Loading...
HomeMy WebLinkAboutC-5444 - PSA for SCADA Upgrade Preliminary PlanPROFESSIONAL SERVICES AGREEMENT WITH DELTA SYSTEMS ENGINEERING FOR SCADA UPGRADE PRELIMINARY PLAN THIS AGREEMENT FQR PROFESS SERVICES (Agreement ") is made and entered into as of this �i �! l day of 13 ( "Effective Date ") by and between the CITY OF NEWPORT EACH, a California Municipal Corporation ( "City ") and DELTA SYSTEMS ENGINEERING, an Arizona corporation ( "Consultant "), whose address is 4157 Avenida De La Plata, Suite 106, Oceanside, CA 92056 and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to prepare a preliminary plan, report, and cost estimate for the purpose of establishing a budget to perform immediate upgrades in 2013, and future upgrades to the City's SCADA system ( "Project "). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. The principal member of Consultant for purposes of Project shall be Brian D. Downing. E. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1111 The term of this Agreement shall commence on the Effective Date, and shall terminate on December 31, 2013 unless terminated earlier as set forth herein. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ( "Services " or "Work "). The City may elect to delete certain Services within the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.1.1 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) days of the occurrence causing the delay to the other party so that all delays can be addressed. 12 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator (as defined in Section 6 below) not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.3 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by fax, hand - delivery or mall. a • - _: �tCsl`►�- �j[�Ie]F'3�I4tilayl 41 City shall pay Consultant for the Services on a flat rate basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Thirty Two Thousand Dollars and 00/100 ($32,040.00) without priorwritten authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and /or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement, or specifically approved in writing in advance by City. DELTA SYSTEMS ENGINEERING Page 2 4.4 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project, This Project Manager shall be available to City at all reasonable times during the Agreement term, Consultant has designated Brian D. Downing to be its Project Manager, Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City "s approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to the City. 6. ADMINISTRATION This Agreement will be administered by the Municipal Operations. George Murdoch, Utilities General Manager or his designee, shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator or his designee shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will DELTA SYSTEMS ENGINEERING Page 3 perform all Services in a manner commensurate with the highest professional standards. For purposes of this Agreement, the phrase "highest professional standards" shall mean those standards of practice recognized by one (1) or more first - class firms performing similar work under similar circumstances. 8.2 All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement; all applicable federal, state and local laws; and the highest professional standard. 83 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.4 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. W 101 Roil 9 F-11:4 6 IN 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents and employees (collectively, the "Indemnified Parties ") from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any breach of the terms and conditions of this Agreement, any Work performed or Services provided under this Agreement including, without limitation, defects in workmanship or materials or Consultant's presence or activities conducted on the Project (including the negligent and /or willful acts, errors and /or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorney's fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy DELTA SYSTEMS ENGINEERING Page 4 limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. fi[i>11lk 17474ki1114Z III KiZi7ai7_7 i7:7 It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Contractor or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. iK1•JZ�ZcIZ�'�? Consultant is responsible for keeping the Project Administrator and /or his duly authorized designee informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. DELTA SYSTEMS ENGINEERING Page 5 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint-venture or syndicate or cotenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power, or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint - venture. 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. The City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and the City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. DELTA SYSTEMS ENGINEERING Page 6 18. COMPUTER DELIVERABLES All written documents shall be transmitted to City in formats compatible with Microsoft Office and /or viewable with Adobe Acrobat. • *_t All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. INTELLECTUAL PROPERTY INDEMNITY The Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 21. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. Fk #TTHtM10711111 iV, City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or his /her designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 23. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would DELTA SYSTEMS ENGINEERING Page - have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 25. CONFLICTS OF INTEREST 25.1 The Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 25.2 If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 26. NOTICES 26.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first - class mail, addressed as hereinafter provided. All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: George Murdoch, Utiities General Manager Municipal Operations City of Newport Beach 3300 Newport Boulevard PO Box 1768 Newport Beach, CA 92658 Phone: 949-718-3401 Fax: 949 -646 -5204 DELTA SYSTEMS ENGINEERING Page 8 26.2 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Brian D. Downing DELTA SYSTEMS ENGINEERING 4167 Avenida De La Plata, Suite 106 Oceanside, CA 92056 Phone: 602 - 266 -4658 Fax: 602 - 266 -4953 27. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. The Consultant and the City expressly agree that in addition to any claims filing requirements set forth in the Agreement, the Consultant shall be required to file any claim the Consultant may have against the City in strict conformance with the Tort Claims Act (Government Code sections 900 et seq.). 28. TERMINATION 28.1 In the event that either parry fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 28.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days prior written notice to Consultant. in the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. DELTA SYSTEMS ENGINEERING Page 9 29. STANDARD PROVISIONS 29.1 Compliance with all Laws. Consultant shall at its own cost and expense comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 29.2 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 293 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 29.4 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 29.5 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 29.6 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 29.7 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 29.8 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 29.9 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex, age or any other impermissible basis under law. DELTA SYSTEMS ENGINEERING Page 10 29.10 No Attorney's Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorney's fees. 29.11 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] DELTA SYSTEMS ENGINEERING Page 11 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S OFFICE Date: 3/ 1 x/13 CITY OF NE A Californ�iy i Date: �I` / f BEACH, al corporation By: U` By: - Aaron ar ar Harmon City Attorney 3) Municipal Operations Director ATTEST: Date: 4. I, 4 - P By: k Vl , b.==� Leilani I. Brown City Clerk CONSULTANT: DELTA SYSTEMS ENGINEERING, an Arizona corporation Date: Brian D. Downing President Date: 2111 // By; Brian D. Downing Treasurer [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements DELTA SYSTEMS ENGINEERING Page 12 EXHIBIT A SCOPE OF SERVICES SCADA Upgrade Preliminary Plan Scope of Services Consultant Responsibilities 1. Prepare a preliminary plan, report, and cost estimate for the purpose of establishing a budget to perform immediate upgrades in 2013, and future upgrades to the City's SCADA system. 2. Perform assessments of the exiting SCADA systems based on an October 5, 2012 report, to include the following items: a. Prepare an as -built network diagram of the existing SCADA system architecture in Microsoft Visio or AutoCAD showing the tiered network configuration of: i. PLCs ii. SCADA communication connections iii. 10 Servers iv. Domain controller v. GR (Galaxy Repository) database vi. HMI city workstations vii. Network switches viii. and other major SCADA network connected devices b. Identify IP addresses of existing devices, and spare addresses to be used for future devices. c. Conduct one (1) workshop meeting with City SCADA and IT staff to collect and review the network information. d. Assess current SCADA InTouch application: 's. Prepare a brief report of recommended improvements and programming changes ii. Cost estimate for making the changes to the new upgraded InTouch application. iii. Conduct one (1) workshop meeting with City SCADA staff to discuss current InTouch application and desired improvements and performance enhancements, including preferred mobile devices to access the SCADA server. e. Assess the condition of the existing Allen Bradley SLC 5103 -04 PLC -based remote telemetry units (RTUs). DELTA SYSTEMS ENGINEERING Page A -1 i. Conduct one (1) workshop meeting to review the existing drawings and discuss the City's goals for the RTU and radio communication network upgrades. ii. Conduct site visits with City staff to inspect BTUs and verify as -built drawings. iii. Assess the condition of the existing radio communication network. iv. Prepare a brief report and cost estimate for recommended upgrades. 3. Prepare and submit a draft implementation schedule in Microsoft Project, with an anticipated start date of July 2013. 4. Draft report review workshop meeting. 5. Final report submittal meeting. City Responsibilities • Provide drawings of existing computer network architecture to be verified during assessment phase of this project. • Provide record drawings or as -built drawings of the Alien Bradley PLC -based RTUs for use during the assessment phase for field verification of existing conditions. • Provide documented copies of the current Allen Bradley PLC programs for review for possible conversion and upgrade to new Allen Bradley model PLCs. • Provide copy of current Wonderware InTouch application for review during the assessment phase of the project. Deliverables • Workshop and meeting minutes. • SCADA network architecture drawing for review and comment by the City. Preliminary Plan in draft form for review and comment by the City, containing recommendation and cost estimates for new SCADA server hardware, Wonderware and server software licenses, engineering and programming labor cost for implementation of the upgrades, engineering, material and labor cost for PLC and radio system upgrades. • Preliminary Plan final submittal. • The final report shall be stamped by a California registered engineer. DELTA SYSTEMS ENGINEERING Page A -2 EXHIBIT B SCHEDULE OF BILLING RATES Billing Rates: Fees for the aforementioned work will be for services provided on a lump sum basis and will not exceed Thirty Thousand Dollars ($30,000.00). Reimbursable expenses will be charged at cost, and will not exceed Two Thousand Dollars ($2,000.00). Any additional services requested by City that are not included herein will be charged at the Standard Hourly Rates as shown in the table below. Principal, PE Senior Engineer Junior Engineer Construction Manager Admin $206.00 $170.00 $125.00 $134.00 $55.00 _I DELTA SYSTEMS ENGINEERING Page B -1 1. INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1.1 Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 1.2 Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager, 1.3 Coverage Requirements. 1.3.1 Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. 1.3.1.1 Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. 1.3.2 General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, products - completed operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract) with no endorsement or modification limiting the scope of coverage for liability assumed under a contract. 1.3.3 Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of the Consultant arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. DELTA SYSTEMS ENGINEERING Page C -1 1.3.4 Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the effective date of this agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the services required by this agreement. 1.4 Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: 1.4.1 Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. 1.4.2 Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, but not including professional liability, shall provide or be endorsed to provide that City and its officers, officials, employees, and agents shall be included as insureds under such policies. 1.4.3 Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self - insurance maintained by City. 1.4.4 Notice of Cancellation. All policies shall provide City with thirty (30) days notice of cancellation (except for nonpayment for which ten (10) days notice is required) or nonrenewai of coverage for each required coverage. 1.5 Additional Agreements Between the Parties. The parties hereby agree to the following: 1.5.1 Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. 1.5.2 City's Right to Revise Requirements, The City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving the Consultant sixty (60) days advance written notice of such change. If such change results in substantial additional cost to the Consultant, the City and Consultant may renegotiate Consultant's compensation. 1.5.3 Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of the City to inform Consultant of non - compliance with any requirement imposes no additional obligations on the City nor does it waive any rights hereunder. 1.5.4 Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. 1.5.5 Self - insured Retentions. Any self- insured retentions must be declared to and approved by City. City reserves the right to require that self- insured retentions be eliminated, lowered, or replaced by a deductible. Self - insurance will not be considered to comply with these requirements unless approved by City. 1.5.6 City Remedies for Non Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. 1.5.7 Timely Notice of Claims. Consultant shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Consultant's performance under this Agreement, and that involve or may involve coverage under any of the required liability policies. 1.5.8 Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. DELTA SYSTEMS ENGINEERING Page C -3 CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach. * Date Received: 3/14/13 Dept. /Contact Received From: Raymund Date Completed: 3/15/13 Sent to: Raymund By: Renee Company /Person required to have certificate: Delta Systems Engineering, Inc. Type of contract: All Other I. GENERAL LIABILITY EFFECTIVE /EXPIRATION DATE: 6 -01- 12/6 -01 -13 A. INSURANCE COMPANY: Travelers Indemnity Co. of Connecticut B. AM BEST RATING (A-: VII or greater): A +: XV C. ADMITTED Company (Must be California Admitted): Is Company admitted in California? N Yes ❑ No D. LIMITS (Must be $1M or greater): What is limit provided? $1,000,000 / $2,000,000 E. ADDITIONAL INSURED ENDORSEMENT— please attach N Yes ❑ No F. PRODUCTS AND COMPLETED OPERATIONS (Must (What is limits provided ?) N/A include): Is it included? (completed Operations status does F. PRIMARY & NON - CONTRIBUTORY WORDING (For Waste not apply to Waste Haulers or Recreation) N Yes ❑ No G. ADDITIONAL INSURED FOR PRODUCTS AND G. HIRED AND NON -OWNED AUTO ONLY: ❑ N/A COMPLETED OPERATIONS ENDORSEMENT (completed H. NOTICE OF CANCELLATION: ❑ N/A Operations status does not apply to Waste Haulers) N Yes ❑ No H. ADDITIONAL INSURED WORDING TO INCLUDE (The City its officers, officials, employees and volunteers): Is it included? N Yes ❑ No I. PRIMARY & NON - CONTRIBUTORY WORDING (Must be included): Is it included? N Yes ❑ No J. CAUTION! (Confirm that loss or liability of the named insured is not limited solely by their negligence) Does endorsement include "solely by negligence" wording? ❑ Yes N No K. ELECTED SCMAF COVERAGE (RECREATION ONLY): N N/A ❑ Yes ❑ No L. NOTICE OF CANCELLATION: ❑ N/A N Yes ❑ No II. AUTOMOBILE LIABILITY EFFECTIVE /EXPIRATION DATE: 6 -01- 12/6 -01 -13 A. INSURANCE COMPANY: Travelers Property Casualty Co. of America B. AM BEST RATING (A-: VII or greater) A +: XV C. ADMITTED COMPANY (Must be California Admitted): Is Company admitted in California? N Yes ❑, No D. LIMITS - If Employees (Must be $1 M min. BI & PD and $500,000 UM, $2M min for Waste Haulers): What is limits provided? 1,000,000 E. LIMITS Waiver of Auto Insurance / Proof of coverage (if individual) (What is limits provided ?) N/A F. PRIMARY & NON - CONTRIBUTORY WORDING (For Waste Haulers only): N N/A ❑ Yes ❑ No G. HIRED AND NON -OWNED AUTO ONLY: ❑ N/A ❑ Yes N No H. NOTICE OF CANCELLATION: ❑ N/A N Yes ❑ No DI. VVORKEFS'Q0MPENS/{T|{>N EFFECTlVE/EXP|RAT|0NDkTE: 6-0 A. INSURANCE COMPANY: Travelers Prop of America B. AM BEST RATING (A^:VUorgneeh:r): C. ADMITTED Company (Must be California Ad,nkted): N Yes FlNo D. VVORKERS'C[}WYPENSAT0NL(WYiT: Statutory 23 Yes FlNn E. EMPLOYERS' LIABILITY LIMIT (Must be$1&8orgreater) 1,000,000 F. WAIVER 0F SUBROGATION (To ino|ude): |sitincluded? ZYou El No G. SIGNED WORKERS' COMPENSATION EXEMPTION FORM: E N/A [J Yes FlNv H. NOTICE 8FCANCELLATION: Fl N/A N Yes F7Nu ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED Ty. PROFESSIONAL LIABILITY \/ POLLUTION LIABILITY V BUILDERS RISK HAVE ALL ABOVE REQUIREMENTS BEEN MET? IF NO, WHICH ITEMS NEED TO BE COMPLETED? Agent of Alliant Insurance Services Date Broker of record for the City of Newport Beach 0 N/A El Yes El No 0 N/A El Yes F1 No Z Yes El No RISK MANAGEMENT APPROVAL REQUIRED Non-admittwd carrier rated less than ___; Self Insured Retention or Deductible greater than $ 0 N/A E] Yes F� No Reason for Risk Management Approved: Risk Management Date * Subject to the terms of the contract.