Loading...
HomeMy WebLinkAboutC-5593 - PSA for Network and Computer Security Consulting Servicesco PROFESSIONAL SERVICES AGREEMENT WITH ACCUVANT INC. FOR �J) NETWORK AND COMPUTER SECURITY CONSULTING AND SERVICES I THIS PROFESSIONAL SERVICES AGREEMENT ( "Agreement ") is made and v entered into as of this 20th day of August 2013( "Effective Date "), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ( "City"), and ACCUVANT INC., a Delaware corporation ( "Consultant "), whose address is 1125 17th St., Suite 1700, Denver, CO 82020, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide network and computer security consulting and related services ( "Project"). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: 1. TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on June 30, 2014, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services and Schedule of Billing Rates attached hereto as Exhibit A and incorporated herein by reference ( "Services" or "Work "). City may elect to delete certain Services within the Scope of Services at its sole discretion. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 33 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand - delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Scope of Services and Schedule of Billing Rates attached hereto as Exhibit A. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Eleven Thousand Dollars and 00/100 ($11,000.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and /or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit A to this Agreement or specifically approved in writing in advance by City. 4.4 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. ACCUVANT INC. Page 2 Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit A. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Ray Burgess to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Police Department ( "Newport Beach Police Department "). The City's Police Computer Systems Manager or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with the highest professional standards. For purposes of this Agreement, the phrase "highest professional standards" shall mean those standards of practice recognized by one (1) or more first - class firms performing similar work under similar circumstances. ACCUVANT INC. •..- 8.2 All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws, and the highest professional standard. 8.3 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.4 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers and employees (collectively, the "Indemnified Parties") from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, reasonable attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise from or in any manner relate (directly or indirectly) to any breach of the terms and conditions of this Agreement, any Work performed or Services provided under this Agreement including, without limitation, defects in workmanship or materials or Consultant's presence or activities conducted on the Project (including the negligent, reckless, and/or willful acts, errors and /or omissions of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them). 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by Consultant. 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of ACCUVANT INC. Page 4 conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit B, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or co- tenancy, which shall result in changing ACCUVANT INC. Page 5 the control of Consultant. Control means fifty percent (50 %) or more of the voting power or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. 17.3 All written documents shall be transmitted to City in formats compatible with Microsoft Office and/or viewable with Adobe Acrobat. 18. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. ACCUVANT INC. '.i' s 19. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 21. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 22. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and /or restoration expense shall be borne by Consultant. (Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. ACCUVANT INC. Page 7 24. CONFLICTS OF INTEREST 24.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 24.2 If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 25. NOTICES 25.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 25.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: John Veale, Police Computer Systems Manager Police Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 25.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Director of Legal Affairs ACCUVANT INC. 1125 17th St., Suite 1700, Denver, CO 80202 26. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request ACCUVANT INC. Page 8 for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 27. TERMINATION 27.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 27.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 28. STANDARD PROVISIONS 28.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 28.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 28.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 28.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged ACCtNANT INC. Page .9 herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 28.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 28.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 28.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 28.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 28.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 28.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex, age or any other impermissible basis under law. 28.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 28.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. 28.13 Limitation of Liability. 28.13.1 Except as otherwise expressly set forth herein, consultant makes no warranties, guarantees, or representations of any kind, express or implied, with respect to the operation, capacity, speed, functionality, qualifications, or capabilities of the Aresight Logger System. 28.13.2 The aggregate amount of any liability of consultant, its Officers, Directors, Agents, Subsidiaries, Affiliates, Partners, and Contractors, for one or more claims arising from or relating to any deficiencies with respect to this Agreement, shall not exceed in the aggregate, three times the amount paid to consultant hereunder ACCLIVANT INC. Page 10 for the performance of Services hereunder. Notwithstanding the foregoing, this limitation does not apply to claims that arise from gross negligence or intentional misconduct by either party. [SIGNATURES ON NEXT PAGE] ACCUVANT INC. Page 11 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY Date: AT�ORTXY'S OFFICE Aaron C. Harp City Attorney ATTEST: Date: By: ow Leilani I. Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation Date: `� -1Z- \l� By: Jay ns Chef of Police CONSULTANT: ACCUVANT INC., a Delaware corporation Date: 7'-3-13 By: C-AiCV Patrick Farre Director of Legal Affairs Date: Q- 3 _t 3 B W, 0, By: David Roshak Chief Financial Officer [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services and Schedule of Billing Rates Exhibit B — Insurance Requirements ACCUVANT INC. Page 12 EXHIBIT A SCOPE OF SERVICES AND SCHEDULE OF BILLING RATES ACCUVANT INC. Page A -1 ArcSight Logger Deployment Project Number. SoCal- OP88793 Prepared By: Ray Burgess / Juan Ruben SAnchex May 29. 2013 Revision: #1.4 SECURITY STRATEGY. EXPERTLY EXECUTED. Experts in Information Security Solutions ArcSight Logger Deployment ACCUVM�jT Newport Beach Police Department - Project #: SoCal-OP88793 Table of Contents ProjectOverview °.~.°°°°^~...-.^.~~~~°"""°"°"~°°~^~-.~.°~^~~~~..~.~.,.~°°^~^,.--^..~.°3 Background.......................................... ~.~~~^~..~^^°°°°~~~~.^-..°~~~.~.~..~^~°^^°~.~..~~-. 3 Goals& Objectives. ..^ ........................ ........... . ... ^-....................................................................................... 3 TaskList ................ ............................ ......................... ^......... .~~~~.^^.°.°^~^...~~ ............. ............... ~.~....3 ProjectScope .................................... ..................................................................................... ° ................... -4 Professional Considerations °.~-°~."~~,°~.~~.--.^^°^°°°°°"°-_-~~°^°°^...~..~.^^~~.......^°^^8 Scheduling...~.~°^°^_.~.~~.~.._...~~.~,°°°°°~°~~....^°°^°~.,......~.^^~~~~..^°^~8 Pm»bmt Completion .~°^,,°...~..~°.~.......°~~~,...~°.~.,°..~..~°~°°°.~°"°°.°°,.8 ChangeIn Scope of Services ......... ^^.^^,°"..~.°^ ..... °^°^°^"°^°~~~~._~.°^°^-,°°~~...~.~.°'"°,°°°°~....^~~^8 "act Assumptions ........... ^°~,' ...... --- ...... . ... ......... ~~~~~~°.°^°"°,°~~~-.~_-.-'~~"°.-~.~~.~..^8 Project Management Approach ........ .°.°,,°...-~_~.°^°^^°.°°^°^,.-..~...~.~-...-~^-.~.^~...~~,,9 Terms.................................................. ...^.~...~.°^°°^°°,^~~...-~. ............................................... 10 ProjectInformation _-..~..~~...~.~^-°°^".......,_^°,°_._~...~~°°°~.-._..°^^^°°^°.°°.,=,1x ProjectLocation ............................................................................................................................................ 11 ClientCondactm ......... . .................................... .... ..................................... ...~°°°°.~^,`°.^°~~~~.,~^°A1 AuammnantContacts ....... ^ ........................ - ....... .^^^~^..^.^°^^°~.~.-~.~~°,°°°"^,°,,,.~~.^.,~.~,.~.~~~~.~~. I I Project Fees, Expenses, Payment Schedule ............................................... .................................................... 72 Fees.......................... ...................... ............................... .~~~.~.°°^,.°.^°°-.~.....^°°°°^.°°°°...t2 PaymentSchedule ................................ . ................................................ .......................... ......................... 12 Travel& Expenses ~,°^.°..°.~..~.°,,°,.,.°.^^°"°°°^°^°--...~~~^,~.,._.-.~.~^°°°^,^'.°°°°°^12 Authorization............ ^.^°~^.~~°..°^°^°.°°^.^,. ............................................................ .~._~~.~^~,.~.~,~..~°12 Appendix A~ Equipment and Log Source Ubt~ ................ ........... ......~~.^^^..... ^~....~~..~~~.~.~.~~. 13 SystemInformation °..,^^°°°°^°°°._^...~^..~..~°°^°^°^^~~.~~^~.^^,,^,^^...~_^°^,^^°^^~°~°~~'.13 LogSources ........... ........................................................................................................... . ................... 13 Appmndkx 8~S|EK« Pro-Installation Preparation Steps ,.~.°~,...-^..-~°°^°.--^..~._^,°°~^.°°°.°..14 Appendix C~Minimum Recommended Logging Policy ....... ^ .......................................................................... 16 RetentionPeriod ~.°°°°~~.~~~ ........................................ ^......... .......... -,°°°° .............................. � ......... 16 Authentication..........~.°....^°^°`°°..^,^~........'`.~. -- .~^.. ....°°°°..°^°~~.........^..^...°^...^'..°.^°"°^"'16 MAC................................................................................. . ......................................................................... 1& Access ar Modification Nf Sensitive Fileg°~-~..^..°°°°°^"°°.....°.°.^...~..°°°.~^.,..~...... 17 NetworkDevices ................................ ........................................................... ..................... ....................... 17 S|ENKCemtrallzed Log Management Considerations ^".^^°,°~._.....°,~^°.°"~..~~^ ...................... 17 Revhdpz#ID Pap 2 of 19 ACCUTA' j Newport Beach Police Project Overview Background Newport Beach Police Department is in the process of deploying ArcSight Logger for the collection of events from Its security and Infrastructure devices for correlation, alerting and reporting purposes. The goal of this project Is to meet the FBI's Criminal Justice Information Systems (CJIS) Security Policy (Version 51, dated 711312612) requirements for Auditing and Accountability. Newport Beach Police Department has requested Accuvarift SEEM and log management expertise to meet the above requirements and to perform a basic Installation and initial configuration of devices as specified in Appendix A and Appendix D. Acouvant will provide a consulting resource to perform an initial implementation, configuration, and basic tuning of the ArcSlght Logger solution, based on the terns of this contract. Goals 8 Objectives • Install ArcSight Logger components and configure required network and system configurations to match customer provided information • Configure data collection of standard ArcSight Logger supported log sources as agreed to in Appendix A • Instruct Newport Beach Police Department on basic system access and usage Task List The following is a list of activities that will be performed during this consulting engagement. Subject to consultant availability, Newport Beach Police Department may extend this engagement by submitting a change order and PO for additional services. This agreement outlines services to be delivered on a fixed deliverable basis, pending availability of a qualified consultant. Tasks: f. Architecture Review Review the proposed deployment design with the customer prior to Implementation. 2. System Installation Hardware will be installed to vendor provided standards and configured to match the customer's environment for the list of devices in Aooendix A 3. Log Collector installation Hardware and /or software components will be installed to collect data from the customer's Identified log sources In Appendix A. 4. System Validation Aocuvant will verify events are being received and stored from the log sources Identified and that default system content is enabled. 5. Documentation and Knowledge Transfer Accuvant will provide Installation and configuration documentation on key settings modified at the time of Installation and basic aocess and usage hands on knowledge transfer during the engagement. The consultant will provide a list of additional recommended log sources, next steps, and best practices as appropriate. Revislorr. #1.0 Page 3 of 19 Accu` ` � ArcSight logger Depl2yment (-t(u {i Newport Beach Rafica Department - Project tt: Sochi- dR887g3 The Newport Beach Police Department is encouraged to participate during the engagement as no formal knowledge transfer session is included in an ArcSight Logger Project Scope Below is a list of the activities that will be performed during an ArcSight Logger Deployment. Accuvant will provide an appropriate consultant to execute the tasks listed below: Planning PLANNING AND Confirm the scope of work has been accurately captured in the project proposal and ENVIRONMENT to identify any significant obstacles to implementing the solution before coming REVIEW onsite. Accuvant consultants will conduct a pre - project call to gather the detailed information about the client environment necessary to complete the engagement objectives. Newport Beach Police Department is required to review and gather as much information as possible from the STEM Pre - installation Preparation Steps in Appendix B prior to the pre - project call and onsite arrival. When possible, having Information available for the kick -off meeting will ensure a more productive dialogue KICK -OFF MEETING This meeting will allow the entire project team to meet, review project objectives and strategy, and confirm the project plan and each team member's responsibilities and will include: • Introductions of team members and their role In the project • A review of the project's success criteria • A walkthrough of the project plan, assigning dates and times of deliverables, status reporting requirements, and any change control impacts • Confirming that the Accuvant consultants understand their point(s) of contact and have all of the necessary materials and access to begin their work • Confirm system components have arrived and match the list from Appendix A APPLIANCE OR Accuvant will install the log collection device, software or appliance in the location SOFTWARE identified by the client and as reviewed in the kickoff meeting. INSTALLATION Newport Beach Police Department is responsible for ensuring logging has been enabled and configured for device appropriate events. See Appendix C for recommendations. CONFIGURATION The log collection system will be configured with the manufacturer's provided content and recommended practices. Network settings, basic administration and connectivity settings will also be applied. The customer is responsible for providing proper IP addressing, network connectivity, and customer - specific DNS, NTP and Mail Server settings. Revision: #1-0 Page 4 of 19 A%1 r^ ` ,1 l {� E� ArcSight logger Deployment i(.i l( N Newport Beach Police Department — Project #: SoCal- OP88793 Database Installation and Configuration APPLIANCE OR Accuvant will install the SIEM database or log management device software or SOFTWARE appliance in the location identified by the client and as reviewed in the kickoff INSTALLATION meeting. CONFIGURATION The system will be configured with the manufacturer's provided content and recommended practices. Network settings, basic administration and connectivity settings will also be applied. Appropriate disk space must be available at the time of installation, If external storage is to be used, it must be provisioned and available prior to project kickoff. Correlation Engine Installation and Configuration APPLIANCE/ Accuvant will install the management or correlation device, software or appliance in SOFTWARE the location identified by the client and as reviewed in the kickoff meeting. INSTALLATION NETWORK AND The log manager or correlation system will be configured with the manufacturer's CONNECTIVITY provided content and recommended practices. Network settings, basic administration and connectivity settings will also be applied. Client /Console Installation CONSOLE Accuvant will install the client or management console software to allow for CONFIGURATION management of the SIEM solution. USER INTERFACE Connectivity will be verified for the user interface for administrators. Kevlslon: #1.0 Page 5 of 19 A t Deployment Newport n Beach Police Department— Project #: So Cai- OP38793 Log Collection Installation and Configuration LOG SOURCE Three (3) unique log collectors or sources will be configured using manufacturer CONFIGURATION supplied connectors or content. A single log source can collect data for multiple devices. A single syslog collector can collect data for many devices and types of devices in the network. For an example in a typical deployment, the syslog collector will parse data for routers, switches, firewalls, UPN, and UNIX hosts, and a single Windows collector will pull data for dozens of servers. The customer may be required to change logging destinations on source devices, and/or provide administrative access and an account for log source types pulled from the host devices (ODBC, Windows, and WMI). For file based sources, full read and write privileges and direct rile access will be required on the files to be read and parsed. Connectivity between the log source collector and the source device Is required prior to project kickoff and changes to firewalis and network devices to allow connectivity are the customer's responsibility prior to the consultant arriving onsite. Accuvant will assist as needed with details of required ports and connectivity as request prior to scheduling onsite installation. Project Documentation DAILY STATUS Accuvant's consultants deliver daily status reports to the primary client contact (by REPORTS default — weekly if preferred) detailing activities and what is planned for the following day as well as any issues which have arisen that may delay the on -time completion of the engagement. All communication is secured using industry accepted encryption software to ensure critical information is not compromised. MANUFACTURER Accuvant will assist the client in obtaining the manufacturer's documentation for the DOCUMENTATION product through the support site. FINAL REPORT Accuvant will provide an installation summary report with recommendations as appropriate to onsite findings. This will include an executive level summary as well as relevant detailed technical findings and recommendations regarding any identified weaknesses in the environment. The deliverable will consist of the following sections: • Executive Summary —A one to two page summary of the findings of the assessment. • Work Performed — A detailed listing of each of the testing activities performed by phase, with links to the reports and outputs created by all of the tools used during the project, • Findings and Recommendations — A listing of the security issues that were identified, the risk they pose and recommendations on how to fix them. Revision: #1.0 Page 6 of 19 ( (fj //� N7 ArcSight Logger Deployment l.l.l V/p Newport Beach Police Department— Project #: SoCal•oP88793 VERSIONS AND Accuvant will apply the most current version available (or as appropriate the best known UPGRADES stable version consistent with Newport Beach Police Department's patch management policy), of software, patches and manufacturer provided fixes to the installed system(s), provided the systems are current on maintenance and support, and patches can be applied during business hours. Accuvant will apply one major patch upgrade. Multiple serial patch upgrades may require additional time and a scope change. SYSTEM ACCESS AND The Accuvant consultant will require system passwords and access to the equipment to PASSWORDS be configured. Accuvant suggests the Newport Beach Police Department should use a temporary password during the engagement and change passwords upon project completion Revision: #1.0 Page 7 of 19 C#� fA N^( AProject logger Deployment (,,,,t,l V'J.�� i Newport Beach Police Department — Project #: SoCal•gP$8793 Professional Considerations Scheduling Accuvant estimates this project will take approximately 5 man -days and will be completed over a one week period, Of the estimated 5 days, 4 days are expected to be on -site and the remaining time has been allocated for documenting the solution, and will be conducted off -site. Accuvant proposes using at least one of our Consultants (bios available upon request) on an as needed basis for the appropriate time necessary to perform the work outlined in this proposal. Accuvant and Newport Beach Police Department will agree to work together to schedule time in advance when both parties will have resources available for the project. Project Completion Accuvant may request that Newport Beach Police Department acknowledge completion of the contract in writing via a Certificate of Acceptance, which would be used to signify the successful completion of the consulting engagement. Change in Scope of Services In the event that unforeseen factors change this Services scope of work and /or impact the term and cost of Accuvant- provided Services, Newport Beach Police Department and Accuvant may mutually revise the SOW and Accuvant shall provide customer with an estimate of the impact of such revisions on the fees, payment terms, completion schedule and other applicable provisions of the SOW. If the parties mutually agree to such changes, a written description of the agreed change (`Change Order) shall be prepared, incorporating such changes to the SOW and shall be signed by both parties. The terms of a Change Order Form prevail over those of the SOW. Project Assumptions The ability to complete this engagement in an efficient and timely manner is critical to Accuvant. The assumptions listed below set forth the expectations of the working relationship between Newport Beach Police Department and Accuvant. Accuvant • The work is to be performed consecutively until project completion. There will be no break in services other than weekends and / or Accuvant recognized holidays • Our consultants consider all Newport Beach Police Department information and documentation as sensitive and confidential and will handle appropriately • Our consultants recognize the value of knowledge transfer and will encourage Newport Beach Police Department to participate in all appropriate aspects of the project • Our consultants and /or project managers will notify Newport Beach Police Department of any Items that may be delayed as soon as possible in order to determine ways to manage any impact (i.e., cost, timeframes, modifications, etc.) Revision: 01.0 Page 8 of 19 Aj^C 14'/� w APt*ct Logger Deployment LL..IJ 17111 V 1 Newport Beach Polies Department — Project #: SoGat- 4P88793 • NI deliverables will, after completion, be reviewed Jointly by Newport Beach Police Department and Accuvant consultants • Accuvant Is not responsible for providing any services or performing any tasks not specifically set forth In this SOW Acouvant shall have no responsibility for other contractors or third parties engaged on the project unless expressly agreed to in writing Newport Beach Police Department • Provides a single point of contact within Newport Beach Police Department's organization to help Accuvant consultants coordinate access to the required project maters and personnel • Provides documents / diagrams detailing the existing policies, specifications and/or architecture in a timely manner • Provides a safe working environment, Including a workspace, telephone and network (and Internet) access for the purpose of Ume entry, email and project- related efforts • Provides any necessary buiiding, parking and/or machine room badges/passes to Acouvant consultants • Accuvant consultants Will be reliant on Newport Beach Police Department staff to complete Identified tasks and participate in interviews. Newport Beach Police Departments inability to provide this staff may affect the completion of tasks and/or deliverables. • Deliverables wUi be reviewed by Newport Beach Police Department and returned with comments within ten business days of delivery. Acceptance of the deliverable will be assumed, if no comments are received from Newport Beach Police Department during that time. If the Newport Beach Police Department assumptions listed above cannot be met, there may be a negative Impact on project duration or cost. For example, time that an Accuvant consultant is prevented from working due to a delay caused by Newport Beach Police Department Is billable, and will Increase the price of a fixed fee or time -base/ project. If there are deviations in scope, effort or duration, a change order will be necessary and an addendum for additional effort will be created. All changes In scope or duration will be negotiated between Accuvant and Newport Beach Police Department. Project Management Approach Accuvant recognizes the importance of our client's awareness of the engagement progress and ongoing open communication throughout the project. In order to assist In this requirement, Accuvant has implemented a number of procedures as part of our engagements to ensure that this awareness and open communication channels are maintained. Pre - Engagement A primary objective of the Accuvant project management services is to make the project as smooth of an experience for the client as possible. To accomplish this goal, the project coordinator engages the dent during the pre- engagement call and pre - engagement validation. This pre-engagement call allows Accuvant consultants to gather the detailed information about the client's environment necessary to perform the project. Accuvant consultants will drive this discussion by going through a pre-engagement checklist with client personnel, The primary goals are to confirm the scope of work has been accurately captured in the project proposal and to Identify any significant obstacles to completion prior to beginning the engagement. Specific tasks performed in this phase Include: • Reviewing the project proposal • Confirming basic project logistics • Walking through the sequence of tasks to be performed Revision: #1.0 Page 9 of 19 ArcSight Logger Deployment n C UVAV Newport Seach Police Department - Project #: SoGat- 01388793 • Listing and assigning any action items necessary to complete prior to the project commencing Following the pre - engagement call, the practice manager or managing consultant engages Accuvanrs consultants) to provide support in meeting project assumptions and action Items from the pre - engagement coll. Establishing the proper environment for the first day of engagement is paramount in creating a smooth and successful Aocuvant expedernce for the client. Ongoing Communications To ensure your project is completed in a timely manner, with minimum Impact to both system resources and personnel, Accuvant utilizes various communication methods during each phase. The list below details the methods utilized to ensure consistent ongoing communication with our clients throughout the engagement: • Aocuvart delivers daily or weekly status report to our primary cunt contact detailing activities, what Is planned for the following day or week, as well as any issues which have arisen that may delay the on- time completion of the engagement. • Accuvant also utilizes informal communication including a•malls and phone calls to ensure the client Is kept Informed during the project. • Ail communication Is secured utilizing industry accepted encryption software to ensure critical Information Is not compromised. • Our engagement model creates an environment in which the client, project manager and consultant are constantly communicating Review: #1.9 Page 10 of 19 /� �1 /^��y * 1T ArcSight Logger Deployment n �/ry (i 1 Newport Beach Police Department — Project #: SoCai- OP88793 Project Information Project Location Locations: Remote [ X ) onsite [ X) Address(es): 870 Santa Barbara Dr Newport Beach, CA 92660 Special Directions: Client Contacts Project Lead: John Veale Phone Number: 949.644.3649 Email: jveate@nbpd.org Billing Contact: John Veale Phone Number: 949.644.3849 Emall: jveale@nbpd.org Billing Address: 870 Santa Barbara Dr Newport Beach, CA 92660 Accuvant Contacts Account Manager. Ray Burgess Phone Number: 714.904.9283 Email: rburgess @accuvant.com Solutions Engineer: Juan Ruben Sanchez Phone Number: 858.449.1972 Email: juan.sanchez @accuvant.com Revision: #1.o Page 11 of 19 n CCU V T ArcSight Logger Deployment Newport BeDepartment — Project #: SoCal- OP88793 Project Fees, Expenses, Payment Schedule Fees The Services shall be performed on a time and materials basis and is detailed in the table below. Services to be rendered: ACVT -TS- ARC -TM' S Days 1 $1,800lday • install ArcSight Logger • Configure Log sources • Provide training I•I Payment Schedule Payment is based on the following schedule: • Accuvant will invoice Newport Beach Police Department on a monthly basis, for the actual hours worked during the previous period • Each invoice is due and payable within 30 days of invoice date • in the event Newport Beach Police Department delays or puts the project on hold, Accuvant reserves the right to bill for the portion of work performed up to that point Travel Ft Expenses Travel and expenses are not included in the estimate and will be billed monthly as incurred. Accuvant will make every attempt to incur reasonable expenses associated with the implementation of the project. Valid expenses typically include parking, meals (unless a per diem is agreed upon), lodging, photocopying and communication costs. Travel costs include: airfare, mileage (if a personal car is used) and automobile rental, If international travel Is required, additional expenses may be incurred. Accuvant assumes that any required travel will be booked a minimum of two weeks in advance of any onsite portion of the engagement. Travel and expenses shall not exceed $2,000. Revision: #1.0 Page 12 of 19 �-- ACCUV/1NT — ProjhtLoSoCal- P887nt_ Newport Beach Police Department — Project #: SoCal- OP88793 Appendix A - Equipment and Log Source List System Information t, '�a ° `ai" .4;� a '� s,�'.�':�,.0 J." ...�kak��i���, ���.m.�.:.- w.w�s�,,�1 • �' .. �� � � � ArcSight Appliance L3400 Server Log Sources Windows Domain Authentication Firewall Logs 3 Standard Syslog Connector a s 6 7 a 9 tU Revision: 01.0 Page 13 of 19 I c d a cl 6 CL U d m 0 lu z ;C. U H m C �3 0 o m L F c 0 c m c 0 b c m c 0 �m m t/f c Q� v V1 E b C N O n J-1 o R3 0 0 CL c � o d N LU w �! 4-J G d L ru o 0 O (G E cc LA o 'm C O _ d E 1 v C1 LN U � U 7 LLI pO N d � � L 1 N m 0,4) X O yr• N d y C /c o m W y A V CL d • __ a �o 0 rn EL a O G E: W a O 'c O E x >` v d 0 CL d L a Ws 0 � E b � m Q a w tm C ow 4 d'. L u a W 0 a o E m o- N d cn 0 o ay m -C m x a d d 'O tn or 40 c O A R V o W c C H Q W Vdi p • A E m w d O W N W tn cn E C y0 « y W O d V w b d N a t` �" N N d C m O P y Q W W J d O d N m N .n Q 9 y i0 w N an m W d ro Z u0i rn w c 3 N = a E 0 mom« rn w rnyc. w V.E ro~ W w O R' N C LV " L t W h Z 10 V O W p U o rn m d ❑ m E E E E m d 1° m a c m m w 5 a •- w c a'w a L a ❑ o 'a ❑ F N V t1� Q IL Z % Q N Q '¢ W o N W o N N N N ftl Q p T d Q 10 Q m Q m U ❑ W u. U' T C Q m U ❑ 0 rn EL a O G dt i V 0 m a O ol c m C m m m° E E C �1 'O rj 1 O O c Cd .S m 2:1 -aC c n a $ pL° g a $ o rod. a $. $ _ R ¢g p � t m V J «�ERa� �� �t �sg O co m `�� m m c T p aw_ 5 � ZS3 t p E {rte{ E o _ G vC CWD :C L '� rJ' m� C C T ruc N� c N $� w mH E $ �gg Sc n� E c Q m CL IL a 0� m E 9 0 c .3 _W 6 N W 6 ? LL c ui u d oo ci = d rri a d N c d m ci c N i d v W o Im 0 m a O — ACCUV- �U V 1 Newport Beach Police Department– Project #: SoCal -01398793 Appendix C - Minimum Recommended Logging Policy In order to meet compliance requirements and enable security threat monitoring, key standard events need to be logged. These Include: A. All authentication events (success and failure) B. Moves, adds and changes (MAC) C. Access or Modification of critical files (Pit, Credit Card data, Sensitive /Classified files, Configurations) D. Permits and Denies by Policy for Network Devices Each application or device is unique and may have different choices on what to monitor and how to output required events. Customer - specific hardening and logging policies by device type are recommended in addition to this minimum policy. Each system reporting to a centralized log source should be synchronized to a standard NTP time server, and using UTC (or another policy to be agreed to and universally applied to all log sources). Retention Period A minimum of 30 days online and 3 years offline is a recommended minimum log retention period. Authentication A. Should Include the source address associated with the authentication event (IP, MAC, or Proxy Session ID) B. Should include the result, Success, or Failure, and the output code (account locked, Invalid account...) – where possible map to the original vendor signature ID/Number C. Target account name or ID iM Moves, adds and changes should Include the same fields as authentication events plus, target ID /Change data. 1. Should include the source address associated with the authentication event (IP, MAC, or Proxy Session ID) 2. Should Include the result, Success, or Failure, and the output code (account locked, invalid account...) 3. Target account name or ID 4. Account/Group/File/Policy changed 5. Type of change made (add, delete, add new member) Revision: #1.0 Page 16 of 19 ACcuNT Newport Beach Poilce Department— Project #: SoC81-OP88793 Access or Modification of Sensitive Files Access and modifications to sensitive files, folders or objects should be logged for any key data that contains system configuration settings, user access settings, personally identifiable information (Pit), credit card data, or sensitive files (Human Resource, Accounting, Financial Information...). These types of events should Include the same fields as above plus the type of access (readlwritefmodify /delete), and the object acted upon. 1. Should Include the source address associated with the authentication evert (Up. MAC, or Proxy Session K)) 2. Should include the result, Success, or Failure, and the output code 3. Target account name or ID 4. Object modified 5. Type of change made (read, add, delete, update, grant permission or role, remove permission, modify logging policy) Network Devices In addition to authentication everts, moves, adds and changes... Firewails will need to log both accepts and denies. Routers, switches should log all ACL denies (accepts are not required or suggested for Intra network communication, but should be logged on border devices). IDSIIPSANAFIDAMIDLP — should log all active signatures for allow or block SIEM/Centralized Log Management Considerations • For SIEMILog Management integration, sysior is often the Preferred out uut and easiest to Integrate, however the specific vendor's product log Integration guides should be consulted. • For custom applications that cannot send output via syslog, output to text file (cSV, or RTF), is often the next best choice. • Most SIEMILM solutions can also pug data via ODBC/SOL cads to data erase applications. These types of calls require a query appropriate to the database with two additional fields — a unique record Identifier andlor a time stamp. • Often, scheduling output of scheduled queries to CSV /RTF files is preferred by database application owners to limit the effect of a query on the application. • By allowing the application owner to write the query used for custom applications, the application owner can limit the fields displayed to avoid leaking sensitive data. • Output via SNMP is supported by some devices and SIEMILM feeds. SNMP is often a last resort due to authentication Issues, and the complexity of OID to event matching. • SNMP v1 & v2 do not support authentication • SNMP v3 is not supported by many applications • Object Identifier Q10 are tuumedc mulg field values (i.e. 1.3.6.1.4.1.5518) that are mapped back to events via Ms. These can be commix and difficult to understand. Where possible, It Is strongly recommended that sample logs with a schema be collected for each critical event and event source. Revision: #1.0 Page 17 of 19 ACCU UN ! Newport Beach Police department — Project #: SoCai•01289793 Appendix D - CJIS Logging Requirements 5.4 Policy Area 4: Auditing and Accountability Agencies shall dement audit and accountability controls to increase the probability of authorized users conforming to a prescribed pattern of behavior. Agencies shall carefully assess the inventory of components that compose their Information systems to determine which security controls are applicable to the various components. Auditing controls are typically applied to the components of an information system that provide auditing capability (servers, etc.) and would not necessarily be applied to every user-level workstation within the agency. As technology advances, more powerful and diverse functionality can be found in such devices as personal digital assistants and cellular telephones, which may require the application of security controls in accordance with an agency assessment of risk. 5.4.1 Auditable Events and Content (information Systems) The agency's information system shall generate audit records for defined events. These defined events Include identifying significant events which need to be audited as relevant to the security of the Information system. The agency shat specify which information system components carry out auditing activities. Auditing activity can affect Information system performance and this issue must be considered as a separate factor during the acquisition of formation systems. The agencys information system shall produce, at the application and/or operating system level, audit records containing sufficient Information to establish what events occurred, the sources of the events, and the outcomes of the events. The agency shall periodically review and update the list of agency- defined auditable events. In the event an agency does not use an automated system, manual recording of activities shall still take place. 5.4.1.1 Events The following events shall be logged: 1. Successful and unsuccessful system log-on attempts. 2. Successful and unsuccessful attempts to access, create, write, delete or change permission on a user account file, directory or other system resource. 3. Successful and unsuccessful attempts to change account passwords. 4. Successful and unsuccessful actions by privileged accounts. 5. Successful and unsuccessful attempts for users to access, modify, or destroy the audit log file. 5.4.1.1.1 Content The following content shall be included with every audited event: 1. Date and time of the event. 2. The component of the information system (e.g., software component, hardware component) where the event occurred. 3. Type of event. 4. User /subject identity. 5. Outcome (success or failure) of the event. 5.4.2 Response to Audit Processing Failures The agency's Information system shall provide alerts to appropriate agency officials in the event of an audit processing failure. Audit processing failures include, for example: softwarethardware errors, failures in the audit capturing mechanisms, and audit storage capacity being reached or exceeded. Revision: 01.0 Page 18 of 19 "— ACCU 1-AD V ! Newport Beach Police Department — Project #: SoCal- OP88793 5.4.3 Audit Monitoring, Analysis, and Reporting The responsible management official shall designate an individual or position to review /analyze Information system audit records for Indications of inappropriate or unusual activity, Investigate suspicious activity or suspected violations, to report findings to appropriate officials, and to take necessary actions. Audit reviewlanatysts sloth be conducted at a minimum once a week. The frequency of reviewlanatysks sham be Increased when the volume of an agency's processing Indicates an elevated need for audit review. The agency shall Increase the level of audit monitoring and analysis activity within the information system whenever there Is an indication of increased risk to agency operations, agency assets, or individuals based on law enforcement information, intelligence Information, or other credible sources of Information. 5.4.4 Time Stamps The agency's information system shall provide time stamps for use in audit record generation. The time stamps shall include the date and time values generated by the internal system clocks in the audit records. The agency shall synchronize internal Information system clocks on an annual basis. 5.4.5 Protection of Audit Information The agency's information system shall protect audit Information and audit tools from modification, deletion and unauthorized access. 5.4.6 Audit Record Retention The agency shall retain audit records for at least 365 days. Once the minimum retention time period has passed, the agency shall continue to retain audit records until it is determined they are no longer needed for administrative, legal, audit, or other operational purposes. This Includes, for example, retention and availability of audit records relative to Freedom of Information Act (FOIA) requests, subpoena, and law enforcement actions. 5.4.7 Logging NCIC and Ili Transactions A log shall be maintained for a minimum of one (1) year on all NCIC and III transactions. The III portion of the log shall clearly identify both the operator and the authorized receiving agency. III logs shall also dearly identify the requester and the secondary recipient. The identification on the log shall take the form of a unique Identifier that shall remain unique to the Individual requester and to the secondary recipient throughout the minimum one year retention period. 5.4.8 References/Citations/Directives Appendix I contains all of the references used in this policy and may contain additional sources that apply to this section. Revision: #1.0 Page 19 or 19 INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VI1 (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, one million dollars ($1,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract) with no endorsement or modification limiting the scope of coverage for liability assumed under a contract. C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented ACCUVANT INC. Page B -1 vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. A. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City and its officers, officials, employees, and agents shall be included as insureds under such policies. C. Primary and Non Contributonr. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self - insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days notice of cancellation (except for nonpayment for which ten (10) calendar days notice is required) or nonrenewal of coverage for each required coverage, 5. Additional Agreements Between the Parties. The parties hereby agree to the following: A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this ACCUVANT INC. Page B -2 I Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at anytime. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non - compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. E. Self - insured Retentions. Any self- insured retentions must be declared to and approved by City. City reserves the right to require that self- insured retentions be eliminated, lowered, or replaced by a deductible. Self - insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non - Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. G. Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractor's performance under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. ACCUVANT INC. Page B -3