10 per page Color Reproduction (8.5x11) $1.00 per page Color Reproduction (11x17) $3.00 per page Mileage Road $0.36 per mile Off -road $0.51 per mile Facsimile $1.00 per page Plotting $5.00 per linear ft. Diazo Printing $0.20 per sq. ft. Film (developing billed separately as a direct cost) $5.00 per roll Disposable camera and film (developing billed separately as a direct cost) $10.00 per camera Search of Specialized Data Bases $100.00 per inquiry Pen map /GPS Unit $200.00 per day Are map /GPS Unit $150.00 per day Aerial Photos $200.00 per photo LACORP \Cull Rate Shectdoc a] 124/03» 7 JAN- 09- 2004�F+ 161. A.M . FAX N0. 0 F Fax ! `[ -!� ��� 3 ,31 O CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach. P. 01/01 Date Received: Dept-/Contact Received From: A C "__ Date Completed: f - U!- O Sent to: 1LL� M_ By: & a Company /Person required to have certificate: L5A lA-' 5 a r-W -t s - GENERAL LIABILITY A. INSURANCE COMPANY: a. AM BEST RATING (A: VII C. ADMITTED Company (Must be California Admitted): Is Company admitted In California? ayes [] No D. LIMITS (Must be $1 M or greater): What is limit provided? a +"r+ E. PRODUCTS AND COMPLETED OPERATIONS (Must include): Is it included? tStjes L7 No F. ADDtTIONAL INSURED WORDING TO INCLUDE (The City its officers, officials, employees and volunteers): is it included? k1fes C] No G. PRIMARY & NON - CONTRIBUTORY WORDING (Must be included): Is it included? (ryes El No H. CAUTION! (Confirm that loss or liability of the named Insured is not limited solely by their negligence) Does endorsement Include "solely by negligence" wording? L] Yes Co I. NOTIFICATION OF CANCELLATION: Although there is a provision that requires notification of cancellation by certified mail; per Lauren Farley, the City will accept the endeavor wording. 11, AUTOMOBILE LIABILITY A. INSURANCE COMPANY: Q6::4 1 yip —0-t Y71 144 -XST B. AM BEST RATING (A: VII or greater): f1� C. ADMITTED COMPANY (Must be California Admitted): Yes [] No Is Company admitted in CalWomia? "r D. LIMITS (Must be $1 M min. BI & PD and $500,000 UM): What is limits provided? E. ADDITIONAL INSURED WORDING TO INCLUDE (The City its fvryLs (] No officers, officials, employees and volunteers): is it included? F. PRIIM nR Y &d NON- CONTRIBUTORY WORDING (For Waste Haulers only): r) la is Yes L] No G. NOTIFICATION OF CANCELLATION: Although there is a provision that requires notification of cancellation by certified mail; per Lauren Farley, the City will accept the endeavor wording. 1R. WORKERS' COMPENSATION A. INSURANCE COMPANY: }V YYL I G6+�, 6 �Q -.nT 60 B. AM BEST RATING (A: VII or greater): x C. LIMITS: Statutory Yes [] No D. WAIVER OF SUBROGATION (To include). Is it included? HAVE ALL ABOVE REQUIREMENTS BEEN MET? )(Yes F1 No IF NO, VyHIC ITEMS TEMS NEED TO BE COMPLETED? CITY OF NEWPORT BEACH CITY COUNCIL STAFF REPORT Agenda Item No. 21 December 9, 2003 TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: Public Works Department Robert Gunther, P.E. 949 - 644 -3311 rgunther@city.newport-beach.ca.us SUBJECT: GEOTECHNICAL, SURVEYING AND MAPPING, ARCHEOLOGICAL, AND INSPECTION ON -CALL SERVICES - APPROVAL OF PROFESSIONAL SERVICES AGREEMENTS RECOMMENDATIONS: Approve Professional Services Agreements with Harrington Geotechnical and Leighton and Associates for on -call geotechnical services and authorize the Mayor and City Clerk to execute the Agreements. 2. Approve Professional Services Agreements with Coast Surveying, Duca- McCoy, and Advanced Survey Services for on -call professional surveying and mapping services and authorize the Mayor and City Clerk to execute the Agreements. 3. Approve a Professional Services Agreement with LSA and Associates for on -call archeological services and authorize the Mayor and City Clerk to execute the Agreement. 4. Approve a Professional Services Agreements with Project Partners and Hubell Technical Services for on -call supplemental public works inspection services and authorize the Mayor and City Clerk to execute the Agreements. DISCUSSION: Prior to the Council meeting of November 26, 2002, geotechnical, survey, archeological and supplemental inspection services were regularly required for many projects and a great number of small but time - consuming Professional Services Agreements (PSA's) were executed between the City and selected consultants to accomplish these on -going tasks. On November 26, 2002, Council approved the use of on -call PSA's with one soils firm and with three surveying firms. Those Agreements have expired. Due to the tremendous efficiencies of using the on -call PSA's, staff now recommends executing SUBJECT: Geotechnical, Surveying And Mapping, Archeological, And Inspection On -Call Services - Approval Of Professional Services Agreements December 9, 2003 Page 2 new agreements with an expanded list of firms as listed in the Recommendations Section above, that is - two geotechnical firms, three surveying and mapping firms, one archeological firm, and two supplemental public works inspection firms. To reduce time in preparing individual agreements for each CIP project, staff is recommending negotiating with these select consultants to provide "as needed" services. Any other firms that may be used would have individual agreements prepared for their work and if greater than $30,000 they would be brought to Council for approval. The City Council approved a Fiscal Year 2003/04 City Wide Capital Improvement Program (CIP), which totals over $33,000,000. More than 100 projects within the CIP will require some sort of geotechnical and survey services as well as occasional archeological or supplemental public works inspection services. These services are paid for from the individual project budgets. On -Call Geotechnical Firms: Harrington Geotechnical and Leighton and Associates have performed geotechnical services for more than 20 projects for the City over the past two years. The fee for their services is typically under $5,000 to perform either soil and base compaction or asphalt testing for a particular project. The firms have provided quality services to the City in the past. On -Call Surveying and Mapping Firms: Similar on -call Professional Services Agreements are recommended for surveying and mapping services. All three recommended firms provide unique specialized services that can be tailored to the City's individual projects, and have provided the City with excellent services on previous projects. The City currently employs only one licensed surveyor who utilizes other City staff to complete his survey.party. In house City survey is only done for selected projects with critical schedules and limited scope of work. The City surveyor is also involved with mapping, GIS coordination, and parcel map reviews, as well as other duties. With the renewal of the On -Call Survey Services Agreements, many of these services will be contracted with one of the above survey companies. On -Call Archeological Services: Archeological inspection and reports are required on a number of projects involving excavation, most recently on the Newport Boulevard - Balboa Boulevard Rehabilitation project and most projects in coordination with Caltrans. LSA has provided timely inspections and reports on previous projects with the City. On -Call Supplemental Public Works Inspection Firms: Over the last two years staff has had to use two supplemental inspectors due to the heavy project loads on our three full -time staff inspectors. Both inspection firms proposed are recommended and Project Partners has provided inspection services to the City in the last year. SUBJECT: Geotechnical, Surveying And Mapping, Archeological, And Inspection On -Call Services - Approval Of Professional Services Agreements December 9, 2003 Page 3 Standard On -Call Professional Services Agreement: This is the standard agreement form that was recently updated by the City Attorney's Office. The On -Call PSA with the geotechnical, survey, archeological and inspection services firms is identical to the new standardized Professional Services Agreements with the exception of Section 2 (Services to be Provided) and Section 4 (Compensation to the Consultant). These sections have been drafted to allow the consultant to provide services for multiple projects. Note - any services requiring expenditures more than $30,000 for an individual project will require a separate City Council action in accordance with Policy F -14. The proposed On -Call PSA attached to this item, would be effective through June 30, 2005. Fundina Availability: Funds for these services are available in each the specific project accounts within the City Council approved Capital Improvement Programs. Environmental Review: Environmental clearances will be completed for each Capital Improvement Project. Prepared by: Submitted by: R: Gunther, P.E. S h G. Badum Construction Engineer Publi.�Works Director Attachment: Sample Standard On -Call Professional Services Agreement SAMPLE PROFESSIONAL SERVICES AGREEMENT WITH FOR ON -CALL SERVICES THIS AGREEMENT is made and entered into as of this day of , 2003, by and between the CITY OF NEWPORT BEACH, a municipal corporation ( "City "), and , a corporation whose address is , CA ( "Consultant'), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City is planning to implement an approximate $30 million dollar Capital Improvement Program for FY03 /04. C. City desires to engage Consultant to perform on -call in various locations and for various City projects. services D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal member of Consultant for purposes of Project, shall be F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned Parties as follows: 1. TERM The term of this Agreement shall commence on the day of 2003, and shall terminate on the _ day of 20_, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall provide "On -Call' Support Services as described in their Statement of Qualifications, attached as Exhibit "A ". Upon verbal request from Contract Administrator, consultant shall provide letter proposals for services requested by the City. The letter proposal shall include the estimated cost and time to complete the services, including the estimated number of hours and position for each person assigned to perform the services contained in the letter proposal. No Services shall be provided until the City has provided written acceptance of the letter proposal. Consultant shall diligently perform the duties in the approved letter. 3. TIME OF PERFORMANCE Time is of the essence in the performance of services under this Agreement and the services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by either telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the services in accordance with the provisions of this Section and the scheduled billing rates set forth in Exhibit "B" attached hereto and incorporated herein by reference. No rate changes shall be made during the term of this Agreement without prior written approval of City. Consultant's compensation for services performed in accordance with this Agreement shall not exceed the approved fees identified in the letter proposals. A letter proposal fee shall not exceed $30,000.00 without City Council approval. 4.1 Consultant shall submit monthly invoices to City describing the work performed the preceding month. Consultant's bills shall include the name of the person and /or classification of employment who performed the work, a brief description of the services performed and /or the specific task in the Scope of Services to which it relates, the date the services were performed, the number of hours spent on all work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay 2 Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in this Agreement, or specifically approved in advance by City. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: A. The actual costs of subconsultants for performance of any of the services that Consultant agrees to render pursuant to this Agreement, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and /or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work without the prior written authorization of City. As used herein, "Extra Work" means any work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. Robert Gunther shall be the Project Administrator and shall have the authority to act for 3 7 [M City under this Agreement. The Project Administrator or his /her authorized representative shall represent City in all matters pertaining to the services to be rendered pursuant to this Agreement. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution Agreement, City agrees to, where applicable: A. Provide access to, and upon request existing relevant information on file at materials in a timely manner so as not work schedule. of its responsibilities under this of Consultant, one copy of all City. City will provide all such to cause delays in Consultant's B. Provide blueprinting and other services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. STANDARD OF CARE 8.1 All of the services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the services required by this Agreement, and that it will perform all services in a manner commensurate with community professional standards. All services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. 8.2 Consultant represents and warrants to City that it has or shall obtain all licenses, permits, qualifications, insurance and approvals of whatsoever nature that are legally required of Consultant to practice its profession. Consultant further represents and warrants to City that Consultant shall, at its sole cost and expense, keep in effect or obtain at all times during the term of this Agreement, any and all licenses, permits, insurance and other approvals that are legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's work promptly, or delay or faulty performance by City, contractors, or governmental agencies. W 9. HOLD HARMLESS To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents and employees (collectively, the "Indemnified Parties') from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any work negligently performed or services provided under this Agreement (including, without limitation, defects in workmanship or materials and /or design defects [if the design originated with Consultant]) or Consultant's presence or activities conducted on the Project (including the negligent and /or willful acts, errors and /or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or 5 12. 13. irl interest in the work to be performed. City agrees to cooperate with the Consultant on the Project. CITY POLICY Consultant shall discuss and review all matters relating to policy and project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. PROGRESS Consultant is responsible for keeping the Project Administrator and /or his /her duly authorized designee informed on a regular basis regarding the status and progress of the work, activities performed and planned, and any meetings that have been scheduled or are desired. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of work. Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, a policy or policies of liability insurance of the type and amounts described below and in a form satisfactory to City. B. Certificates of Insurance. Consultant shall provide certificates of insurance with original endorsements to City as evidence of the insurance coverage required herein. Insurance certificates must be approved by City's Risk Manager prior to commencement of performance or issuance of any permit. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. C. Signature. A person authorized by the insurer to bind coverage on its behalf shall sign certification of all required policies. D. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. E. Coverage Requirements. Workers' Compensation Coverage. Consultant shall maintain Workers' Compensation Insurance and Employer's Liability Insurance for his or her employees in accordance with the laws of the State of California. In addition, Consultant shall require each Q subcontractor to similarly maintain Workers' Compensation Insurance and Employers Liability Insurance in accordance with the laws of the State of California for all of the subcontractors employees. Any notice of cancellation or non - renewal of all Workers' Compensation policies must be received by City at least thirty (30) days prior to such change. The insurer shall agree to waive all rights of subrogation against City, its officers, agents, employees and volunteers for losses arising from work performed by Consultant for City. 2. General Liability Coverage. Consultant shall maintain commercial general liability insurance in an amount not less than Two Million Dollars ($2,000,000) per occurrence for bodily injury, personal injury, and property damage, including without limitation, contractual liability. If commercial general liability insurance or other form with a general aggregate limit is used, either the general aggregate limit shall apply separately to the work to be performed under this Agreement, or the general aggregate limit shall be at least twice the required occurrence limit. 3. Automobile Liability Coverage. Consultant shall maintain automobile insurance covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than One Million Dollars ($1,000,000) combined single limit for each occurrence. 4. Professional Errors and Omissions Insurance. Consultant shall maintain professional errors and omissions insurance, which covers the services to be performed in connection with this Agreement in the minimum amount of One Million Dollars ($1,000,000). F. Endorsements. Each general liability and automobile liability insurance policy shall be endorsed with the following specific language: i. The City, its elected or appointed officers, officials, employees, agents and volunteers are to be covered as additional insureds with respect to liability arising out of work performed by or on behalf of the Consultant. ii. This policy shall be considered primary insurance as respects to City, its elected or appointed officers, officials, employees, agents and volunteers as respects to all claims, losses, or liability arising directly or indirectly from the Consultant's operations or services provided to City. Any insurance maintained by City, including any self- insured retention City may have, shall be considered excess 7 insurance only and not contributory with the insurance provided hereunder. iii. This insurance shall act for each insured and additional insured as though a separate policy had been written for each, except with respect to the limits of liability of the insuring company. iv. The insurer waives all rights of subrogation against City, its elected or appointed officers, officials, employees, agents and volunteers. V. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to City, its elected or appointed officers, officials, employees, agents or volunteers. vi. , The insurance provided by this policy shall not be suspended, voided, canceled, or reduced in coverage or in limits, by either party except after thirty (30) days written notice has been received by City. G. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claim made or suit instituted arising out of or resulting from Consultant's performance under this Agreement. H. Additional Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the work. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 16. SUBCONTRACTING The parties recognize that a substantial inducement to City for entering into this Agreement is the professional reputation, experience and competence of Consultant. Assignments of any or all rights, duties or obligations of the Consultant under this Agreement will be permitted only with the express written 0 consent of City. Consultant shall not subcontract any portion of the work to be performed under this Agreement without the written authorization of City. 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultants expense, provide such Documents to City upon written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed documents for other projects and any use of incomplete documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 18. COMPUTER DELIVERABLES CADD data delivered to City shall include the professional stamp of the engineer or architect in charge of or responsible for the work. City agrees that Consultant shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the modification or misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy or readability of CADD data due to inappropriate storage conditions or duration; or (c) any use by City, or anyone authorized by City, of CADD data for additions to this Project, for the completion of this Project by others, or for any other Project, excepting only such use as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to indemnify Consultant for damages and liability resulting from the modification or misuse of such CADD data. All original drawings shall be submitted to City in the version of AutoCAD used by City in ".dwg" file format on a CD, and should comply with the City's digital submission requirements for Improvement Plans. The City will provide AutoCAD file of City Title Sheets. All written documents shall be transmitted to City in the City's latest adopted version of Microsoft Word and Excel. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the services in this Agreement, shall be kept confidential unless City authorizes the release of information. a 20. OPINION OF COST Any opinion of the construction cost prepared by Consultant represents his judgment as a design professional and is supplied for the general guidance of City. Since Consultant has no control over the cost of labor and material, or over competitive bidding or market conditions, Consultant does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to City. 21. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against liability, including costs, for infringement of any United States' letters patent, trademark, or copyright infringement, including costs, contained in Consultant's drawings and specifications provided under this Agreement. 22. RECORDS Consultant shall keep records and invoices in connection with the work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant to this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records during regular business hours. Consultant shall allow inspection of all work, data, documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement. 23. WITHHOLDINGS City may withhold payment of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or his designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 24. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the work accomplished by Consultant, the additional design, construction and /or 10 restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under any other sections of this Agreement. 25. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 26. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 27. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: R. Gunther Public Works Department City of Newport Beach 3300 Newport Boulevard Newport Beach, CA, 92658 -8915 Phone: 949 - 644 -3325 Fax: 949 - 644 -3318 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Company: Address: Phone: Fax: 11 28. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provision, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 29. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all work prepared by Consultant shall conform to applicable City, county, state and federal laws, regulations and permit requirements and be subject to approval of the Project Administrator and City. 30. WAIVER A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 31. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the Parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 32. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 12 33. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 34. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 35. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 36. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: Robin Clauson, Assistant City Attorney for the City of Newport Beach ATTEST: M LaVonne Harkless CITY Clerk CITY OF NEWPORT BEACH A Municipal Corporation M CONSULTANT 0 Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates f: \users\pbwJshared \agreements \blank -on -call services.doc 13