Loading...
HomeMy WebLinkAboutC-4034 - PSA for Newport Bay-Related Consulting1 AMENDMENT NO. 1 TO PROFESSIONAL SERVICES AGREEMENT WITH TOM ROSSMILLER FOR NEWPORT BAY - RELATED CONSULTING THIS AMENDMENT NO. 1 TO PROFESSIONAL SERVICES AGREEMENT, is entered into as of this �Ifh day of _ 70 2010, by and between the CITY OF NEWPORT BEACH, a Municipal Corporati ( "CITY"), and TOM ROSSMILLER an individual whose address is 209 Keystone Way, Eagle Point, OR 97524 ( "CONSULTANT), and is made with reference to the following: RECITALS: A. On March 31, 2008, CITY and CONSULTANT entered into a Professional Services Agreement, hereinafter referred to as "AGREEMENT," to assist the Harbor Resources Manager on issues such as the Harbor Area Management Plan, Upper and Lower Newport Bay dredging, eelgrass, harbor fee issues, moorings, and inter - agency agreements regarding the harbor, hereinafter referred to as "PROJECT." B. CITY desires to enter into this AMENDMENT NO. 1 to extend the term of the AGREEMENT to December 31, 2010 and to increase the total compensation. C. CITY desires to compensate CONSULTANT for additional professional services needed for PROJECT. D. CITY and CONSULTANT mutually desire to amend AGREEMENT, hereinafter referred to as "AMENDMENT NO. 1," as provided here below. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of the AGREEMENT shall be extended to December 31, 2010. 1.1 Consultant shall not work more than 960 hours during the Term of this Agreement in accordance with CaIPERS post retirement employment guidelines, as outlined below. The Employee shall be responsible for monitoring the hours worked during these time periods. 1.2 Consultant may work for a CalPERS- covered public agency without reinstatement from retirement into active employment, per Government Code section 2122(h), if all of the following conditions are met: a. Consultant has specialized skills needed to perform work of limited duration or his /her employment is needed during an emergency to prevent stoppage of public business; 0 b. Consultant's temporary employment will not exceed 960 -hours in a fiscal year (July 15'through June 30"'); and C. Consultant's rate of pay received will not be less than the minimum, nor exceed the maximum that is paid to other employees performing comparable duties. 2. COMPENSATION City shall pay Consultant for the services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached to the AGREEMENT at an hourly rate of Sixty Two Dollars and 30/100 ($62.30). Consultant's total amended compensation for all work performed in accordance with this Agreement and all amendments thereto, including all reimbursable items and subconsultant fees, shall not exceed One Hundred Thirty One Thousand Dollars and no /100 ($131,000) without prior written authorization from City. 2.1 The amended compensation reflects Consultant's additional compensation for additional services to be performed in accordance with this AMENDMENT NO. 1, including all reimbursable items and subconsultant fees, in an amount not to exceed Twenty Three Thousand Dollars and no /100 ($23,000.00), without prior written authorization from City. 3. INTEGRATED CONTRACT Except as expressly modified herein, all other provisions, terms, and covenants set forth in AGREEMENT shall remain unchanged and shall be in full force and effect. N IN WITNESS WHEREOF, the parties hereto have executed this AMENDMENT NO. 1 on the date first above written. APPROVED AS TO FORM: OFFICE OF THE CITY ATTORNEY By: David R. Hunt City Attorney ATTEST: Leilani I. Brown, � City Clerk (>i10 -0-(I Attachments: CITY OF NEWPORT BEACH, A Municipal Corporation By: Keith Curry Mayor CONSULTANT: Tom Rossmiller B t -4)72744k Y• Tom Rossmiller '16 91- FOR Exhibit A — Sco-qpTTMervices Exhibit B — Schedule of Billing Rates K Exhibit A Scope of Services Tom Rossmiller shall provide consulting, advice, attendance at meetings and teleconferences, and other tasks as directed by the Harbor Resources Manager with the following issues: • Upper Newport Bay Dredging • Lower Newport Bay Dredging • Eelgrass • Moorings • Harbor Fee Study • Inter - Agency Agreements within the Harbor and Bay • And more, as needed. 4 • Exhibit B Schedule of Billing Rates 40 1. Tom Rossmiller's hours worked shall be billed at $62.30 per hour. 2. Tom Rossmiller may use the City's payroll system to record his hours. 3. Travel and meetings shall be funded at the discretion of the Harbor Resources Manager and the Assistant City Manager. 0 CITY OF NEWPORT BEACH CITY COUNCIL STAFF REPORT THE Cm OF NEWP Agenda Item No. 9 January 12, 2010 TO: . , HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: City Manager's Office Sharon Wood, Assistant City Manager (949) 644 -3222, swood @newportbeachca.gov Chris Miller, Harbor Resources Manager (949) 644 -3043, cmiller @newportbeachca.gov SUBJECT: Authorization to Retain Tom Rossmiller (retired employee) on a Part-Time Basis ISSUE: Should the City continue to retain Tom Rossmiller, a retired City employee, for consulting services related to Newport Bay issues? RECOMMENDATION: Authorize the City Manager and City Clerk to execute Amendment No. 1 to the Professional Services Agreement for part-time work associated with Newport Bay for a not to exceed cost of $23,000. DISCUSSION: Council Policy F -20 requires City Council approval before the City may hire a retired City employee for work if that person has been retired for fewer than five (5) years. Tom Rossmiller, former Harbor Resources Manager, had worked for the City for about five years, having served previously with the County of Orange as a Coastal Engineer for about 30 years, often in the context of working on the Upper and Lower Newport Bays. Tom Rosmiller has been consulting for the City for nearly two years. Tom Rossmiller's current role with Harbor Resources is diminishing but his assistance is still needed occasionally with a few key projects including: • Upper Newport Bay Dredging • Lower Newport Bay Dredging • Eelgrass • Moorings • Harbor Fee Study • Inter - Agency Agreements within the Harbor and Bay • And more, as needed. PSA with Tom Rossmiller January 12, 2010 Page 2 TERMS OF THE AGREEMENT: Tom Rossmiller is proposing to work approximately 360 hours at the same hourly rate as provided in his current contract ($63.20), for a total cost of not more than $23,000. This Professional Services Agreement will commence immediately and expire on December 31, 2010. Funding has been budgeted in FY 2009 -10, account 2371 -8080 for $23,000. ENVIRONMENTAL REVIEW: The City Council's approval of this Agenda Item does not require environmental review. PUBLIC NOTICE: This agenda item has been noticed according to the Ralph M. Brown Act (72 hours in advance of the public meeting at which the City Council considers the item). Submitted by: Sharon Wood Assistant City Manager Prepared by: /.Y 014 Chris Miller Harbor Resources Manager Attachments: Amendment No.1 to Professional Services Agreement 0 0 AMENDMENT NO. 1 TO PROFESSIONAL SERVICES AGREEMENT WITH TOM ROSSMILLER FOR NEWPORT BAY - RELATED CONSULTING THIS AMENDMENT NO. 1 TO PROFESSIONAL SERVICES AGREEMENT, is entered into as of this day of , 2010, by and between the CITY OF NEWPORT BEACH, a Municipal Corporation ( "CITY"), and TOM ROSSMILLER an individual whose address is 209 Keystone Way, Eagle Point, OR 97524 ( "CONSULTANT"), and is made with reference to the following: RECITALS: A. On March 31, 2008, CITY and CONSULTANT entered into a Professional Services Agreement, hereinafter referred to as "AGREEMENT," to assist the Harbor Resources Manager on issues such as the Harbor Area Management Plan, Upper and Lower Newport Bay dredging, eelgrass, harbor fee issues, moorings, and inter - agency agreements regarding the harbor, hereinafter referred to as "PROJECT." B. CITY desires to enter into this AMENDMENT NO. 1 to extend the term of the AGREEMENT to December 31, 2010 and to increase the total compensation. C. CITY desires to compensate CONSULTANT for additional professional services needed for PROJECT. D. CITY and CONSULTANT mutually desire to amend AGREEMENT, hereinafter referred to as "AMENDMENT NO. 1," as provided here below. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of the AGREEMENT shall be extended to December 31, 2010. 1.1 Consultant shall not work more than 960 hours during the Term of this Agreement in accordance with CalPERS post retirement employment guidelines, as outlined below. The Employee shall be responsible for monitoring the hours worked during these time periods. 1.2 Consultant may work for a CalPERS- covered public agency without reinstatement from retirement into active employment, per Government Code section 2122(h), if all of the following conditions are met: a. Consultant has specialized skills needed to perform work of limited duration or his/her employment is needed during an emergency to prevent stoppage of public business; 0 0 b. Consultant's temporary employment will not exceed 960 -hours in a fiscal year (July 1st through June 30`h); and C. Consultant's rate of pay received will not be less than the minimum, nor exceed the maximum that is paid to other employees performing comparable duties. 2. COMPENSATION City shall pay Consultant for the services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached to the AGREEMENT at an hourly rate of Sixty Two Dollars and 30/100 ($62.30). Consultant's total amended compensation for all work performed in accordance with this Agreement and all amendments thereto, including all reimbursable items and subconsultant fees, shall not exceed One Hundred Thirty One Thousand Dollars and no /100 ($131,000) without prior written authorization from City. 2.1 The amended compensation reflects Consultant's additional compensation for additional services to be performed in accordance with this AMENDMENT NO. 1, including all reimbursable items and subconsultant fees, in an amount not to exceed Twenty Three Thousand Dollars and no /100 ($23,000.00), without prior written authorization from City. 3. INTEGRATED CONTRACT Except as expressly modified herein, all other provisions, terms, and covenants set forth in AGREEMENT shall remain unchanged and shall be in full force and effect. 2 r 0 IN WITNESS WHEREOF, the parties hereto have executed this AMENDMENT NO. 1 on the date first above written. APPROVED AS TO FORM: CITY OF NEWPORT BEACH, OFFICE OF THE CITY ATTORNEY A Municipal Corporation By: David R. Hunt City Attorney ATTEST: By: Leilani I. Brown, City Clerk Attachments: 22 Keith Curry Mayor CONSULTANT: Tom Rossmiller in Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates 3 Tom Rossmiller Cl Exhibit A Scope of Services 0 Tom Rossmiller shall provide consulting, advice, attendance at meetings and teleconferences, and other tasks as directed by the Harbor Resources Manager with the following issues: • Upper Newport Bay Dredging • Lower Newport Bay Dredging • Eelgrass • Moorings • Harbor Fee Study • Inter - Agency Agreements within the Harbor and Bay • And more, as needed. S 0 Exhibit B Schedule of Billing Rates 0 1. Tom Rossmiller's hours worked shall be billed at $62.30 per hour. 2. Tom Rossmiller may use the City's payroll system to record his hours. 3. Travel and meetings shall be funded at the discretion of the Harbor Resources Manager and the Assistant City Manager. • ` 0140 1 PROFESSIONAL SERVICES AGREEMENT WITH TOM ROSSMILLER FOR NEWPORT BAY - RELATED CONSULTING THIS AGREEMENT is made and entered into as of this 31st day of March, 2008, by and between the CITY OF NEWPORT BEACH, a Municipal Corporation ( "City "), and TOM ROSSMILLER an individual, whose address is 27621 Niguel Village Drive, Laguna Niguel, California, 92677 ( "Consultant'), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City is planning to retain consultant services relating to Newport Bay. C. City desires to engage Consultant to assist the Harbor Resources Manager on issues such as the Harbor Area Management Plan, Upper and Lower Newport Bay Dredging, Eelgrass, Harbor Fee Issues, Moorings, and Inter - Agency Agreements regarding the Harbor ( "Project'). D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal member[s] of Consultant for purposes of Project, shall be Mr. Thomas Rossmiller. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the above written date, and shall last at most 21 months and shall terminate on the 315t day of December, 2009, unless terminated earlier as set forth herein. 0 0 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference. The City may elect to delete certain tasks of the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE Time is of the essence in the performance of services under this Agreement and the services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the services to be provided for the Project, each party hereby agrees to provide notice to the other parry so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by either telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed One Hundred Eight Thousand Dollars and no /100 ($108,000.00) without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.1 Consultant shall submit monthly invoices to City describing the work performed the preceding month. Consultant's bills shall include the name of the person who performed the work, a brief description of the services performed and /or the specific task in the Scope of Services to which it 2 relates, the date the services were performed, the number of hours spent on all work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in this Agreement, or specifically approved in writing in advance by City. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: A. The actual costs of subconsultants for performance of any of the services that Consultant agrees to render pursuant to this Agreement, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and /or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated TOM ROSSMILLER to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. c 0 • 6. ADMINISTRATION This Agreement will be administered by the HARBOR RESOURCES DIVISION within the CITY MANAGER'S OFFICE as the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his /her authorized representative shall represent City in all matters pertaining to the services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's work schedule. B. Provide blueprinting and other services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. S. STANDARD OF CARE 8.1 All of the services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the services required by this Agreement, and that it will perform all services in a manner commensurate with community professional standards. All services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. By delivery of completed work, Consultant certifies that the work conforms to the requirements of this Agreement and all applicable federal, state and local laws and the professional standard of care. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force in effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 2 0 0 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 8.4 The term Construction Management or Construction Manager does not imply that Consultant is engaged in any aspect of the physical work of construction contracting. Consultant shall not have control over or be in charge of and shall not be responsible for the project's design, City's project contractor ( "Contractor'), construction means, methods, techniques, sequences or procedures, or for any health or safety precautions and programs in connection with the work. These duties are and shall remain the sole responsibility of the Contractor. Consultant shall not be responsible for the Contractors' schedules or failure to carry out the work in accordance with the contract documents. Consultant shall not have control over or be responsible for acts or omissions of City, Design Engineer, Contractor, Subcontractors, or their Agents or employees, or of any other persons performing portions of the work. 9. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the services. 10. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the work to be performed. City agrees to cooperate with the Consultant on the Project. R 11 11. CITY POLICY • Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 12. PROGRESS Consultant is responsible for keeping the Project Administrator and /or his /her duly authorized designee informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 13. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 14. SUBCONTRACTING The parties recognize that a substantial inducement to City for entering into this Agreement is the professional reputation, experience and competence of Consultant. Assignments of any or all rights, duties or obligations of the Consultant under this Agreement will be permitted only with the express written consent of City. Consultant shall not subcontract any portion of the work to be performed under this Agreement without the prior written authorization of City. 15. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon prior written request. 3 0 0 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 16. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the services in this Agreement, shall be kept confidential unless City authorizes in writing the release of information. 17. RECORDS Consultant shall keep records and invoices in connection with the work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 18. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or his /her designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 7 0 0 19. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the work accomplished by Consultant, the additional design, construction and/or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under the law or any other sections of this Agreement. 20. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 21. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 22. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Harbor Resources Manager Harbor Resources Division City of Newport Beach 829 Harbor Island Drive Newport Beach, CA, 92660 Phone: 949 - 644 -3034 Fax: 949 - 723 -0589 I3 • • All notices, demands, requests or approvals from CITY to Consultant shall be addressed to Consultant at: Attention: Tom Rossmiller 27621 Niguel Village Drive Laguna Niguel, CA 92677 Phone: (949) 831-8452 23. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provisions, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 24. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 25. WAIVER A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach V 0 of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 26. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 27. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 28. INTERPRETATION The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 30. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 31. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 32. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. 10 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: t)F ! City Attorney° for the City of Newport Beach ATTEST:` By: (5� LaVonne Harkless, City Clerk CITY OF NEWPORT BEACH, A Municipal Corporation By: ity Manager for the City of Newport Beach CONSULTANT: By:/D'� �& Tom Rossmiller Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates 11 0 Exhibit A Scope of Services 0 Consulting, advice, meetings, teleconferences, and directed tasks under the supervision of the Harbor Resources Manager and other City staff and officials regarding the following issues: • Upper Newport Bay Dredging • Lower Newport Bay Dredging • Eelgrass • Moorings • Harbor Fee Study • Inter- Agency Agreements within the Harbor and Bay • And more, as needed. 12 0 0 Exhibit B Schedule of Billing Rates • Hours worked shall be billed at $62.30 /hour. • Mr. Rossmiller may use the City's payroll system to record his hours. • Travel and meetings shall be funded at the discretion of the Harbor Resources Manager and the Assistant City Manager. 13 • .rnewvonreEAt�l CITY OF NEWPORT BEACH CITY COUNCIL STAFF REPORT (* /10-2X19) Agenda Item No. S23 March 25, 2008 TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: City Manager's Office Dave Kiff, Assistant City Manager 949/644 -3002 or dkiff @city.newport- beach.ca.us SUBJECT: Authorization to Retain Tom Rossmiller (retired employee) on a Part-Time Basis ISSUE: Should the City retain Tom Rossmiller, about to retire from the City from his position as Harbor Resources Manager, for services relating to Newport Bay issues? RECOMMENDATION: • Authorize the City Manager to execute a Professional Services Agreement in substantially similar form to the attached with Mr. Tom Rossmiller for part-time work associated with Newport Bay. DISCUSSION: City Council Policy F -20 (attached) requires City Council approval before the City may hire a retired City employee for work if that person has been retired for less than five (5) years. Harbor Resources Manager Tom Rossmiller has worked for the City for about five years, having served previously with the County of Orange as a Coastal Engineer for about 29 years, often in the context of working on the Upper and Lower Newport Bays. There are several issues that the City desires Tom to continue to work on, on a part-time and as needed basis, for a period of time as the new Harbor Resources Manager becomes more familiar with the same issues. These include: • Upper Newport Bay Dredging • Lower Newport Bay Dredging ■ Eelgrass • Moorings • Harbor Fee Study • Inter - Agency Agreements within the Harbor and Bay • And more, as needed. • If the City retains Tom for this work, Tom can only work up to 960 hours on an annual basis. He would make the same hourly rate that he makes upon his retirement ($62.30 /hour). It is not • • PSA with Tom Rossmiller March 25, 2008 Page 2 envisioned that the City would need Tom's services for too long, but this recommendation • suggests authorizing us up through December 31, 2009 for such services (equal to 21 months). Environmental Review: The City Council's approval of this Agenda Item does not require environmental review. Public Notice: This agenda item may be noticed according to the Brown Act (72 hours in advance of the public meeting at which the City Council considers the item). Funding: While staff is requesting authorization for up to 21 months' work from Tom, the work is part time and highly variable. Further, Tom has expressed an interest in genuinely retiring. Much depends on the skill and experience of the new Harbor Resources Manager. Someone relatively new to the issues may need to rely upon Tom's counsel more often. Someone with great familiarity with the Bay and experience less so. Staff believes that the cost of Tom's work can be addressed through salary savings, and, if needed, the existing budget allocations within 8080 (Professional and Technical Services) accounts. Prepared and Submitted by: Dave Kiff Assistant City Manager • Attachments: Draft Professional Services Agreement (Rossmiller) Council Policy F -20 n U • PSA with Tom Rossmiller March 25, 2008 Page 3 • PROFESSIONAL SERVICES AGREEMENT WITH TOM ROSSMILLER FOR NEWPORT BAY - RELATED CONSULTING THIS AGREEMENT is made and entered into as of this 31st day of March, 2008, by and between the CITY OF NEWPORT BEACH, a Municipal Corporation ( "City"), and TOM ROSSMILLER an individual, whose address is 27621 Niguel Village Drive, Laguna Niguel, California, 92677 ( "Consultant'), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City is planning to retain consultant services relating to Newport Bay. C. City desires to engage Consultant to assist the Harbor Resources Manager on • issues such as the Harbor Area Management Plan, Upper and Lower Newport Bay Dredging, Eelgrass, Harbor Fee Issues, Moorings, and Inter - Agency Agreements regarding the Harbor ( "Project'). D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal member[s] of Consultant for purposes of Project, shall be Mr. Thomas Rossmiller. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the above written date, and shall last at most 21 months and shall terminate on the 31st day of December, 2009, unless terminated earlier as set forth herein. • 2. SERVICES TO BE PERFORMED 3. 4. • • PSA with Tom RossmWer March 25, 2008 Page 4 is Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference. The City may elect to delete certain tasks of the Scope of Services at its sole discretion. TIME OF PERFORMANCE Time is of the essence in the performance of services under this Agreement and the services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable • time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by either telephone, fax, hand - delivery or mail. COMPENSATION TO CONSULTANT City shall pay Consultant for the services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed One Hundred Eight Thousand Dollars and no /100 ($108,000.00) without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.1 Consultant shall submit monthly invoices to City describing the work performed the preceding month. Consultant's bills shall include the name of the person who performed the work, a brief description of the services • performed and /or the specific task in the Scope of Services to which it • PSA with Tom Rossmiller March 25, 2008 Page 5 • relates, the date the services were performed, the number of hours spent on all work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in this Agreement, or specifically approved in writing in advance by City. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: A. The actual costs of subconsultants for performance of any of the services that Consultant agrees to render pursuant to this Agreement, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and/or other costs and /or payments specifically authorized in advance in writing and incurred by Consultant in the is performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated TOM ROSSMILLER to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. • Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of services upon written request of City. 6. • • PSA with Tom Rossmiller March 25, 2008 Page 6 Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. ADMINISTRATION This Agreement will be administered by the HARBOR RESOURCES DIVISION within the CITY MANAGER'S OFFICE as the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his /her authorized representative shall represent City in all matters pertaining to the services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's work schedule. 1r, u B. Provide blueprinting and other services through City's reproduction • company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. STANDARD OF CARE 8.1 All of the services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the services required by this Agreement, and that it will perform all services in a manner commensurate with community professional standards. All services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. By delivery of completed work, Consultant certifies that the work conforms to the requirements of this Agreement and all applicable federal, state and local laws and the professional standard of care. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force in effect during the term hereof, at its sole cost and • expense, all licenses, permits, qualifications, insurance and approvals of • • PSA with Tom RossmWer March 25, 2008 Page 7 • whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 8.4 The term Construction Management or Construction Manager does not imply that Consultant is engaged in any aspect of the physical work of construction contracting. Consultant shall not have control over or be in charge of and shall not be responsible for the project's design, City's project contractor ( "Contractor "), construction means, methods, techniques, sequences or procedures, or for any health or safety precautions and programs in connection with the work. These duties are and shall remain the sole responsibility of the Contractor. Consultant shall not be responsible for the Contractors' schedules or failure to carry out the • work in accordance with the contract documents. Consultant shall not have control over or be responsible for acts or omissions of City, Design Engineer, Contractor, Subcontractors, or their Agents or employees, or of any other persons performing portions of the work. 9. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the services. 10. COOPERATION • Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or • • PSA with Tom Rossmitter March 25, 2008 Page 8 interest in the work to be performed. City agrees to cooperate with the Consultant on the Project. 11. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 12. PROGRESS Consultant is responsible for keeping the Project Administrator and/or his/her duly authorized designee informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 13. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty-five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 14. SUBCONTRACTING The parties recognize that a substantial inducement to City for entering into this Agreement is the professional reputation, experience and competence of Consultant. Assignments of any or all rights, duties or obligations of the Consultant under this Agreement will be permitted only with the express written consent of City. Consultant shall not subcontract any portion of the work to be performed under this Agreement without the prior written authorization of City. 1S. OWNERSHIP OF DOCUMENTS • Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of • implementing this Agreement, shall become the exclusive property of City, and • • • PSA with Tom Rossmiller March 25, 2008 Page 9 City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon prior written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 16. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the services in this Agreement, shall be kept confidential unless City authorizes in writing the release of information. • 17. RECORDS Consultant shall keep records and invoices in connection with the work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 18. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue work as a result of such withholding. Consultant • shall have an immediate right to appeal to the City Manager or his /her designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its • PSA with Tom Rossmfller March 25, 2008 Page 10 investments during the time period, from the date of withholding of any amounts • found to have been improperly withheld. 19. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under the law or any other sections of this Agreement. 20. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 21. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such • persons to disclose any financial interest that may foreseeably be materially affected by the work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 22. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Harbor Resources Manager Harbor Resources Division • City of Newport Beach CJ • • PSA with Tom Rossmiller March 25, 2008 Page 11 829 Harbor Island Drive Newport Beach, CA, 92660 Phone: 949 - 644 -3034 Fax: 949 - 723 -0589 All notices, demands, requests or approvals from CITY to Consultant shall be addressed to Consultant at: Attention: Tom Rossmiller 27621 Niguel Village Drive Laguna Niguel, CA 92677 Phone: (949) 831 -8452 23. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to • give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provisions, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 24. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all work prepared by Consultant shall conform to applicable City, • county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. • • PSA with Tom Rossmiller March 25, 2008 Page 12 25. WAIVER • A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 26. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 27. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 28. INTERPRETATION • The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 30. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 31. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. • • • PSA with Tom Rossra ler March 25, 2008 Page 13 • 32. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: City Attorney for the City of Newport Beach ATTEST: CITY OF NEWPORT BEACH, A Municipal Corporation as City Manager for the City of Newport Beach CONSULTANT: By: By: • LaVonne Harkless, Tom Rossmiller City Clerk Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates • • • PSA with Tom Rossmiller March 25, 2008 Page 14 Exhibit A Scope of Services Consulting, advice, meetings, teleconferences, and directed tasks under the supervision of the Harbor Resources Manager and other City staff and officials regarding the following issues: • Upper Newport Bay Dredging • Lower Newport Bay Dredging • Eelgrass • Moorings • Harbor Fee Study • Inter - Agency Agreements within the Harbor and Bay • And more, as needed. • r1 U • • PSA with Tom Rossmiller March 25, 2008 Page 15 • Exhibit B Schedule of Billing Rates • Hours worked shall be billed at $62.30 /hour. • Mr. Rossmiller may use the City's payroll system to record his hours. • Travel and meetings shall be funded at the discretion of the Harbor Resources Manager and the Assistant City Manager. n U • • • F -20 • CONTRACTS WITH FORMER CTTY EMPLOYEES To establish a city policy regarding contracting with former city employees. POLICY When not more than 5 years has passed since a person who is a former City employee has left service with the City: 1. All professional services contracts with former city employees or temporary employment contracts with retiring or former city employees shall require approval of the City Council; and 2. Council approval shall also be required for professional services contracts with a corporation or other business entity owned or operated by a former City employee or that employs a former City employee. Adopted - November 10, 1997 Amended - March 9,1998 Amended - March 22, 1"9 Amended - April 8,20D3 Formerly J -1 • 1 •