Loading...
HomeMy WebLinkAboutC-4624 - PSA for Newport Beach Bridge Seismic Retrofit ProjectPROFESSIONAL SERVICES AGREEMENT WITH AECOM TECHNICAL SERVICES, INC. FOR NEWPORT BEACH BRIDGE SEISMIC RETROFIT PROJECT THIS AGREEMENT FOR PROFESSIONAL SERVICES ( "Agreement') is made and entered into as of this P-1,11 day of Q`11 , 2010, by and between the CITY OF NEWPORT BEACH, a California Municipal Corporation ( "City "), and AECOM TECHNICAL SERVICES, INC., a California Corporation whose address is 999 Town & Country Road, Orange, California, 92868 ( "Consultant "), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City plans to perform seismic retrofits on three bridges: Goldenrod Pedestrian Overcrossing, Jamboree Road over San Diego Creek (Northbound) and Jamboree Road over San Diego Creek (Southbound). C. City desires to engage Consultant to provide construction management services for the Bridge Seismic Retrofit Project ( "Project!). D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. . The principal member of Consultant for purposes of Project, shall be Peter Lim. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the above written date, and shall terminate on the 31St day of December, 2011, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ( "Work" or "Services "). The City may elect to delete certain tasks of the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE Time is of the essence in the performance of Services under this Agreement and the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the Services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by either telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the Services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed One Hundred Eighty -Six Thousand, Six Hundred Seventy -Three Dollars and 94/100 ($186,673.94) without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.1 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and /or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in this Agreement, or specifically approved in writing in advance by City. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: Professional Services Agreement Page 2 A. The actual costs of subconsultants for performance of any of the Services that Consultant agrees to render pursuant to this Agreement, which have been approved in advance by City and awarded in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and /or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated JIM HANNIGAN to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. TOM SANDEFUR, or his designee, shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his authorized representative shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: Professional Services Agreement Page 3 A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. B. Provide blueprinting and other Services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards. All Services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement and all applicable federal, state and local laws and the professional standard of care. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force in effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers and employees (collectively, the "Indemnified Parties) from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, Professional Services Agreement Page 4 attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, .suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them. Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator and/or his /her duly authorized designee informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. Professional Services Agreement Page 5 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. A. Proof of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation. Insurance certificates and endorsement must be approved by City s Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this contract. City reserves the right to require complete, certified copies of all required insurance policies, at any time. Consultant shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damages to property, which may arise from or in connection with the performance of the Work hereunder by Consultant, his agents, representatives, employees or suibconsultants. The cost of such insurance shall be included in Consultant's bid. B. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner .a- transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. C. Coverage Requirements Workers' Compensation Coverage. Consultant shall maintain Workers' Compensation Insurance (Statutory Limits) and Employer's Liability Insurance (with limits of at least one million dollars ($1,000,000)) for Consultant's employees in accordance with the laws of the State of California, Section 3700 of the Labor Code In addition, Consultant shall require each subconsultant to similarly maintain Workers' Compensation Insurance and Employer's Liability Insurance in accordance with the laws of the State of California, Section 3700 for all of the subconsultant's employees. Any notice of cancellation or non - renewal of all Workers' Compensation policies must be received by City at least thirty (30) calendar days (ten (10) calendar days written notice of non- payment of premium) prior to such change. Professional Services Agreement Page 6 Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. ii. General Liability Coverage. Consultant shall maintain commercial . general liability insurance in an amount not less than one million dollars ($1,000,000) per occurrence for bodily injury, personal injury, and property damage, including without limitation, blanket contractual liability. iii. Automobile Liability Coverage. Consultant shall maintain automobile insurance covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit for each accident. iv. Professional Liability (Errors & Omissions) Coverage. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) limit per claim and in the aggregate. D. . Other Insurance Provisions or Requirements. 'The policies are to contain, or be endorsed to contain, the following provisions: i. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants. ii. Enforcement of Contract Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of the City to inform Consultant of non - compliance with any requirement imposes no additional obligations on the City nor does it waive any rights hereunder. iii. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party Professional Services Agreement Page 7 or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. iv. Notice of Cancellation. Consultant agrees to oblige its insurance agent or broker and insurers to provide to City with thirty (30) days notice of cancellation (except for nonpayment for which ten (10) days notice is required) or nonrenewal of coverage for each required coverage. E. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement. F. Additional Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint - venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty - five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 16. SUBCONTRACTING City and Consultant agree that subconsultants may be used to complete the Work outlined in the Scope of Services. The subconsultants authorized by City to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of the subcontractor. Nothing in this Agreement shall create any contractual relationship between City and subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. The City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and the City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its Professional Services Agreement Page 8 officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon prior written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 18. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City authorizes in writing the release of information. 19. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement of any United States' letters patent, trademark, or copyright infringement, including costs, contained in Consultant's drawings and specifications provided under this Agreement. 20. RECORDS Consultant shall keep records and invoices in connection with the Work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 21. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an Professional Services Agreement Page 9 immediate right to appeal to the City Manager or his /her designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 22. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under the law or any other sections of this Agreement. 23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 24. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 25. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Tom Sandefur Public Works Department City of Newport Beach 3300 Newport Boulevard PO Box 1768 Newport Beach, CA 92658 Phone: 949 - 644 -3312 Fax: 949 - 644 -3318 Professional Services Agreement Page 10 All notices, demands, requests or approvals from CITY to Consultant shall be addressed to Consultant at: Attention: Jim Hannigan AECOM Technical Services, Inc. 999 Town & Country Road Orange, CA 92868 Phone: 714- 567 -2501 Fax: 714 - 567 -2594 26. CLAIMS The Consultant and the City expressly agree that in addition to any claims filing requirements set forth in the Contract and Contract documents, the Consultant shall be required to file any claim the Consultant may have against the City in strict conformance with the Tort Claims Act (Government Code sections 900 et seq.). 27. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provisions, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 28. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. Professional Services Agreement Page 11 29. WAIVER A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 30. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 31. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 32. INTERPRETATION The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 1010 11Pd4►101 PtlX101116'? This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 34. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 35. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 36. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shalt not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Professional Services Agreement Page 12 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: OFFICE OF THE CITY ATTORNEY: By: ;�:� q / -2& eonie Mulvihill I I r Iry �( Assistant City Attorney `\ ATTEST: � A,r' By: wf'�l, Leilani I. Brown, City Clerk Attach mer its CITY OF NFWPORT BOCH, A Municip I C rpgratiorj/ IN Michael F. Henn Mayor CONSULTANT: AECOM TECHNICAL SERVIC 4C-. By: ( Nk:�s Peter Lim, Senior Vice President By: -Et e-6�' Wo t+ ffiv 6041z— Vice President F -Il -it A — Scope of Services Exhibit B — Schedule of Billing Rates Professional Services Agreement Page 13 EXHIBI TA A=COM August 13, 2010 Tom Sandefur, PE Associate Civil Engineer City of Newport Beach Public Works Department 3300 Newport Boulevard Newport Beach, CA 92663 -3884 AECOM 714.567.2400 tel 999 Town & Country Road 714.285.0740 fax orange, CA 92868 www.aecom.00m RE: Proposal for Construction Management Services for Newport Beach Bridge Seismic Retrofit Projects, Contract No. 3531 Dear Tom: AECOM is a global provider of highest quality, efficient and cost effective construction management services to a diverse group of clientele; both in the private and public sector. Particularto the latter sector, our clientele encompasses Federal, State, County, and City agencies; Transportation Authorities such as OCTA, RCTC, SANBAG, ACTH to name a few; Flood Control Districts; Water /wastewater Authorities; and other Public Works entities. AECOM's CM history includes similar construction projects and especially our extensive experience working with Caltrans on freeway, highway and bridge projects,gives our firm a unique perspective into the entire work scope required to assist the City and Caltrans in successfully completing this project's construction. Our experience as construction manager on similar projects includes Caltrans On -call Phase 2 Seismic Retrofit construction projects; the Fairview Road /1 -405 Interchange and the Harbor Blvd Widening ($7.2 million) for City of Costa Mesa; the Linnel Lane overcrossing the 1 -215 ($3 million) and the Los Alamos /1 -215 Interchange Improvement ($11.3 million) for City of Murrieta; the I- 5/ Burbank Blvd Widening ($6 million) for City of Burbank; and the 1- 710 /Firestone Blvd Widening ($10.7 million) for City of South Gate. AECOM is proposing to the City as the Prime consultant for the services. As such, we will be the singular entity responsible for all contractual, administrative, managerial and technical requirements. To supplement our in -house staff, AECOM has formed a teaming relationship with Safework, Sequoia Consultants, , and Coast Surveying, to provide safety oversight, material testing, and surveying services respectively. Those firms are consistent team partners of AECOM on projects of this nature. They are dependable, responsive and do quality work. While alt the above summarized experience is necessary to get the work performed efficiently and cost effectively, at the end of the day it is the committed managers and staffing who will DELIVER. No firm is any better than the leadership it provides. We are anxious to perform the required services for the City and have no hesitation committing our A -Team to get the job done. Between myself serving as the Project Director, Project Manager Jim Hannigan, and Resident Engineer Samson Engeda, the City is getting three leaders who are among the very best (if not "the best ") in Southern California. The remaining leadership we are committing in specialty areas is all seasoned veterans in their respective specialty areas. Our proposed project organization and qualification of our leadership will be highlighted in a subsequent section of our submittal m m 0 n As project Director, I am proud to present this team and staff to the City of Newport Beach. In my role I will serve as the firm's primary representative and responsible for all duties from contract negotiations through project completion. Project Manager Jim Hannigan will serve as the alternate representative. Both of us are committed to do whatever it takes for the success of this project Peter Lim / Principal -in- Charge _ o Peter.lim @aecom.com / 949.293.6282 (cell) J °---------- ----- ------ ---- -- -- - - - -- -- ;c Jim Hannigan / Project Manager ----— - -- - -- - - - - -- - -- o Jim.hanniaan @aecom.com / 858.205.7730 (cell) E 999 Town & Country Road, Orange, CA 92868 We appreciate the opportunity to submit this proposal and look forward to continuing our working relationship with the City. Sincerely, Peter Lim, PE Project Director/ Sr. Vice President E m a- U m �o 2 Q Q Q O C t V 9 f�. I AECom 24 i Technical Approach AECOM is one of the nation's leading firms for transportation infrastructure design, program management and construction management. Headquartered in Los Angeles, AECOM offers a project 'j team with extensive experience in public construction, particularly in,bridge seismic retrofits, 'I working and coordinating with Caltrans. AECOM's CM /CEI Division specializes exclusively in providing full- service construction management in bridge seismic retrofit projects. AECOM has successfully completed construction management on some of the largest and most complex projects along the West Coast. As a result, the AECOM team is thoroughly familiar with the challenges of working within the State's highway system, Department of Fish & Game, USACE, and SCWRB. With our unchallenged experience in this area, we understand the importance of looking ahead to avoid potential problems associated with this work. And because we pride ourselves on the fact that we are proven problem solvers, and not just "paper pushers ", we will quickly mitigate unforeseen conditions when they are encountered - AECOM engineers and team members will provide solutions. ib We have provided construction management and engineering design services on numerous assignments of very similar scope and nature to the Newport Beach Bridge Seismic Retrofit Projects and will bring this experience to carry out this project to a successful completion. The AECOM Team's mission is to deliver an exemplary project that all involved are proud to claim as their own. Summary Project Approach and Schedule The purpose of the project is to provide construction management services in support of the City's seismic.,retrofit program. The City is proposing seismic retrofits on three bridges, they are: Goldenrod Pedestrian Overcrossing (POC), Jamboree Road over San Diego Creek (Northbound) and Jamboree Road over San Diego Creek (Southbound). The Goldenrod POC retrofit includes strengthening the bent caps with concrete bolsters, column casings, and strengthening the abutments with drill and bond dowels in preparation of increasing the abutment stem walls. Jamboree Road has both northbound and southbound structures to retrofit over the San Diego Creek. The northbound structure consists of abutment shear walls, infill walls between columns at the bents, and structure approach stabs. The Southbound structure includes abutment back wall retrofit and reconstruction of structure approach slab. We understand thatthe environmental clearance, right -of -way certifications, and the final design have been completed. The City of Newport Beach is anticipating for construction to begin in November of 2010. The total project is estimated to be approximately $1.7 million and has various funding sources including: California Prop 1 B funds and Federal HBRR funds. With the California Transportation Commission as the responsible party to ensure allocation of Prop 1 B funds to the various agencies, one of the requirements is for the City to comply with a Baseline Agreement which contains a proposed timeline of committed target dates that are required to be met forthe project. The schedule becomes very critical and shall be supported and adhered to in orderto not only obtain the funds for this project yet set the precedence for other future projects the City may on the project list for Prop 1 B funds. Choosing the right construction management partner is key. The City needs a team that understands the organization and its goals, knows how to interface with Caltrans and regulatory agencies, can effectively and efficiently manage a contractorto build the project within schedule and budget constraints, is well - versed in traffic management far safe pedestrian and vehicular movement through the construction site, and understands the sensitivities of businesses and residents and the importance of quick response to address their concerns. AECOM is that partner. Newport Beach Bridge Seismic Retrofit Projects AECOM ZS Project Elements In reviewing the site, we have identified key issues facing the City and your construction manager in delivering the Newport Beach Bridge Seismic Retrofit Projects: safety, construction staging, traffic handling, and coordination. Safety Our role starts with "Safety" and we begin with our pre- construction surveys. One of our prime concerns are overhead power lines as well as underground duct banks located near live traffic, both distribution and transmission lines. During construction activity, we must take precautions so that this high voltage electricity does not arc to a crane or inspectors working nearby. Under the direction of AECOM Team safety officer, we will ensure that AECOM internal "Code of Safe Practices" fully complies with any and all local, State, and Federal safety codes and regulations. In addition the safety officer will ensure that all personnel adopt the "Code of Safe Practices" that is published bi- weekly. The safety officer will also conduct weekly safety meeting and minutes of meetings will be properly documented. On a regular basis, the AECOM Safety Officer wilt inspect the job site to ensure that the "Code of Safe Practices" is being followed and that the equipment is being operated in accordance the manufacturer recommendations. Traffic Handling and PedestrianNehicularAccess The City has made commitments to local businesses and property owners to maintain access and a Level of parking during construction, it is important for your construction managerto be your proxy on site to honor those commitments. The specifications need to clearly state that the Contractor is responsible for 24/7 access for the business and have capability of pedestrian crossings and each at grade crossing location. One way to mitigate any inconvenience is for the Contractor to conduct night work in lieu of partially closing a particular driveway during the day — proper planning is essential. Safe movement of vehicles and pedestrians through the job site, protection for workers, removing unnecessary obstacles, providing clean passage for pedestrians are all key considerations. Handling traffic during construction also means we make early coordination and close communication with Caltrans District 12 personnel, and the City staff for any actions that could affect traffic conditions within their right -of -way. The construction manager has a responsibility to review the staging of the project plans and bring attention to not only risks, but also any alternative staging of construction that will mitigate time on the project which will serve as cost savings to the City as well as promote efficiency. Coordination and Utility Relocations The construction manager will be responsible for the day to day administration and coordination of the project. The CM will act as the point of contact between Contractor, consultant surveyors, consultant material testers, AGENCY, Designer, and other project participants. All the project information related to the construction contract shall flow through the construction manager to /from the contractor and all other project participants. Coordination Proper coordination with the City, Caltrans, and various regulatory agencies is important to verify that we meet their expectations. With weekly construction meetings along with special coordination meetings, coordination efforts and reviewing the requirements prior to the work helps with ensuring compliance to all regulatory permits on the project. Newport Beach Bridge Seismic Retrofit Projects 0 a 0 a` 0 cr AECOM 26 Public Outreach The construction manager shall work directly with the City's Public Outreach team with timely notifications, and up to date progress on lane closures, traffic control, phasing /staging notifications o for the media, residents and business owners within the vicinity of the project. a AECOM's Project Approach We have a team of highly experienced construction management and scheduling professionals available to review the plans and special provisions for accuracy and completeness. Our team members are very familiar with Caltrans standard plans and specifications and will ensure the Contractor constructs the project in accordance with not only Caltrans standard plans and specification but also the City of Newport Beach's standard plans and specifications. Proactive vs. Reactive As part of any construction management project, identifying and preparing for potential risks is an important early action, hence bringing on board a construction manager in advance of construction is an asset to the project and has the potential to save costs and time on the project. AECOM can serve the City with a service prior to construction which is commonly referred to as the preconstruction phase. During this phase, tasks include development of a Resident Engineer's Manual for the project which serves as a Project Management & Execution Plan for CM services to the client. This manual explicitly informs the client of document control, contract administration, and management of the project from Preconstruction Phase, Construction Phase, and the Post Construction Phase of work. The AECOM team shalt perform a preliminary constructability review to reassure the City of Newport Beach that all potential risks have been property identified prior to going out to construction. For each risk identified, we assess probability and impact, define party best able to manage the risk, and propose mitigation orelimination strategies. In general, during the construction phase, the CM shalt have primary responsibility for • Construction completion on schedule, within budget, and in accordance with the contract documents and sound safety practices. • Proper documentation, negotiation and processing of all changes and claims. • Processing of progress payments in a timely manner. • Performance of required field quality control surveillance and inspections. • Third Party Coordination The CM shall ensure that all contract deliverables are properly documented and promptly processed. These construction /procurement contract deliverables include, but are not limited to: • Shop drawings, working drawings, and vendor data • QA /QC Procedures • As -built drawings • Inspection and testing records • Contractor Construction Baseline Schedule and updates • RFI's and RFCs Payment requests As the authorised representative of the AGENCY, the CM's detailed responsibilities include: • Coordinate all construction /procurement activity, including interface with adjacent contracts. • Manage construction support activities. • Document, verify and report contractual progress. • Monitor Contractor progress against the approved schedule. • Work with Contractor to develop and implement corrective actions to mitigate delays. Newport Beach Bridge Seismic Retrofit Projects AECOM -27 • Review Contractor submittals for content and format. Process and track submittals to and from the reviewing entity. • Manage the change control process, including processing valid contract change notices /orders. • Maintain contract deficiency lists. Implement claims mitigation and claims resolution actions. • Provide surveillance of in- process work and acceptance testing. • Monitor the Contractor's QC Program, where applicable. • Monitor the Contractor's Safety Program. Monitor and report Contractor compliance with the federal, state and local government requirements. • Coordinate survey work performed by CM surveyors. • Coordinate "Third Party" services and work affecting construction. • Process and coordinate Requests for Information.(RFIs) from contractors. • Monitor and verify delivery of equipment and material to job -site. • Recommend expedited construction techniques. • Monitor contract compliance with environmental and archaeological requirements. Monitor performance and startup tests. • Enforce warranty provisions of contracts. • Manage the contract closeout process. Post Construction Phase . consists: of wrapping up any potential claim or claim issues, as built plans and schedule, as long as prepare project closeout paperwork for the project in accordance with the {LAPM Chapter 17) Caltrans Local Assistance Procedures Manual. Delivering all project records and ,processing final payment to the Contractor and obtain Project acceptance and completion forms ffbm all parties involved. Summary of Scope of Services (Responsibility Matrix) In the figure below, we demonstrate an example of a typical responsibility matrix we may generate for a typical grade separation project. The scope of services is based on performing the following construction phase services outlined in the Responsibility Matrix on the next page. Schedule We review the contractor's initial baseline schedule to verify that it is a reasonable, practical, and comprehensive plan for accomplishing the work. We look to see whether or not the contractor has provided the appropriate schedule interfaces with the other project activities, such as submittal review, material deliveries, and agency reviews. To better inform the Contractor of the constraints to the project, we conduct a preconstruction schedule meeting where we inform the contractor of details pertaining to the schedule contents, formats, contractual requirements, and update submissions. We also review the contractor's monthly schedule updates, perform time impact analyses, review and approve recovery and as -built schedules. We maintain an as -built schedule throughout the project. We can typically rely on the as -built information provided by the contractor through its monthly schedule updates to create the record of as -built construction. Sometimes there are unknown or unforeseen impacts to the project which are generated by the agency or third parties. When this arises, we generally try and foresee these issues in advance and /or mitigate the delay as soon as possible. Taking a proactive approach and generating work a- rounds and /or accelerating the project with certain "What -if' scenarios to the schedule. We generate a cost and time impact /savings to each scenario for the client as options to mitigate a delay. Newport Beach Bridge Seismic Retrofit Projects. a 0 0 a U i .i AECOM 28 PERSONNEL RESPONSIBILITY MATRIX Le end- v a v a a � P —Primary Responsibility 3 w S— Support Role � 3 a i a R — Review a A— Approve = m v m 2 ° ° v a C— Consult if Necessary 2 F- Resident Engineer's Manual R Constructability Analysis P P S Initial Construction Schedule and Project Budget Analysis 71s, P Bid Documents (Review and Bid Tabulations) P Pre Condition Survey (Photos /Documentation) C S P Contract Award (Bid Analysis, Insurance, Sureties etc.) P Pre - Construction Meetings 5 5 P S S S Progress Management &Administration E mug C P S Progress Schedule C P 5 Construction Coordination 5 P 5 Changes /Claims P S S Monitor, Review, Approve (SWPPP AQMD) Compliance P S Construction Safety C P S S Utility Coordination P S Coordinate Flagpersons and Watchpersons P S Quality Control Inspection and ]DR R P Materials Testing and Support Services S S P Environmental Services R S Progress Payments P S S Submittals and RFI's (Requests for Information) R S Conferences / Meetings P S Reports and Records R S Review of Traffic Plans (Detours and Lane Closures) R S Survey Support (QC) Services S S S Public Affairs P Document Control R S Contractor Insurance P Labor Compliance and DBE Monitoring P As -Built Drawings R S Other Services as Required S P S Contract Closeout S P S S S S 5 . 9 Newport Beach Bridge Seismic Retrofit Projects a N D a n a 0 U — __-- ....... . ........... .... a i Local. Assistance Procedures Manua[ Exhibit 10 -H Construction Management (CM) Services for Newport Beach Seismic Retorfit Project CONTRACT NO. 358 -ST Date: August 14, 2010 I Consultant: AECOM Classification I Project Manager Resident Engineer /Snunure Rep. Structures Inspector - Labor Compimm Project ContmIs/Scheduler Constmctability Review DIRECT LABOR (SPECIFY) Name Range Hours Jim Hannigan, PE $65.00 $85.00 8 $ Samson Engeda, PE/SE $55.00 $65.00 1160 $ Stan Vander Mey, PE $45.00 $60.00 0 $ Shad Gaffney $35.00 $45.00 7 $ Ricaudo Fajrdo $45.00 $50.00 28 $ Gerald Schoben, PE $55.00 $65.00 0 $ Anticiapted Salary Raise None. Hourly Rate Year Ending 2010 $ 0.00 rect Rate (Fringe Benefits + Overhead + General and Adminsitrative) 121.8% �$ 84,020.94 (Profit) 8% Is 12,240.29 Other Direct Costs Travel Costs (Form 60.2) $ 0 Equipment and Supplies (Form 60 -2) $ 9,430.00 All Other Direct Costs (See Form 6G-2)1 $ 9.430.00 Total Subcontractor Coats $ Subcontractor Adminstratwn $ 12,000.00 Local Assistance Procedures Manual Exhibit 10 -H Other Other Direct Cost Construction Management (CM) Services for Newport Beach Seismic Retorfit Project CONTRACT NO. 358 -ST Consultant: AECOM OTHER DIRECT COSTS SCHEDULE Date: August 14, 2010 1. All ODC other than Vehicle Usage and Monthly Cellular Charges will be billed. Actual Costs with Outside Vendors Invoice 2. Vehicle Usage Cost includes all insuracne, maintenance and operating costs. Vehicle Usage Rate will be fixed for the duration of the contract with no increase for allowance for increase gas prices, insurance, maintenance and operation costs. 3. Mileage Rate show above is for estimate only. Mileage Rate will be reimbursed in accordance with IRS Standard Mileage Rates. 4. All other Travel and Subsistence will be reimbursed in accordance with DPA guidelines for non - exempt State employees CITY OF Newport Beach Construction Management Services: Neavvort Beach Seismic Retrofit Project Labor Person-Hours Calculation CLASSIFICATION FIRM Pre-Construction Phase CONSTRUCTION PHASE PHASE Post Construction Aug 1 0 2010 Sept Oct ct 2 3 0 0 0 ov 4 1 Dec e c 5 1 D5 . an 6 1 20�1 Feb 7 1 Mar Mar a a 1 1 Apr 9 1 2011 May to 2 Total Hours Total Hours 8 8 Project Manager ARCOM Resident Engineer /Structure Rep. ARCOM 8 40 80 0 168 168 8 168 168 6 168 8 168 24 1160 11 60 Structures Inspector AHCOM 0 0 0 0 0 0 0 0 0 0 0 L20 Labor Complance ARCOM 0 0 0 1 1 1 1 1 1 1 7 Project Controls/Scheduler AECOM 0 0 12 1]_ 2 2 2 1 2 2 2 4 28 Constructability Review ARCOM 16 4 0 0 0 0 0 0 Materials Inspection 0 0 0 8 8 8 0 48 Surveyor (As- Needed) C,,.t Sw.yl.g 0 0 0 0 0 0 0 TOTAL PERSONNEL HOURS 24 44 92 1 So I So ISO 180 31 I 1271 ___"'1 ACOI ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR `...� CERTIFICATE OF LIABILITY INSURANCE 4/1/2011 PRODUCER Lockton Insurance Brokers, LLC INSR THIS CERTIFICATE IS ISSUED AS A MAT MacArthur Blvd., Suite 550 HOLDER. AND CONFERS DOES NO CA License #OF15767 CA Li Irvine 92612 TYPE OF INSURANCE ALTER THE COVERAGE AFFORDED BY 949 - 252-4400 DATE(MMIDD/YY) LIMITS INSURERS AFFORDING COVERAGE INSURED AECOM ToChnolog Corporation INSURERA TravelerSProperty Casualty CoofAmeric a Se 1075642 AECOM Technical rvices, Inc. 999 Town & Country Road $ XXXXXXX INSURER B Orange CA 92868 INSURER C COVERAGES DATE(MMIDDIYYYY) 12/13/2010 ' INFORMATION CERTIFICATE ID, EXTEND OR ILICIES BELOW. NAIC # 25674 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDT POLICYEFFECTIVE POLICY EXPIRATION LTR INSRD TYPE OF INSURANCE POLICY NUMBER DATE(MMIDD/YY) DATE(MMIDD/YY) LIMITS GENERAL LIABILITY EACH OCCURRENCE $ XXXXXXX COMMERCIAL GENERAL LIABILITY DAMAGE TO RENTED $ XXXXXXX CLAIMS MADE 1:1 OCCUR NOT APPLICABLE MED EXP(Any one Person) $ XXXXXXX PERSONAL &ADV INJURY $ XXXXXXX ' GENERA-AGGREGATE $ XXXXXXX GEHL AGGREGATE LIMIT APPLIES PER PRODUCTS - COMPIOPAGG s XXXXXXX PRO - PRO- 17 POLICY JECT LOG AUTOMOBILE LIABILITY ANY AUTO COMBINED SINGLE LIMIT (Ea accident) $ XXXXXXX BODILY INJURY (Per Person) $ XXXXXXX ALL OWNED AUTOS SCHEDULED AUTOS NOT APPLICABLE BODILY INJURY (Per accident) $ XXXXXXX HIRED AUTOS NON -OWNED AUTOS PROPERTY DAMAGE (Peraccident) $ XXXXXXX GARAGE LIABILITY AUTO ONLY - EA ACCIDENT $ XXXXXXX ANY AUTO NOT APPLICABLE OTHER THAN EA ACC $ XXXXXXX - AUTO ONLY. AGE $ XXXXXXX EXCESSIUMBRELLA LIABILITY EACH OCCURRENCE $ XXXXXXX OCCUR Ll CLAIMS MADE AGGREGATE $ XXXXXXX $ XXXXXXX UMBRELLA 1:1 APPLICABLE $ XXXXXXX FORM DEDUCTIBLE FORM $ XXXXXXX RETENTION $ A A A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN MY PROPRIETOWPARTNEWEXECUTIVE OFHCEWM,,ei FxcwDEw N❑ (Mandatory NH) TRJUB- 4245323 -1 -10 (AZ,MA,OR,WI) TC2JUB- 4245B22 -A -10 4/112010 4/12010 4/112011 4/1/2011 X T'CSTAITS OTH RY E.L. EACH ACCIDENT $ 1,000,000 E1, DISEASE - EA EMPLOYEE $ 1,000,000 A SPECIAL PROVISIONS below (All Other States) E.L. DISEASE - POLICY LIMIT $ 1;000,000 OTHER DESCRIPTION OF OPERATIONSILOCATIONSIVEHICLEVE XCLUSIONS ADDED BY ENDORSEMENTISPECIAL PROVISIONS For Newport Beach Bridge Seismic Retrofit Project. Waiver of Subrogation applies per attached endorsement. uCR I Iriu. I C MUL VCR MXtlMCLLA I KJPI 1-1—vvvl 11095555 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION City of Newport Beach (CA) DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN 3300 Newport Boulevard - PO Box 1768 NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL Newport Beach CA 92658 IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR ACORD 2512009!011 CORPnRATION_ All rinhtc reserved The ACORD name and to o are registered marks of ACORD For questions re0erdiro this cer ificale, contact the number IisTed in the'Pr registered section above and sceciNthe client code'AECTE01'. TRAVELERS WORKERS COMPENSATION AND EMPLOYERS LIABILITY POLICY ENDORSEMENT WC 99 03 76 (00) POLICY NUMBER: 2J 2 22 10 WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT - CALIFORNIA (BLANKET WAIVER) We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be % of the California workers' compensation premium otherwise due on such remuneration. Schedule Person or Organization ANY PERSON OR ORGANIZATION FOR WHOM THE NAMED INSURED HAS AGREED BY WRITTEN ' CONTRACT EXECUTED PRIOR TO LOSS TO FURNISH THIS WAIVER. Job Description Miscellaneous Attachment : M 100686 Certificate ID : 11095555 AiCR" CERTIFICATE OF LIABILITY INSURANCE DATE 61ro4ao11 EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.- ILSR -- -� -- _TYPE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the pothey(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER GILD 596589102 C TACT Insurance SeNlces EACH OCCURRENCE NAME: _ PHONE FAX Marsh Risk & CA license #0437153 AIC� !{o_t— .__._.— __.._.__._.._._ 777 $OUfh Figueroa Street ._ . — — 1,000. E -MAIL _ COMMERCIAL GENERAL UABIUTY Los Angeles, CA 90017 PRDDUSECER AM: Lori Bryson (213)-346-5484 EUSIGEfEH1Q.H.___.______ _.,.____ _ — __._— _�_.�..___r__..... 06510-AECOWCAS -10/11 _ AECTE AECOM REGINA 12TH _ _INSURER(SjAFFORDING COYERHGE NAIC9 _ INSURED e a MED E %P (Any one D rmn BAW INSURER #: Zurich Mlencan Insurance Company 16535 AECOM Technical Serme3. Inc, ; 999 Town & Country Road PERSONA INJURY INSURER 6: GENERAL AGGREGATU Orange, CA 92868 INSURER C. Illinois umon Insurance Cc 27960 INSURER D: NIA N/A tGENLAGGRrAT' LIMITAPPLIESPER' INSURERS: PRODUCTS -0OMP/OP AGG S 4D00.000 POLICY' PR0. LOD �AUTOMOBILE INSURER F: COVERAGES CERTIFICATE NUMBER: LOS - 00127699531 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.- ILSR -- -� -- _TYPE AOD �TiT ` -- -- `POLICY PM DY EFF FIE-u EE %P-- _ �_.._.___-- ^_LIMITS OF INSURANCE AI NUMBER A GENERAL LIABILITY GILD 596589102 04I01I2010 04N1/2011 EACH OCCURRENCE $ 1•�•� ._ . — — 1,000. _ COMMERCIAL GENERAL UABIUTY PREMISES Ee _ I 3 I�S Ilr 1 CLAIMS MADE X 'OCCUR e a MED E %P (Any one D rmn BAW ; PERSONA INJURY _�8 S GENERAL AGGREGATU 2.000 3 F � I I tGENLAGGRrAT' LIMITAPPLIESPER' PRODUCTS -0OMP/OP AGG S 4D00.000 POLICY' PR0. LOD �AUTOMOBILE - -_� a - - - -- -- A UgewTY (BAP 596589302 0410v2010 110410112011 COMBINED SINGLE'JMIT S 1.000,000 X.,, ANY AUTO { IEa socum.0 i IROUILY INJURY (Per parsap ALL OWNED AUTOS I 1 BODILY INJURY (Per Per acutlenp , - S SCHEDULED AUTOS ✓ - " " "' " "" PROPERTY DAMAGE S { i HIRED AUTOS - I I I (Per imodimn NON OWNED AUTOS f I IS I UMBRELIA LIAR OCCUR I f EACH OCCURRENCE 15 _ EXCESS LIAR _.l_,Ct-AIM6 -MADE( (AGf'RCGATE , L —IDEDUCTIBLE RETENTION S S WORSERSCOMPENSATION - STA U- OTH �3Y11MpSB AND EMPLOYERS'LIABILITY YIN! TV OR (--- ANY PROPRIETORIPARTNER IEHECUTIVE' OFFICEFUMEMSER E%CLUDEOn L� ! N 1 A I I I ! EL EACHACCIDENT is (Mandatory in NH) I j • SAL DISEASE EA EMPLOYEE S r If yea, describe dntlm { 1 DESCRIPTION OF OPERATIONS Uelovr E.L. DISEASE POLICY LIMIT 5 C IpRCHITECTSB ENG (EON G21654693 104101/2010 j10i0 &•2.011 Per ClainiAgg 61000,000 PROFESSIONAL i I I"CLAIMS MADE " I ! (Defense Included DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES IAtNrh ACORD 101, Additional Remarks Schedule, B more space is required) RE For Newport Bead 81 Seismic pencil Projecl (SEE ADDITIONAL PAGE TEX13 City of Newport Beam [CA) 3300 Newport Boulevard PO Box 176E Nevrpod bears, CA 926E8 AGORD 25(2UDgi09} SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. O(Mar9n RIaN 8nauran54 $efVlceS DO ID Denman The AGORD name and logo are registered marks of AGORD ADDITIONAL INFORMATION LOSA0127699531 DAIS IMMNUIYY) PRODUCER Marsh Risk & Insurance Services CA Ucense &0437153 777 Scuth Figueroa Street Las Algeles, CA 90017 a 34 &5M164 -I0 T(273)- 06510- AECOM- CAS -101st AECTE AECOM REGINA 17171 - - -Alin -Lon INSURERS AFFORDING COVERAGE NAICC NSURED INSURER G AECOM Technical Services Inc. - - -- - - - - -- - -- �-WVRERI — 999Town &County RRomURERH INS— J Orange, CA 92868 INSURER J TEXT THE CITY OF NEWPORT BEACH (CA), ITS OFFICERS, OFFICIALS, EMPLOYEES AND VOLUNTEERS ARE NAMED AS ADDITIONAL INSURED FOR GL COVERAGES. BUT ONLY AS RESPECTS WORT( PERFORMED BY OR ON BEHALF OF THE NAMED INSURED. IA WAIVER OF SUBROGATION IS PROVIDED FOR THE GENERAL LIABILITY, AUTO LABILITY COVERAGE AND PROFESSIONAL LIABILITY COVERAGE. 30 DAY NOTICE OF CANCELLATION IF INSURER CANCELS, APPLIES TO ALL POLICIESAS REQUIRED BY WRITTEN CONTRACT FOR GENERAL LIABILITY, AUTOMOBILE LIABILITY AND PROFESSIONAL LIABILITY POLICIES, SUCH INSURANCE AFFORDED SHALL BE PRIMARY INSURANCE AND ANY INSURANCE CARRIED BY CERTIFICATE HOLDER& ADDITIONAL INSURED SHALL BE EXCESS AND NOT CONTRIBUTORY INSURANCE FOR GENERAL LIABILITY COVERAGE. (AUTO WORDING IS INCLUDED IN THE POLICY FORM). CERTIFICATE HOLDER City of Newport Bench (CA) 3300 NewPon Boulevard PO Rex 1768 Newport Beech. CA 92658 POLICY NUMBER. GLO 5965891 02 COMMERCIAL GENERAL LIABILITY CO 20 26 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - DESIGNATED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE CITY OF NEWPORT BEACH (CA) 3300 NEWPORT BOULEVARD P.O. BOX 1768 NEWPORT BEACH, CA 92658 ITS OFFICERS, OFFICIALS, EMPLOYEES AND VOLUNTEEP.S RE: For Newport Beach Bridge Seismic Retrofit Project Section II — Who Is An Insured is amended to in- clude as an additional insured the persons) or or- ganizations) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or Omissions or the acts or omissions of those acting on your behalf: A. In the performance of your ongoing operations, or B. In connection with your premises owned by or rented to you. CG 20 26 07 04 Copyright, i5:0 Properties. Inc , 2054 - - Page 1 of 1 UNIFORM. POLICY NUMBER: GLO 5965891 02 COMMERCIAL GENERAL LIABILITY CG 20370704 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or O cl nizationfst: Location And Description Of Completed Oaerati n City of Newport Beach (CA) RE: For Newport Beach Bridge Seismic Retrofit Project. 3300 Newport Boulevard P.O. Box 1768 Newport Beach, CA 92658 ITS OFFICERS, OFFICIALS, EMPLOYEES AND VOLUNTEERS Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Section II — Who Is An Insured is amended to in- clude as an additional insured the person(s) or or- ganizations) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or In part, by "your work" at the location designated and described in the schedule of this endorsement performed for that ad- ditional insured and included In the "products -com- pleted operations hazard ". CO 20 37 07 04 Cap,jrlght, ISO Praperties, Inc.. 2004 Page 1 of 1 UNIFORM 0 Additional Insured - Owners, Lessees or Contractors (Primary Insurance) a ZURICH I Policy No I CR._ Dare of Poi I Exn Date of Pol. I =fr. Dam ol'End. I Producer I Add -1. [rem I RMUm Pram. GLO 5965891 -02 104/01/10 0 This endorsement modifies the insurance provided under the following' Commercial General Liability Coverage Form SCHEDULE Name of Person or Organization: Only those as required by written contract. (if no entry appears above. info,mation required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) SECTION 11- WHO IS AN INSURED is amended to include as an insured the person or organization shown in the Schedule, but only with respect to liability arising out of your ongoing operations performed for that insured. The insurance provided by this endorsement is primary insurance and we will not seek contribution from any other insurance available to the person or organization shown: in the Schedule unless the other insurance is provided by a contractor other than you for the same operation and job location. Then we will share with that -other insurance by the method described in paragraph 4.c. of SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS. 0 Endorsement ZURICH Polley No. I EH. Date of Pol. Ext). Date of POI ER. Dote of End. I Producer Add'I. Pram Retum Prom. THIS ENDORSEMENT CHANGES THE POLICY, PLEASE READ IT CAREFULLY. The Insured: AECOM TECHNOLOGY CORPORATION Endorsement No. 4 Melling Address (Including Zip Code): 555 SOUTH FLOWER STREET, #3700 LOS ANGELES, CA 00071 Liability Polley{ It Is hereby agreed that U-GL- 1114 -A CW (10102), Blanket Notilloetlon to Others Cancellation, Is added to the policy per the attached: All otber iemre and conditions of this policy remain unciumged. .:111710 my Countersigned tNJU; 14 -A CW (10103) Page 1 of 1 a Blanket Notification to Others of Cancellation ZURICH* Poacy No. I Ea, Date or Pd. E* Ogre of Poi. Ea. Date of End. PMduwr No. Add%Prom RaNm Preen. OL05905 01-02 04/01r20110 04/0112011 10212010 75420AOD THIS ENDORSEMENT CHANGES THE POLICY, PLEASE READ IT CAREFULLY. This endorsement modifies Insurance provided under the: Commercial General Liability Coverage Part A. If we cancel this Coverage Part by written notice to the Bret Named Insured for any reason other than nonpayment of premium, we will deliver electronic notification that such Coverage Part has been cancelled to each person or organization shown In a Schedule provided to us by the First Named Insured, Such Schedule: 1. Must be Initially provided to us within 10 days: a. After the beginning of the policy period shown In the Declarations; or b. After this endorsement has been added to policy; 2. Must contain the names and e-mail addresses of only the persons or organizations requiring nodgcation that such Coverage Pori has been cancelled; 3. Must be In an electronic format that Is acceptable to us; and 4. Must be accurate. Such Schedule may be updated and provided to us by the First Named Insured during the policy period. Such updated Schedule must comply with Paragraphs 2.3. and 4. above. S. Our delivery of the electronic notification as described In Paragraph A. of this endorsement will be based on the most recent Schedule In our records as of the date the notice of cancellation Is mailed or delivered to the first Named Insured. Delivery of the notification as described In Parogreph A. of this endorsement will be completed as soon as practicable after the effective date of cancellation to the first Named Insured. C. Proof of entailing the electronic notification will be sufficient proof that we have complied with Paragraphs A. and S, of this endorsement. D. Our delivery of electronic notification described In Paragraphs A. and S. of tlds endorsement Is Intended as a courtesy only. Our failure to provide such delivery of electronic notlitcatlon will not: 1. Extend the Coverage Part cencellalion date; 2. Negate the cancellation; or 3.. Provide any additional Insurance that would not have been provided In the absence of this endorsement. E. We are not responsible for the accuracy, integrity, Ilmellnese and validity of Information contained. In the Schedule provided to us as described In Paragraphs A, and S, of this endorsement. All other terms and condigons of this policy remain unchanged. LL01,4114-A CW (10.02) Page 104 t Insdudes mpynghleo maleAal of N wmre Services O@ce, Im- VAth la pormisaiae. Endorsement 0 ZURICH Policy No ER. Date of Poi. JExp Date of Pot Eft Date of End. Producer I Add', Pram Return Pram. BAP 5955193-02 D0112010 0 r S I ypso: THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. The Insured: AECOM TECHNOLOGY CORPORATION Endorsement No.: 13 Mailing Address (Including Zip Code): 555 SOUTH FLOWER STREET, #3700 LOS ANGELES, CA 9OD71 Business Auto Policy It is hereby agreed that UCA812AC W (05/10), Notification of Others Cancellation, is added to the policy for the City of Newport Beach, CA per the attached: All other terms and conditions of this policy remain unchanged. 121710 MY Countersigned _ Authorized Represe,tat.ve Page 1 a I a Notification to Others of Cancellation ZURICH PoMry No Ex. THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Commercial Automobile Coverage Part A. if we cancel this Coverage Part by written notice to you for any reason other than nonpayment of premium, we will mail or deliver a copy of such written notice of cancellation: 1. To the name and address corresponding to each person or organization shown In the Schedule below; and 2. At least 10 days prior to the effective date of the cancellation, as advised In our notice to you, or the longer number of days notice It Indicated In the Schedule below. B. If we cancel this Coverage Part by written notice to you for nonpayment of premium, we will mail or deliver a copy of such written notice of cancellation to the name and address corresponding to each person or organization shown In the Schedule below at least 10 days prior to the effective date of such cancellation. C. If notice as described in Paragraphs A. or B. of this endorsement Is mailed, proof of mailing will be sufficient proof of such notice. SCHEDULE Name and Address of Other Person(s) / O anlzatlon s Number of Days Notice: City of Newport Beach, CA 3300 Newport Blvd. P.O. Box 1768 45 Newport Beach CA 82668 All other terms and conditions of this policy remain unchanged. v- CA -8 +2.A VA t05P 0 Page'. o: ��c:uaas ruVY, 9 °tea maiera. a' 1 ^5� once Servkes CJiTGe. ^,L a' ^n, q � - ?� S5 >qo. We of Pol. I Exp. DOW of Pol. I En. Date of End. I Producer No I A . Pram Retum Pram. BAP5965893 -02 t 4/01/2010 1 4101/2011 1 10/21/2010 1 75428 -000 1 TBD THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. This endorsement modifies insurance provided under the: Commercial Automobile Coverage Part A. if we cancel this Coverage Part by written notice to you for any reason other than nonpayment of premium, we will mail or deliver a copy of such written notice of cancellation: 1. To the name and address corresponding to each person or organization shown In the Schedule below; and 2. At least 10 days prior to the effective date of the cancellation, as advised In our notice to you, or the longer number of days notice It Indicated In the Schedule below. B. If we cancel this Coverage Part by written notice to you for nonpayment of premium, we will mail or deliver a copy of such written notice of cancellation to the name and address corresponding to each person or organization shown In the Schedule below at least 10 days prior to the effective date of such cancellation. C. If notice as described in Paragraphs A. or B. of this endorsement Is mailed, proof of mailing will be sufficient proof of such notice. SCHEDULE Name and Address of Other Person(s) / O anlzatlon s Number of Days Notice: City of Newport Beach, CA 3300 Newport Blvd. P.O. Box 1768 45 Newport Beach CA 82668 All other terms and conditions of this policy remain unchanged. v- CA -8 +2.A VA t05P 0 Page'. o: ��c:uaas ruVY, 9 °tea maiera. a' 1 ^5� once Servkes CJiTGe. ^,L a' ^n, q � - ?� S5 >qo. TERMINATION AMENDED ENDORSEMENT N¢med Neared ErWwv&rrtd NumEdf AECOM Technology Corporation 26 Palley symbd Ptlky mEer PMky eAOd Efladna Hate d E eemem EON - 021664683 003 0410112010 to 10108!2011 12/16/2010 Issued BY (Name b Ieeur namPany) Illinois Union Insurance Company THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. It is agreed that Section XV, Termination, is amended by adding the following; Notwithstanding anything in this section to the contrary, except with respect to termination for nonpayment of premium, the Insurer shall give the following parties, at the addresses listed In this endorsement, at least 30 days' prior notice in the event the Policy is cancelled or nonrenewed: C old City of Newport Beach (CA) 3300 Newport Boulevard P 0 Box 1768 Newport Beach, CA 82658 All other terms and conditions of this Policy remain unchanged. JOHN J. LUPICA. President Authorized Representative ?F -00000 ra "0; E0 0231'0 r t i I CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach. Date Received: 1 -04 -11 Dept. /Contact Received From: Shauna Date Completed: I -04 -11 Sent to: Shauna By: Joel Griffin Company /Person required to have certificate: AECOM TECHNICAL SERVICES, INC I. GENERAL LIABILITY A. INSURANCE COMPANY: Zurich American Insurance Company B. AM BEST RATING (A-: VII or greater): A +: XV C. ADMITTED Company (Must be California Admitted): Is Company admitted in California? ® Yes ❑ No D. LIMITS (Must be $1 M or greater): What is limit provided? 1,000,000 E. PRODUCTS AND COMPLETED OPERATIONS (Must include): Is it included? (completed Operations status does not apply to Waste Haulers) ® Yes ❑ No F. ADDITIONAL INSURED WORDING TO INCLUDE (The City its officers, officials, employees and volunteers): Is it included? ® Yes ❑ No G. PRIMARY & NON - CONTRIBUTORY WORDING (Must be included): Is it included? IN Yes ❑ No H. CAUTION! (Confirm that loss or liability of the named insured is not limited solely by their negligence) Does endorsement include "solely by negligence" wording? ❑ Yes ® No I. NOTIFICATION OF CANCELLATION: Although there is a provision that requires notification of cancellation by certified mail; per Lauren Farley, the City will accept the endeavor wording. Attached endorsement notice of cancellation II. AUTOMOBILE LIABILITY A. INSURANCE COMPANY: Zurich American Insurance Company B. AM BEST RATING (A-: VII or greater) A +: XV C. ADMITTED COMPANY (Must be California Admitted): Is Company admitted in California? ® Yes ❑ No D. LIMITS (Must be $1M min. BI-& PD and $500,000 UM, $2M min for Waste Haulers): What is limits provided? 1,000,000 E. PRIMARY & NON - CONTRIBUTORY WORDING (For Waste Haulers only): Is it included? N/A ❑ Yes ❑ No F. NOTIFICATION OF CANCELLATION: Although there is a provision that requires notification of cancellation by certified mail; per Lauren Farley, the City will accept the endeavor wording. Attached endorsement notice of cancellation III. WORKERS' COMPENSATION A. INSURANCE COMPANY: Travelers B. AM BEST RATING (A-: VII or greater): A +: XV C. LIMITS: Statutory D. WAIVER OF SUBROGATION (To include): Is it included? HAVE ALL ABOVE REQUIREMENTS BEEN MET? IF NO, WHICH ITEMS NEED TO BE COMPLETED? Approved: January 6, 2011 Agent of Alliant Insurance Services Broker of record for the City of Newport Beach ❑ Requires approval /exception /waiver by Risk Management Comments: I Approved: Risk Management Date Date initials ® Yes ❑ No ® Yes ❑ No � I prT 7ni0 CITY OF NEWPORT BEACH CITY COUNCIL STAFF REPORT ,_ mnnnnnr October 12. 2010 TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL FROM: Public Works Department Tom Sandefur, Associate Civil Engineer 949 - 644 -3312 or tandefur@newportbeachca.gov SUBJECT: SEISMIC RETROFIT OF SAN DIEGO CREEK BRIDGES AND GOLDENROD PEDESTRIAN OVERCROSSING — APPROVAL OF PROFESSIONAL SERVICES AGREEMENT WITH AECOM ISSUE The upcoming bridge retrofit project requires the services of a construction management consultant. RECOMMENDATION Approve a Professional Services Agreement with AECOM of Orange, California, for the San Diego Creek Bridge and Goldenrod Pedestrian Overcrossing bridge retrofits of a not to exceed price of $186,673.94, and authorize the Mayor and City Clerk to execute the Agreement. DISCUSSION This project involves seismically retrofitting three bridges within the City. Jamboree Road over San Diego Creek both Northbound and Southbound and Goldenrod Pedestrian Overcrossing have all been listed as a mandatory bridge retrofit by the State of California. The project plans have been finalized and approved. The plans have been bid and the award of contract is pending. Recently, Staff requested proposals from five firms to provide construction management services for the Jamboree over State Route 73 Bridge Widening Project in accordance with Council Policy F -14. The five firms were (1) Anderson Penna, (2) Caltrop, (3) Parsons Brinkerhoff, (4) AECOM, and (5) Engineering Resources of Southern California. Three proposals were received from Anderson Penna, Parsons Brinkerhoff and AECOM. Proposals were independently evaluated and rating sheets Seismic Retrofit of San Diego Creek Bridges and Goldenrod Pedestrian Overcrossing — Approval of Professional Services Agreement with AECOM October 12, 2010 Page 2 were completed and discussed by two City staff members and one Caltrans representative. This established a list of qualified bridge construction management firms. Anderson Penna was chosen for the Jamboree Widening job. AECOM placed a very close second in the evaluation. Since the Retrofit projects and the Jamboree widening require nearly identical construction management services and AECOM showed excellent project understanding and expertise, Staff determined that this met the guidelines of F -14 and requested a revised cost estimate to perform Construction Management services on this bridge retrofit project. A summary of the consultant selection process: Statements of Qualification Reviewed Request for Proposals Requested: Request for Proposals Received: The proposed not to exceed construction management services fee is $186,673.94. The scope of services include: Pre - Construction Phase: a) Complete a Constructability Review b) Evaluate Bids c) Review Existing Project Files d) Prepare a Resident Engineer's Project Schedule e) Administer Construction Contract f) Pre - Construction Meeting g) Prepare Administrative Process for Dispute Resolution Construction Management During Construction: a) Coordinate all Construction Activities b) Manage Project Schedule, Progress Meetings, and Reports c) Prepare Progress Payments and Change Orders d) Manage Shop Drawing and Materials Submittals e) Manage Request for Information f) Perform Construction Observation /Inspection Services g) Monitor, Review, and Approve Environmental Compliance h) Survey Support Services Material Testing: Provide Material Testing Post - Construction Services: Prepare Contract Records and Final Report At the approval of this Professional Services Agreement, AECOM will begin the tasks associated with the Pre - Construction Phase. The remaining tasks will be completed upon award of the construction contract. 2_ w in Seismic Retrofit of San Diego Creek Bridges and Goldenrod Pedestrian Overcrossing — Approval of Professional Services Agreement with AECOM October 12, 2010 Page 3 ENVIRONMENTAL REVIEW Construction management services are not projects as defined by the California Environmental Quality Act (CEQA) Implementing Guidelines. PUBLIC NOTICE Not Applicable FUNDING AVAILABILITY This work will be paid from federal and state sources with 88.53% of the cost funded from Federal Highway Bridge Rehabilitation Funds and 11.47% funded from Proposition 1 B funds. Both programs are administered by Caltrans and reimbursement will be sought through Caltrans. Sufficient funds are available in the following account for the project: Account Description Account Number Amount Contributions 7251- C5100695 186,673.94 Prepared by: Tom Sandefur, POV Associate Civil Engineer Attachments: Project Location Maps Total $ Submitted by: 186,673.94 Director N LOCATION MAP JAMBOREE ROAD OVER SAN DIEGO CREEK BRIDGE RETROFIT CONTRACT NO. 3531 BaYV1EW WAY O X00 Sp' PROJECT LOCATION 0 m D AOQ !9L /O9 BACK BAY J o� J h 4 PROFESSIONAL SERVICES AGREEMENT WITH AECOM TECHNICAL SERVICES, INC. FOR NEWPORT BEACH BRIDGE SEISMIC RETROFIT PROJECT THIS AGREEMENT FOR PROFESSIONAL SERVICES ( "Agreement ") is made and entered into as of this day of , 2010, by and between the CITY OF NEWPORT BEACH, a California Municipal Corporation ( "City "), and AECOM TECHNICAL SERVICES, INC., a California Corporation whose address is 999 Town & Country Road, Orange, California, 92868 ( "Consultant "), and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City plans to perform seismic retrofits on three bridges: Goldenrod Pedestrian Overcrossing, Jamboree Road over San Diego Creek (Northbound) and Jamboree Road over San Diego Creek (Southbound). C. City desires to engage Consultant to provide construction management services for the Bridge Seismic Retrofit Project ( "Project'): D. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the services described in this Agreement. E. The principal member of Consultant for purposes of Project, shall be Peter Lim. F. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement_. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the above written date, and shall terminate on the 31St day of December, 2011, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ('Work" or "Services'). The City may elect to delete certain tasks of the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE Time is of the essence in the performance of Services under this Agreement and the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to perform the Services in a diligent and timely manner may result in termination of this Agreement by City. Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice to the other party so that all delays can be addressed. 3.1 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.2 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by either telephone, fax, hand - delivery or mail. 4. COMPENSATION TO CONSULTANT City shall pay Consultant for the Services on a time and expense not -to- exceed basis in accordance with the provisions of this, Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed One Hundred Eighty -Six Thousand, Six Hundred Seventy -Three Dollars and 94/100 ($186,673.94) without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.1 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and /or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.2 City shall reimburse Consultant only for those costs or expenses specifically approved in this Agreement, or specifically approved in writing in advance by City. Unless otherwise approved, such costs shall be limited and include nothing more than the following costs incurred by Consultant: Professional Services Agreement Page 2 W A. The actual costs of subconsultants for performance of any of the Services that Consultant agrees to render pursuant to this Agreement, which have been approved in advance by City and awarded. in accordance with this Agreement. B. Approved reproduction charges. C. Actual costs and /or other costs and /or payments specifically authorized in advance in writing and incurred by Consultant in the performance of this Agreement. 4.3 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated JIM HANNIGAN to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. TOM SANDEFUR, or his designee, shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his authorized representative shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES In order to assist Consultant in the execution of its responsibilities under this Agreement, City agrees to, where applicable: Professional Services Agreement Page 3 t7 i j i A. Provide access to, and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. B. Provide blueprinting and other Services through City's reproduction company for bid documents. Consultant will be required to coordinate the required bid documents with City's reproduction company. All other reproduction will be the responsibility of Consultant and as defined above. C. Provide usable life of facilities criteria and information with regards to new facilities or facilities to be rehabilitated. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards. All Services shall be performed by qualified and experienced personnel who are not employed by City, nor have any contractual relationship with City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement and all applicable federal, state and local laws and the professional standard of care. 8.2 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force in effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession_ Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.3 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents,. or acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or govemmental agencies. 9. HOLD HARMLESS To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers and employees (collectively, the "Indemnified Parties) from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, Professional Services Agreement Page 4 a attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them. Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator and /or his /her duly authorized designee informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. Professional Services Agreement Page 5 i 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. A. Proof of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this contract. City reserves the right to require complete, certified copies of all required insurance policies, at any time. Consultant shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damages to property, which may arise from or in connection with the performance of the Work hereunder by Consultant, his agents, representatives, employees or subconsultants. The cost of such insurance shall be included in Consultant's bid. B. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner :a- transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. C. Coverage Requirements Workers' Compensation Coverage. Consultant shall maintain Workers' Compensation Insurance (Statutory Limits) and Employer's Liability Insurance (with limits of at least one million dollars ($1,000,000)) for Consultant's employees in accordance with the laws of the State of California, Section 3700 of the Labor Code In addition, Consultant shall require each subconsultant to similarly maintain Workers' Compensation Insurance and Employer's Liability Insurance in accordance with the laws of the State of California, Section 3700 for all of the subconsultant's employees. Any notice of cancellation or non - renewal of all Workers' Compensation policies must be received by City at least thirty (30) calendar days (ten (10) calendar days written notice of non- payment of premium) prior to such change. Professional Services Agreement Page 6 I Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. ii. General Liability Coverage. Consultant shall maintain commercial general liability insurance in an amount not less than one million dollars ($1,000,000) per occurrence for bodily injury, personal injury, and property damage, including without limitation, blanket contractual liability. iii. Automobile Liability Coverage. Consultant shall maintain automobile insurance covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit for each accident. iv. Professional Liability (Errors & Omissions) Coverage. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) limit per claim and in the aggregate. D. Other Insurance Provisions or Requirements. The policies are to contain, or be endorsed to contain, the following provisions: i. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers and insurance clauses from each of its subconsultants. ii. Enforcement of Contract Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of the City to inform Consultant of non - compliance with any requirement imposes no additional obligations on the City nor does it waive any rights hereunder. iii. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party Professional Services Agreement Page 7 ,, I or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. iv. Notice of Cancellation. Consultant agrees to oblige its insurance agent or broker and insurers to provide to City with thirty (30) days notice of cancellation (except for nonpayment for which ten (10) days notice is required) or nonrenewal of coverage for each required coverage. E. Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement. F. Additional Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or _ joint venturer or syndicate member or cotenant if Consultant is a partnership or joint - venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty - five percent (25 %) or more of the assets of the corporation, partnership or joint - venture. 16. SUBCONTRACTING City and Consultant agree that subconsultants may be used to complete the Work outlined in the Scope of Services. The subconsultants authorized by City to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of the subcontractor. Nothing in this Agreement shall create any contractual relationship between City and subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. The City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and the City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its Professional Services Agreement Page 8 Ll officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon prior written request. Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 18. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City authorizes in writing the release of information. 19. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement of any United States' letters patent, trademark, or copyright infringement, including costs, contained in Consultant's drawings and specifications provided under this Agreement_ 20. RECORDS Consultant shall keep records and invoices in connection with the Work to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 21. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an Professional Services Agreement Page 9 immediate right to appeal to the City Manager or his /her designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 22. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. Nothing in this paragraph is intended to limit City's rights under the law or any other sections of this Agreement. 23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 24. CONFLICTS OF INTEREST The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 25. NOTICES All notices, demands, requests or approvals to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first -class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: Tom Sandefur Public Works Department City of Newport Beach 3300 Newport Boulevard PO Box 1768 Newport Beach, CA 92658 Phone: 949 - 644 -3312 Fax: 949 - 644 -3318 Professional Services Agreement Page 10 iZ� All notices, demands, requests or approvals from CITY to Consultant shall be addressed to Consultant at: i Attention: Jim Hannigan AECOM Technical Services, Inc. 999 Town & Country Road Orange, CA 92868 Phone: 714 - 567 -2501 Fax: 714 - 567 -2594 26. CLAIMS The Consultant and the City expressly agree that in addition to any claims filing requirements set forth in the Contract and Contract documents, the Consultant shall be required to file any claim the Consultant may have against the City in strict conformance with the Tort Claims Act (Government Code sections 900 et seq.). 27. TERMINATION In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. Notwithstanding the above provisions, City shall have the right, at its sole discretion and without cause, of terminating this Agreement at any time by giving seven (7) calendar days prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 28. COMPLIANCE WITH ALL LAWS Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. Professional Services Agreement Page 11 29. WAIVER _ A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 30. INTEGRATED CONTRACT This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 31. CONFLICTS OR INCONSISTENCIES In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 32. INTERPRETATION The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply- 33. AMENDMENTS This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 34. SEVERABILITY If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 35. CONTROLLING LAW AND VENUE The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange. 36. EQUAL OPPORTUNITY EMPLOYMENT Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex or age. Professional Services Agreement Page 12 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the day and year first written above. APPROVED AS TO FORM: OFFICE OFF THE CITY ATTORNEY: By :/� ``` eonie Mulvihill( \ Assistant City Attorney ATTEST: M Leilani I. Brown, City Clerk CITY OF NEWPORT BEACH, A Municipal Corporation Keith D. Curry, Mayor CONSULTANT: AECOM TECHNICAL SERVICES, INC. M Peter Lim, Senior Vice President Eugene Grilli, Vice President Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Professional Services Agreement Page 13 a m 10 /LCOM AECOM 714.567.2400 tel 999 Town 8 Country Road 774.285.0740 tax O2nge, CA 92868 www.aec .com Augustl3,2010 Tom Sandefur, PE Associate Civil Engineer City of Newport Beach Public Works Department 3300 Newport Boulevard Newport Beach, CA 92663 -3884 RE: Proposal for Construction Management Services for Newport Beach Bridge Seismic Retrofit Projects, Contract No. 3531 Dear Tom: AECOM is a global provider of highest quality, efficient and cost effective construction management services to a diverse group of clientele; both in the private and public sector. Particular to the latter sector, our clientele encompasses Federal, State, County, and City agencies; Transportation S Authorities such as OCTA, RCTC, SANBAG, ACTA to name a few; Flood Control Districts; ® Water /wastewater Authorities; and other Public Works entities. AECOM's CM history includes similar construction projects and especially our extensive experience working with Caltrans on freeway, highway and bridge projects gives our firm a unique perspective into the entire work scope required to assist the City and Caltrans in successfully completing this project's construction. Our experience as construction manager on similar projects includes Caltrans S On =call Phase 2 Seismic Retrofit construction projects; the Fairview Road /1 -405 Interchange and the Harbor Blvd Widening ($7.2 million) for City of Costa Mesa; the Linnel Lane overcrossing the 1 -215 ($3 million) and the Los Alamos /1 -215 Interchange Improvement ($11.3 million) for City of Murrieta; the I- 5/ Burbank Blvd Widening ($6 million) for City of Burbank; and the I- 710 /Firestone Blvd Widening S ($10.7 million) for City of South Gate. AECOM is proposing to the City as the Prime consultant for the services. As such, we will be the singular entity responsible for all contractual, administrative, managerial and technical requirements. To supplement our in -house staff, AECOM has formed a teaming relationship with Safework, Sequoia Consultants, , and Coast Surveying, to provide safety oversight, material testing, and surveying services respectively. Those firms are consistent team partners of AECOM on projects of this nature. They are dependable, responsive and do quality work. While all the above summarized experience is necessary to get the work performed efficiently and cost effectively, at the end of the day it is the committed managers and staffing who will DELIVER. No firm is any better than the leadership it provides. We are anxious to perform the required services for the City and have no hesitation committing our A-Team to get the job done. Between myself serving as the Project Director, Project Manager Jim Hannigan, and Resident Engineer Samson Engeda, the City is getting three leaders who are among the very best (if not "the best ") in Southern California. The remaining leadership we are committing in specialty areas is all seasoned veterans in their respective specialty areas. Our proposed project organization and qualification of our leadership will be highlighted in a subsequent section of our submittal. m As project Director, I am proud to present this team and staff to the City of Newport Beach- In my role I will serve as the firm's primary representative and responsible for all duties from contract negotiations through project completion. Project Manager Jim Hannigan will serve as the alternate representative- Both of us are committed to do whatever it takes for the success of this project Peter Lim / Principal -in- Charge peter.lim @aecom.com / 949.293.6282 (cell) '— =------------------- - -- - -- Jim Hannigan / Project Manager Jim.hannigan@aecom.com / 858.205.7730 (cell) 999 Town & Country Road, Orange, CA 92868 We appreciate the opportunity to submit this proposal and look forward to continuing our working relationship with the City. Sincerely, J Peter Lim, PE Project Director /Sr. Vice President 7( m m 0 n h C W o' E LL E m d m 0 a C� n 2 m v H I� 1 ® AECOM 24 Technical Approach AECOM is one of the nation's leading firms for transportation infrastructure design, program management and construction management. Headquartered in Los Angeles, AECOM offers a project team with extensive experience in public construction, particularly in bridge seismic retrofits, working and coordinating with Caltrans. AECOM's CM /CEI Division specializes exclusively in providing full- service construction management in bridge seismic retrofit projects. AECOM has successfully completed construction management on some of the largest and most complex projects along the West Coast. As a result, the AECOM team is thoroughly familiar with the challenges of working within the State's highway system, Department of Fish & Game, USACE, and SCWRB. With our unchallenged experience in this area, we understand the importance of looking ahead to avoid potential problems associated with this work. And because we pride ourselves on the fact that we are proven problem solvers, and not just "paper pushers ", we will quickly mitigate unforeseen conditions when they are encountered - AECOM engineers and team members will provide solutions. We have provided construction management and engineering design services on numerous 0 assignments of very similar scope and nature to the Newport Beach Bridge Seismic Retrofit Projects and will bring this experience to carry out this project to a successful completion. The AECOM Team's mission is to deliver an exemplary project that all involved are proud to claim as their own. Summary Project Approach and Schedule The purpose of the project is to provide construction management services in support of the City's seismic.retrofit program. The City is proposing seismic retrofits on three bridges, they are: Goldenrod Pedestrian Overcrossing (POC), Jamboree Road over San Diego Creek (Northbound) and Jamboree Road over San Diego Creek (Southbound). The Goldenrod POC retrofit includes strengthening the bent caps with concrete bolsters, column casings, and strengthening the abutments with drill and bond dowels in preparation of increasing the abutment stem walls. Jamboree Road has both northbound and southbound structures to retrofit over the San Diego Creek. The northbound structure consists of abutment shear wafts, infill walls between columns at the bents, and structure approach slabs. The Southbound structure includes abutment back wall retrofit and reconstruction of structure approach slab. We understand that the environmental clearance, right -of -way certifications, and the final design have been completed. The City of Newport Beach is anticipating for construction to begin in November of 2010. The total project is estimated to be approximately $1.7 million and has various funding sources including: California Prop 1 B funds and Federal HBRR funds. With the California Transportation Commission as the responsible party to ensure allocation of Prop 1 B funds to the various agencies, one of the requirements is for the City to comply with a Baseline Agreement which contains a proposed timeline of committed target dates that are required to be met for the project. The schedule becomes very critical and shall be supported and adhered to in order to not only obtain the funds for this project yet set the precedence for other future projects the City may on the project list for Prop 1 B funds. Choosing the right construction management partner is key. The City needs a team that understands the organization and its goals, knows how to interface with Caltrans and regulatory agencies, can effectively and efficiently manage a contractor to build the project within schedule and budget constraints, is well- versed in traffic management far safe pedestrian and vehicular movement through the construction site, and understands the sensitivities of businesses and residents and the importance of quick response to address their concerns. AECOM is that partner. Newport Beach Bridge Seismic Retrofit Projects it AECOM ZS iroject Elements ,n reviewing the site, we have identified key issues facing the City and your construction manager in delivering the Newport Beach Bridge Seismic Retrofit Projects: safety, construction staging, traffic handling, and coordination. Safety Our rote starts with "Safety" and we begin with our pre- construction surveys. One of our prime concerns are overhead power lines as well as underground duct banks located near live traffic, both distribution and transmission lines. During construction activity, we must take precautions so that this high voltage electricity does not are to a crane or inspectors working nearby. Under the direction of AECOM Team safety officer, we will ensure that AECOM internal "Code of Safe Practices" fully complies with any and all local, State, and Federal safety codes and regulations. In addition the safety officer will ensure that all personnel adopt the "Code of Safe Practices" that is published bi- weekly. The safety officer will also conduct weekly safety meeting and minutes of meetings will be properly documented. On a regular basis, the AECOM Safety Officer will inspect the job site to ensure that the "Code of Safe Practices" is being followed and that the equipment is being operated in accordance the manufacturer recommendations. Traffic Handling and Pedestrian/Vehicular Access The City has made commitments to local businesses and property owners to maintain access and a level of parking during construction, it is important for your construction manager to be your proxy on site to honor those commitments. The specifications need to clearly state that the Contractor is responsible for 24/7 access for the business and have capability of pedestrian crossings and each at ' "3grade crossing location. One way to mitigate any inconvenience is for the Contractor to conduct night `,�_Jwork in lieu of partially closing a particular driveway during the day— proper planning is essential. Safe movement of vehicles and pedestrians through the job site, protection for workers, removing unnecessary obstacles, providing clean passage for pedestrians are all key considerations. Handling traffic during construction also means we make early coordination and close communication with Caltrans District 12 personnel, and the City staff for any actions that could affect traffic conditions within their right -of -way. The construction manager has a responsibility to review the staging of the project plans and bring attention to not only risks, but also any alternative staging of construction that will mitigate time on the project which will serve as cost savings to the City as well as promote efficiency. Coordination and Utility Relocations The construction manager will be responsible for the day to day administration and coordination of the project. The CM will act as the point of contact between Contractor, consultant surveyors, consultant material testers, AGENCY, Designer, and other project participants. All the project information related to the construction contract shalt flow through the construction manager to /from the contractor and all other project participants. Coordination Proper coordination with the City, Caltrans, and various regulatory agencies is important to verify that we meet their expectations. With weekly construction meetings along with special coordination meetings, coordination efforts and reviewing the requirements prior to the work helps with ensuring compliance to all regulatory permits on the project. Newport Beach Bridge Seismic Retrofit Projects .73 AECOM 26 Public Outreach The construction manager shall work directly with the City's Public Outreach team with timely 0 notifications, and up to date progress on lane closures, traffic control, phasing /staging notifications o for the media, residents and business owners within the vicinity of the project. ° N O AECOM's Project Approach We have a team of highly experienced construction management and scheduling professionals available to review the plans and special provisions for accuracy and completeness. Our team members are very familiar with Caltrans standard plans and specifications and will ensure the Contractor constructs the project in accordance with not only Caltrans standard plans and specification but also the City of Newport Beach's standard plans and specifications. Proactive vs. Reactive As part of any construction management project, identifying and preparing for potential risks is an important early action, hence bringing on board a construction manager in advance of construction is an asset to the project and has the potential to save costs and time on the project. AECOM can serve the Citywith a service prior to construction which is commonly referred to as the preconstruction phase. During this phase, tasks include development of a Resident Engineer's Manual for the project which serves as a Project Management & Execution Plan for CM services to the client. This manual explicitly informs the client of document control, contract administration, and management of the project from Preconstruction Phase, Construction Phase, and the Post Construction Phase of work. The AECOM team shall perform a preliminary constructability review to reassure the City of Newport Beach that all potential risks have been property identified prior to going out to construction. For each risk identified, we assess probability and impact, define party best able to manage the risk, and propose mitigation or elimination strategies. In general, during the construction phase, the CM shalt have primary responsibility for: • Construction completion on schedule, within budget, and in accordance with the contract documents and sound safety practices. • Proper documentation, negotiation and processing of ail changes and claims. • Processing of progress payments in a timely manner. • Performance of required field quality control surveillance and inspections. • Third Party Coordination The CM shalt ensure that all contract deliverables are property documented and promptly processed. These construction /procurement contract deliverables include, but are not limited to: • Shop drawings, working drawings, and vendor data • QA /QC Procedures • As-buitt drawings • Inspection and testing records • Contractor Construction Baseline Schedule and updates • RFI's and RFCs • Payment requests As the authorized representative of the AGENCY, the CM's detailed responsibilities include: • Coordinate all construction /procurement activity, including interface with adjacent contracts. • Manage construction support activities. • Document, verify and report contractual progress. • Monitor Contractor progress against the approved schedule. • Work with Contractor to develop and implement corrective actions to mitigate delays. Newport Beach Bridge Seismic Retrofit Projects ® AECONI 27 • Review Contractor submittals for content and format. • Process and track submittals to and from the reviewing entity. • Manage the change control process, including processing valid contract change notices /orders. • Maintain contract deficiency lists. • Implement claims mitigation and claims resolution actions. • Provide surveillance of in- process work and acceptance testing. • Monitor the Contractor's OC Program, where applicable. • Monitor the Contractor's Safety Program. • Monitor and report Contractor compliance with the federal, state and local government requirements. • Coordinate survey work performed by CM surveyors. • Coordinate "Third Party" services and work affecting construction. • Process and coordinate Requests for Information.(RFIs) from contractors. • Monitor and verify delivery of equipment and material to job -site. • Recommend expedited construction techniques. • Monitor contract compliance with environmental and archaeological requirements. • Monitor performance and startup tests. • Enforce warranty provisions of contracts. • Manage the contract closeout process. Post Construction Phase consists of wrapping up any potential claim or claim issues, as built plans and schedule, as long as prepare project closeout paperwork for the project in accordance with the (LAPM Chapter 17) Caltrans Local Assistance Procedures Manual. Delivering all project records and processing final payment to the Contractor and obtain Project acceptance and completion forms ~�om all parties involved. rnmary of Scope of Services (Responsibility Matrix) In the figure below, we demonstrate an example of a typical responsibility matrix we may generate for a typical grade separation project. The scope of services is based on performing the following construction phase services outlined in the Responsibility Matrix on the next page. Schedule We review the contractor's initial baseline schedule to verify that it is a reasonable, practical, and comprehensive plan for accomplishing the work. We look to see whether or not the contractor has provided the appropriate schedule interfaces with the other project activities, such as submittal review, material deliveries, and agency reviews. To better inform the Contractor of the constraints to the project, we conduct a preconstruction schedule meeting where we inform the contractor of details pertaining to the schedule contents, formats, contractual requirements, and update submissions. We also review the contractor's monthly schedule updates, perform time impact analyses, review and approve recovery and as -built schedules. We maintain an as -built schedule throughout the project. We can typically rely on the as -built information provided by the contractor through its monthly schedule updates to create the record of as -built construction. Sometimes there are unknown or unforeseen impacts to the project which are generated by the agency or third parties. When this arises, we generally try and foresee these issues in advance and /or mitigate the delay as soon as possible. Taking a proactive approach and generating work a- rounds and /or accelerating the project with certain "What -if" scenarios to the schedule. We generate a cost nd time impact/savings to each scenario for the client as options to mitigate a delay. ® Newport Beach Bridge Seismic Retrofit Projects m 0 0 a N U AECOM zs PERSONNEL RESPONSIBILITY MATRIX a Legend: v P- Primary Responsibility v 3 S- Support Role v a v °' m R - Review a A - Approve A ,W o C- Consult if Necessary 4d v v a v - 2 U 6 2 d h N Resident Engineer's Manual C R Constructability Analysis P C P P S Initial Construction Schedule and Project Budget Analysis P P Bid Documents (Review and Bid Tabulations) S P Pre - Condition Survey (Photos / Documentation) C S P Contract Award (Bid Analysis, Insurance, Sureties etc.) S P Pre - Construction Meetings S S P 5 S S Progress Management & Administration C P 5 Progress Schedule C P 5 Construction Coordination S P S Changes /Claims P 5 S Monitor, Review, Approve (SWPPP A D) Compliance P S Construction Safety C P S S- Utility Coordination P S Coordinate Flagpersons and Watchpersons P S Quality Control Inspection and IDR R P Materials Testing and Support Services S S P Environmental Services R 5 Progress Payments P S 5 Submittals and RFI's (Requests for Information) R S Conferences /Meetings P S Reports and Records R S Review of Traffic Plans (Detours and Lane Closures) R S Survey Support (QC) Services S S S Public Affairs P Document Control R S Contractor Insurance P Labor Compliance and DBE Monitoring P As -Built Drawings R S Other Services as Required S P 5 Contract Closeout S I P 5 S 5 S S Newport Beach Bridge Seismic Retrofit Projects .?t h 0 a a V __ __ _ _. i . .., p E...,,, ��_ > i . .., p Local Assistance Procedures Manual Exhibit 10 -H i Construction Management (CM) Services for Newport Beach Seismic Retorfit Project C i CONTRACT NO. 358 -ST DIRECT LABOR (SPECIFY) Range $6500 $85.00 8 $55.00 Consultant: AECOM $ 57.5E $45.00 $60.00 7 $35.00 845.00 $ 46.35 $45.00 $50.00 $55.00 Classification Name Project Manager Jim Hannigan, PE Raidem Engineer/Str u-m Rep. Samson Engcda, PE E Structures Inspector Sr.. Vander Mey, PE Labor Compiance_ Shari Gaffney i Pmjecr Convols/Scheduler Riccardo FajN. Conswetabilky Review Gereld Schubert, PE Subtotal Direct Labor DIRECT LABOR (SPECIFY) Range $6500 $85.00 8 $55.00 865.00 $ 57.5E $45.00 $60.00 7 $35.00 845.00 $ 46.35 $45.00 $50.00 $55.00 $6500 Anticiapted Salary Raise None. Indirect Rate (Fringe Benefits + Overhead + General and Hate Fee (Profit) s - Other Direct Costs i� 7 i 9 l 1 1 Date: August 14, 2010 Hours Hourly Rate Year Ending 2010 8 $ 80.0( 1160 $ 57.5E 0 % 54.47 7 8 39.33 28 $ 46.35 0 $ 58.48 $ 68,982.71 $ 0.80 121.6% $ 84,020.94 8% $ 12,240.29 Travel Costs (Form 60-2) $ 0 Equipment and Supplies (Form 60-2) $ 9,430.00 All Other Direct Costs (See Form 60-2)1$ 9.430.00 Totaf SubContractor Costs $ 12,000.00 Subcontractor Adminstration $ Local Assistance Procedures Manual Exhibit 10 -H Other Other Direct Cost Construction Management (CM) Services for Newport Beach Seismic Retorfit Project CONTRACT NO. 358 -ST Date: August 14, 2010 Consultant: AECOM OTHER DIRECT COSTS SCHEDULE 1. All ODC other than Vehicle Usage and Monthly Cellular Charges will be billed Actual Costs with Outside Vendors Invoice 2. Vehicle Usage Cost includes all insuracne, maintenance and operating costs. Vehicle Usage Rate will be fixed for the duration of the contract with no increase for allowance for increase gas prices, insurance, maintenance and operation costs. 3. Mileage Rate show above is for estimate only. Mileage Rate will be reimbursed in accordance with IRS Standard Mileage Rates. ?11 other Travel and Subsistence will be reimbursed in accordance with DPA guidelines for non - exempt State employees ,24 CITY OF Newport Beach Construction Management Services: Newport Beach Seismic Retrofit Project Labor Person -Hours Calculation CLASSIFICATION FIRM 4 Post Construction Pre-Construction Phase CONSTRUCTION PHASE Post Construction 2010 201,1 2011 Total Hours Total Hours Aug Oct Nov Dec Jan Feb Mar Apr May Sept r Apr 1 0 2 0 3 4 0 1 8 1 6 1 7 1 8 1 9 9 10 1 2 I Project Manager AI�COM Resident Engineer /Structure Rep, Ar�.Com 8 r40 80 166 168 166 168 168 168 24 1160 Structures Inspector AT�COM 0 0 0 0 0 1 0 1 0 1 0 1 0 0 0 1 1 7 Labor Complance AlICOM 0 0 0 1 Project Controls/Scheduler Ar.COM 0 0 12 2 1 2 1 2 2 2 2 4 28 Constmetability Review ATICOM 16 4 0 0 0 0 0 0 0 0 Materials Inspection squ'l' 0 0 0 8 8 8 8 0 ISurveyor (AsINeeded) 0 0 0 0 0 0 0 0 TOTAL PERSONNEL HOURS 24 44 22 ISO 180 160 180 31 180