HomeMy WebLinkAboutC-5980 - On-Call M/RSA for As-Needed Building Maintenance and Repair Services0e-0
0
00
Cl ON -CALL MAINTENANCEIREPAIR SERVICES AGREEMENT
WITH FLAGSHIP FACILITY SERVICES, INC. FOR
AS- NEEDED BUILDING MAINTENANCE AND REPAIR SERVICES
THIS ON -CALL MAINTENANCE /REPAIR SERVICES AGREEMENT
( "Agreement') is made and entered into as of this 22nd day of October, 2014 ( "Effective
Date "), by and between the CITY OF NEWPORT BEACH, a California municipal
corporation and charter city ( "City'), and FLAGSHIP FACILITY SERVICES, INC., a
California corporation ( "Contractor"), whose address is 21270 South Wilmington
Avenue, Suite 301 -302, Long Beach, California 90810, and is made with reference to
the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Contractor to perform on -call maintenance and /or repair
services for City (`Project').
C. Contractor possesses the skill, experience, ability, background, certification and
knowledge to provide the maintenance and /or repair services described in this
Agreement.
D. Contractor has examined the location of all proposed work, carefully reviewed
and evaluated the specifications set forth by City for the Project, is familiar with
all conditions relevant to the performance of services, and has committed to
perform all work required for the compensation specified in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned
parties as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on October 31, 2016, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Contractor shall perform the on -call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ( "Services"
or "Work "). Upon written request from the Project Administrator as defined herein,
Contractor shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal'). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the
Services, and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Contractor shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this
Agreement and Contractor shall perform the Services in accordance with the schedule
included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the
Services shall be performed to completion in a diligent and timely manner. The failure
by Contractor to strictly adhere to the schedule set forth in Exhibit A and the Letter
Proposal, if any, or perform the Services in a diligent and timely manner may result in
termination of this Agreement by City.
3.2 Notwithstanding the foregoing, Contractor shall not be responsible for
delays due to causes beyond Contractor's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Contractor shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein, not later than two (2) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Contractor's control.
3.4 For all time periods not specifically set forth herein, Contractor shall
respond in the most expedient and appropriate manner under the circumstances, by
fax, hand - delivery or mail.
4. COMPENSATION TO CONTRACTOR
4.1 City shall pay Contractor for the Services on a time and expense not -to-
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Except as otherwise provided herein, no rate changes shall be made
during the term of this Agreement without the prior written approval of City. Contractor's
compensation for all Services performed in accordance with this Agreement, including
all reimbursable items, shall not exceed One Hundred Twenty Thousand Dollars and
001100 ($120,000.00), without prior written amendment to the Agreement.
Flagship Facility Services, Inc. Page 2
4.2 Contractor shall submit monthly invoices to City describing the Work
performed the preceding month. Contractor's bills shall include the name and/or
classification of employee who performed the Work, a brief description of the Services
performed and /or the specific task in the Scope of Services to which it relates, the date
the Services were performed, the number of hours spent on all Work billed on an hourly
basis, and a description of any reimbursable expenditures. City shall pay Contractor no
later than thirty (30) calendar days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Contractor only for those costs or expenses
specifically identified in Exhibit B to this Agreement and the Letter Proposal, or
specifically approved in writing in advance by City.
4.4 Contractor shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the
Project, but which is not included within the Scope of Services and which the parties did
not reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with Exhibit B
and the Letter Proposal.
5. PROJECT MANAGER
5.1 Contractor shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Contractor has designated Steve Gobet to be its
Project Manager. Contractor shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Contractor, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Contractor warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
6. ADMINISTRATION
This Agreement will be administered by the Fire Department. City's
Administrative Manager, Fire Department or designee shall be the Project Administrator
and shall have the authority to act for City under this Agreement. The Project
Administrator shall represent City in all matters pertaining to the Services to be
rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Contractor in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Contractor, one copy of all
Flagship Facility Services, Inc. Page 3
existing relevant information on file at City. City will provide all such materials in a
timely manner so as not to cause delays in Contractor's Work schedule.
8. TYPE AND INSTALLATION OF MATERIALS /STANDARD OF CARE
8.1 Contractor shall use only the standard materials described in Exhibit A in
performing Services under this Agreement. Any deviation from the materials described
in Exhibit A shall not be installed or utilized unless approved in advance and in writing
by the Project Administrator.
8.2 All of the Services shall be performed by Contractor or under Contractor's
supervision. Contractor represents that it possesses the personnel required to perform
the Services required by this Agreement, and that it will perform all Services in a
manner commensurate with highest industry standards. All Services shall be performed
by qualified and experienced personnel who are not employed by City. By delivery of
completed Work, Contractor certifies that the Work conforms to the requirements of this
Agreement and all applicable federal, state and local laws and the industry standard.
8.3 Contractor represents and warrants to City that it has, shall obtain and
shall keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Contractor to practice its profession. Contractor shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.4 Contractor shall not be responsible for delay, nor shall Contractor be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Contractor's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. RESPONSIBILITY FOR DAMAGES OR INJURY
9.1 City and all officers, employees and representatives thereof shall not be
responsible in any manner for any loss or damage to any of the materials or other things
used or employed in performing the Project or for injury to or death of any person as a
result of Contractor's performance of the Services required hereunder; or for damage to
property from any cause arising from the performance of the Project by Contractor, or
its subcontractors, or its workers, or anyone employed by either of them.
9.2 Contractor shall be responsible for any liability imposed by law and for
injuries to or death of any person or damage to property resulting from defects,
obstructions or from any cause arising from Contractor's Work on the Project, or the
Work of any subcontractor or supplier selected by Contractor.
9.3 To the fullest extent permitted by law, Contractor shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, and employees (collectively, the "Indemnified Parties') from and against any
and all claims (including, without limitation, claims for bodily injury, death or damage to
Flagship Facility Services, Inc. Page 4
property), demands, obligations, damages, actions, causes of action, suits, losses,
judgments, fines, penalties, liabilities, costs and expenses (including, without limitation,
attorneys' fees, disbursements and court costs) of every kind and nature whatsoever
(individually, a Claim; collectively, "Claims "), which may arise from or in any manner
relate (directly or indirectly) to any breach of the terms and conditions of this
Agreement, any Work performed or Services provided under this Agreement including,
without limitation, defects in workmanship or materials or Contractor's presence or
activities conducted on the Project (including the negligent and/or willful acts, errors
and /or omissions of Contractor, its principals, officers, agents, employees, vendors,
suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of
them or for whose acts they may be liable or any or all of them).
9.4 Notwithstanding the foregoing, nothing herein shall be construed to
require Contractor to indemnify the Indemnified Parties from any Claim arising from the
sole negligence or willful misconduct of the Indemnified Parties. Nothing in this
indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims
and liability regardless of whether any insurance policies are applicable. The policy
limits do not act as a limitation upon the amount of indemnification to be provided by
Contractor.
9.5 Contractor shall perform all Work in a manner to minimize public
inconvenience and possible hazard, to restore other work areas to their original
condition and former usefulness as soon as possible, and to protect public and private
property. Contractor shall be liable for any private or public property damaged during
the performance of the Work by Contractor or its agents.
9.6 To the extent authorized by law, as much of the money due Contractor
under and by virtue of the Agreement as shall be considered necessary by City may be
retained by it until disposition has been made of such suits or claims for damages as
aforesaid.
9.7 The rights and obligations set forth in this Section shall survive the
termination of this Agreement.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Contractor on an independent contractor basis
and Contractor is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Contractor, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No
civil service status or other right of employment shall accrue to Contractor or its
employees. Nothing in this Agreement shall be deemed to constitute approval for
Contractor or any of Contractor's employees or agents, to be the agents or employees
of City. Contractor shall have the responsibility for and control over the means of
performing the Work, provided that Contractor is in compliance with the terms of this
Agreement. Anything in this Agreement that may appear to give City the right to direct
Flagship Facility Services, Inc. Page 5
Contractor as to the details of the performance of the Work or to exercise a measure of
control over Contractor shall mean only that Contractor shall follow the desires of City
with respect to the results of the Services.
11. COOPERATION
Contractor agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with Contractor on the Project.
12. CITY POLICY
Contractor shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in
order to ensure the Project proceeds in a manner consistent with City goals and
policies.
13. PROGRESS
Contractor is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Contractor's indemnification of City, and prior to commencement
of Work, Contractor shall obtain, provide and maintain at its own expense during the
term of this Agreement or for other periods as specified in this Agreement, policies of
insurance of the type, amounts, terms and conditions described in the Insurance
Requirements attached hereto as Exhibit C, and incorporated herein by reference.
15. PREVAILING WAGES
Pursuant to the applicable provisions of the Labor Code of the State of California,
not less than the general prevailing rate of per diem wages including legal holidays and
overtime Work for each craft or type of workman needed to execute the Work
contemplated under the Agreement shall be paid to all workmen employed on the Work
to be done according to the Agreement by the Contractor and any subcontractor. In
accordance with the California Labor Code (Sections 1770 et seq.), the Director of
Industrial Relations has ascertained the general prevailing rate of per diem wages in the
locality in which the Work is to be performed for each craft, classification, or type of
workman or mechanic needed to execute the Agreement. A copy of said determination
is available by calling the prevailing wage hotline number (415) 703 -4774, and
requesting one from the Department of Industrial Relations. The Contractor is required
to obtain the wage determinations from the Department of Industrial Relations and post
at the job site the prevailing rate or per diem wages. It shall be the obligation of the
Contractor or any subcontractor under him /her to comply with all State of California
Flagship Facility Services, Inc. Page 6
labor laws, rules and regulations and the parties agree that the City shall not be liable
for any violation thereof.
16. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall
be construed as an assignment: The sale, assignment, transfer or other disposition of
any of the issued and outstanding capital stock of Contractor, or of the interest of any
general partner or joint venturer or syndicate member or cotenant if Contractor is a
partnership or joint-venture or syndicate or cotenancy, which shall result in changing the
control of Contractor. Control means fifty percent (50 %) or more of the voting power or
twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint -
venture.
17. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Contractor shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it
create any obligation on the part of City to pay or to see to the payment of any monies
due to any such subcontractor other than as otherwise required by law. City is an
intended beneficiary of any Work performed by the subcontractor for purposes of
establishing a duty of care between the subcontractor and City. Except as specifically
authorized herein, the Services to be provided under this Agreement shall not be
otherwise assigned, transferred, contracted or subcontracted out without the prior
written approval of City.
18. OWNERSHIP OF DOCUMENTS
Each and every report, draft, map, record, plan, document and other writing
produced (hereinafter "Documents "), prepared or caused to be prepared by Contractor,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole
right to use such materials in its discretion without further compensation to Contractor or
any other party. Contractor shall, at Contractor's expense, provide such Documents to
City upon prior written request.
W0161 19 1174►kil 1_\IkCA
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept
confidential unless City expressly authorizes in writing the release of information.
Flagship Facility Services, Inc. Page 7
KIaIIIIIIIIII NX101 RIP,
Contractor shall keep records and invoices in connection with the Services to be
performed under this Agreement. Contractor shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3)
years, or for any longer period required by law, from the date of final payment to
Contractor under this Agreement. All such records and invoices shall be clearly
identifiable. Contractor shall allow a representative of City to examine, audit and make
transcripts or copies of such records and invoices during regular business hours.
Contractor shall allow inspection of all Work, data, Documents, proceedings and
activities related to the Agreement for a period of three (3) years from the date of final
payment to Contractor under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Contractor of any disputed sums until satisfaction
of the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Contractor shall not
discontinue Work as a result of such withholding. Contractor shall have an immediate
right to appeal to the City Manager or his /her designee with respect to such disputed
sums. Contractor shall be entitled to receive interest on any withheld sums at the rate of
return that City earned on its investments during the time period, from the date of
withholding of any amounts found to have been improperly withheld.
22. CITY'S RIGHT TO EMPLOY OTHER CONTRACTORS
City reserves the right to employ other contractors in connection with the Project.
23. CONFLICTS OF INTEREST
23.1 Contractor or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act'), which (1) requires such persons to
disclose any financial interest that may foreseeably be materially affected by the Work
performed under this Agreement, and (2) prohibits such persons from making, or
participating in making, decisions that will foreseeably financially affect such interest.
23.2 If subject to the Act, Contractor shall conform to all requirements of the
Act. Failure to do so constitutes a material breach and is grounds for immediate
termination of this Agreement by City. Contractor shall indemnify and hold harmless
City for any and all claims for damages resulting from Contractor's violation of this
Section.
24. NOTICES
24.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
Flagship Facility Services, Inc. Page 8
business day after the deposit thereof in the United States mail, postage prepaid, first -
class mail, addressed as hereinafter provided.
24.2 All notices, demands, requests or approvals from Contractor to City shall
be addressed to City at:
Attn: Administrative Manager, Fire Department
Fire Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
24.3 All notices, demands, requests or approvals from City to Contractor shall
be addressed to Contractor at:
Attn: Steve Gobet
Flagship Facility Services, Inc.
21270 S. Wilmington Avenue, Suite 301 -302
Long Beach, CA 90810
25. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Contractor shall submit to City, in
writing, all claims for compensation under or arising out of this Agreement.
Contractor's acceptance of the final payment shall constitute a waiver of all claims for
compensation under or arising out of this Agreement except those previously made in
writing and identified by Contractor in writing as unsettled at the time of its final request
for payment. Contractor and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Contractor shall be required to file any claim
Contractor may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 et seq.).
26. TERMINATION
26.1 In the event that either party fails or refuses to perform any of the
provisions of this Agreement at the time and in the manner required, that party shall be
deemed in default in the performance of this Agreement. If such default is not cured
within a period of two (2) calendar days, or if more than two (2) calendar days are
reasonably required to cure the default and the defaulting party fails to give adequate
assurance of due performance within two (2) calendar days after receipt of written
notice of default, specifying the nature of such default and the steps necessary to cure
such default, and thereafter diligently take steps to cure the default, the non - defaulting
party may terminate the Agreement forthwith by giving to the defaulting party written
notice thereof.
Flagship Facility Services, Inc. Page 9
26.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Contractor. In the
event of termination under this Section, City shall pay Contractor for Services
satisfactorily performed and costs incurred up to the effective date of termination for
which Contractor has not been previously paid. On the effective date of termination,
Contractor shall deliver to City all reports, Documents and other information developed
or accumulated in the performance of this Agreement, whether in draft or final form.
27. LABOR
27.1 Contractor shall conform with all applicable provisions of state and federal
law including, but not limited to, applicable provisions of the federal Fair Labor
Standards Act ( "FLSA ") (29 USCA § 201, et seq.).
27.2 Whenever Contractor has knowledge that any actual or potential labor
dispute is delaying or threatens to delay the timely performance of this Agreement,
Contractor shall immediately give written notice to City, and provide all relevant
information.
27.3 Contractor represents that all persons working under this Agreement are
verified to be U.S. citizens or persons legally authorized to work in the United States.
27.4 To the fullest extent permitted by law, Contractor shall indemnify, defend,
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, and employees from loss or damage, including but not limited to attorneys'
fees, and other costs of defense by reason of actual or alleged violations of any
applicable federal, state and local labor laws or law, rules, and /or regulations. This
obligation shall survive the expiration and /or termination of the Agreement.
28. STANDARD PROVISIONS
28.1 Recitals. City and Contractor acknowledge that the above Recitals are
true and correct and are hereby incorporated by reference.
28.2 Compliance with all Laws. Contractor shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Contractor shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be
subject to approval of the Project Administrator and City.
28.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent
breach of the same or any other term, covenant or condition contained herein, whether
of the same or a different character.
Flagship Facility Services, Inc. Page 10
28.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged
herein. No verbal agreement or implied covenant shall be held to vary the provisions
herein.
28.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
28.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
28.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Contractor and City and approved as to form by the
City Attorney.
28.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
28.9 Controlling Law and Venue. The laws of the State of California shall
govern this Agreement and all matters relating to it and any action brought relating to
this Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
28.10 Equal Opportunity Employment. Contractor represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because of race, religion, color, national origin, handicap,
ancestry, sex, age or any other impermissible basis under law.
28.11 No Attorneys' Fees. In the event of any dispute or legal action arising
under this Agreement, the prevailing party shall not be entitled to attorneys' fees.
28.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Flagship Facility Services, Inc. Page 11
IN WITNESS WHEREOF, the parties have caused this Agreement to be
executed on the dates written below.
APPROVED AS TO FORM:
CITY ATT REY'S OFFICE
Date:
- /A/j(-/7/q
Bn___ , OA
y:
Aa on C. Harp tAm
City ttorney
ATTEST:
Date: 1 �• fig.
r
By; a.4/;�W -
Leilan
I. Brown
City Clerk —
�FOR14
CITY OF NEWPORT BEACH,
a California municipal corporation
Date: ►j _►2- ZzkA
By:
Dave
City Manager
CONTRACTOR: Flagship Facility
Services, Inc., a California corporation
Date:
By:
D k vid Pasek
Presid6ht-
Date: /0 -2z- - /U/V
Kathy P sek
Secretary
[END OF SIGNATURES]
Attachments: Exhibit A - Scope of Services
Exhibit B - Schedule of Billing Rates
Exhibit C - Insurance Requirements
Flagship Facility Services, Inc. Page 12
EXHIBIT
SCOPE OF SERVICES
Flagship Facility Services, Inc. Page A -1
EXHIBIT A— SCOPE OF SERVICES
1. INTENT
The intent of these specifications is to provide general maintenance and repair services
at the following City facilities operated by the Fire Department:
FACILITY
ADDRESS
Balboa Peninsula Fire Station #1
110 E. Balboa Blvd.
Lido Fire Station #2
475 32nd St.
Fashion Island Fire Station #3
868 Santa Barbara Drive
Balboa Island Fire Station #4
124 Marine Ave.
Corona Del Mar Fire Station #5
410 Marigold
Mariners Fire Station #6
1348 Irvine Ave.
Santa Ana Heights Fire Station #7
20401 Acacia St.
Newport Coast Fire Station #8
6502 Ridge Park Road
Lifeguard Headquarters
70 Newport Pier
Services may also include Jr. Lifeguard Headquarters and Lifeguard Towers.
2. DESCRIPTION OF PROJECT
Contractor shall furnish all labor, equipment, materials, and supervision to perform
repairs as described herein including, but not limited to, the following: carpentry, painting,
plumbing, electrical, flooring, roofing, and concrete work. Unless previously approved by
the City's Project Administrator, City will not provide materials for Projects. Materials are to
be purchased and provided by the Contractor, which shall be reimbursed.
3. WORKING HOURS
Normal working hours shall be between the hours of 7:00 a.m. and 4:00 p.m., Monday
through Friday. Site meetings and repair requests shall be coordinated with the Project
Administrator to minimize potential impact to operations.
4. LEVEL OF MAINTENANCE
All work shall be performed in accordance with the HIGHEST INDUSTRY STANDARDS, as
stated in the enclosed maintenance specification description. Standards and frequencies
may be modified from time to time as deemed necessary by the City for the proper
maintenance of the sites.
If, in the judgment of the City, the level of maintenance is less than that specified
EXHIBIT A — SCOPE OF SERVICES
herein, the City shall, at its option, in addition to or in lieu of other remedies provided
herein, withhold appropriate payment from the Contractor until services are rendered in
accordance with specifications set forth within this document and providing no other
arrangements have been made between the Contractor and the City. Failure to notify of a
change and /or failure to perform an item or work on a scheduled day may, at the City's sole
discretion, result in deduction of payment for that date, week, or month. Payment will be
retained for work not performed until such time as the work is performed to City standard.
The Contractor is required to correct deficiencies within the time specified by the City. If
noted deficient work has not been completed, payment for subject deficiency shall be
withheld and shall continue to be withheld until deficiency is corrected, without right to
retroactive payments.
5. SUPERVISION OF CONTRACT
All work shall meet the approval of the Project Administrator. Any specific problem area
which does not meet the conditions of the specifications set forth herein shall be called to
the attention of the Contractor and if not corrected, payment to the Contractor will not be
made until condition is corrected in a satisfactory manner as set forth in the specifications.
6. PROJECT ADMINISTRATION
This contract is entered into on an on -call basis and does not guarantee or imply any
specific quantity of work during the contract term. When the need for service arises, the
Project Administrator shall request in writing, the necessary repair services required in
adequate detail. Contractor shall then provide a letter proposal for services requested
(hereinafter referred to as the "Letter Proposal "). The Letter Proposal shall include the
following:
• A detailed description of the services to be provided;
• The estimated number of hours and cost to complete the services; and
• The time needed to finish the specific project.
City will assess the Letter Proposal to ensure that services and costs proposed are
commensurate with those agreed upon herein. No services shall be provided until the
Project Administrator has provided written acceptance of the Letter Proposal. Once
authorized to proceed, Contractor shall diligently perform the duties in the approved Letter
Proposal.
As a material inducement to City entering into this Agreement, Contractor represents
and warrants that Contractor is a provider of first class work and Contractor is experienced
in performing the work contemplated herein and, in light of such status and experience,
Contractor covenants that it shall follow the highest industry standards in performing the
work required hereunder and that all materials will be of good quality. For purposes of this
EXHIBIT A— SCOPE OF SERVICES
agreement, the phrase "highest industry standards" shall mean those standards of practice
recognized by one or more first -class firms performing similar work under similar
circumstances.
Contractor shall perform all work required to be performed, and shall provide and
furnish all the labor, materials, necessary tools, expendable equipment and all utility and
transportation services necessary for the project.
7. WORKMANSHIP AND SUPERVISION
Contractor shall maintain a B- contractor's license at all time for the duration of the
agreement.
8. BILLING AND INVOICING
Any and all invoices submitted to the City for work performed related to this Agreement
shall be itemized based on labor and materials.
9. REPAIR AND TECHNICAL RESPONSIBILITIES
9.1 General Carpentry
• Install, rehabilitate, and repair existing structures
• Finish carpentry
e.g.: Interior and exterior doors, cabinet work
9.2 Painting
■ Interior and exterior surfaces
9.3 Minor Plumbing Repairs
Rehabilitate and repair existing structures
■ e.g.: Water heater replacement, faucets, drains, venting pipes
9.4 Electrical Repairs
■ Repair and renovate existing structures
e.g.: Light fixtures, ballasts, service panels, branch circuits.
9.5 Flooring Repairs
■ Removal and installation
e.g.: Tile replacement, floor sealing
9.6 Miscellaneous Repair Work
• Removal and installation of appliances, surfaces
Assembly of Manufactured Items
e.g.: Window coverings, windows and screens, drywall
9.7 Roof Repairs and /or replacements
EXHIBIT B
SCHEDULE OF BILLING RATES
Flagship Facility Services, Inc. Page B -1
EXHIBIT B— SCHEDULE OF BILLING RATES
No project will begin without the Contractor's initial bid or letter proposal. The letter proposal will be
accepted and agreed upon by the City Project Administrator before any work commences. Unless
previously approved by the City's Project Administrator, City will not provide materials for
Projects. Materials are to be purchased and provided by the Contractor, which shall be
reimbursed.
Table B -1: Hourly Rates WITH Prevailing Wage
Regular Rate
After -Hours Rate*
Supervisor
$ 84.77
perhour
$ 127.69
per hour
Journeyman
$ 69.10
perhour
$ 92.63
per hour
Laborer
$ 58.67
perhour
$ 76.96
perhour
Apprentice
$ 51.47
perhour
$ 61.37
perhour
Maximum Overhead
Charged **
10%
Minimum Number of
Hours Per Call
Two (2) hours
*After -Hours rate will be any time outside the regular hours of Monday- Friday 7:OOAM to 4:OOPM,
this rate also includes weekends and holidays.
** Project Administrator reserves the right to request that all original receipts of materials be turned
in with invoices before Contractor is paid.
EXHIBIT C
INSURANCE REQUIREMENTS — MAINTENANCE /REPAIRIJANITORIAL SERVICES
1. Provision of Insurance. Without limiting Contractor's indemnification of City, and
prior to commencement of Work, Contractor shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Contractor
agrees to provide insurance in accordance with requirements set forth here. If
Contractor uses existing coverage to comply and that coverage does not meet
these requirements, Contractor agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Contractor shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury
by disease in accordance with the laws of the State of California, Section
3700 of the Labor Code.
Contractor shall submit to City, along with the certificate of insurance,
a Waiver of Subrogation endorsement in favor of City, its officers,
agents, employees and volunteers.
B. General Liability Insurance. Contractor shall maintain commercial general
liability insurance and, if necessary, umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The
policy shall cover liability arising from premises, operations, products -
completed operations, personal and advertising injury, and liability
assumed under an insured contract (including the tort liability of another
assumed in a business contract).
C. Automobile Liability Insurance. Contractor shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Contractor
arising out of or in connection with Work to be performed under this
Agreement, including coverage for any owned, hired, non -owned or rented
Flagship Facility Services, Inc. Page C -1
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation
against City, its elected or appointed officers, agents, officials, employees
and volunteers or shall specifically allow Contractor or others providing
insurance evidence in compliance with these requirements to waive their
right of recovery prior to a loss. Contractor hereby waives its own right of
recovery against City, and shall require similar written express waivers
from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
products and completed operations, excess liability, pollution liability, and
automobile liability, if required, shall provide or be endorsed to provide that
City and its officers, officials, employees, and agents shall be included as
insureds under such policies.
C. Primary and Non Contributory. All liability coverage shall apply on a
primary basis and shall not require contribution from any insurance or self -
insurance maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days notice of cancellation (except for nonpayment for which ten
(10) calendar days notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
A. Evidence of Insurance. Contractor shall provide certificates of insurance
to City as evidence of the insurance coverage required herein, along with
a waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance
certificates and endorsement must be approved by City's Risk Manager
prior to commencement of performance. Current certification of insurance
shall be kept on file with City at all times during the term of this
Agreement. City reserves the right to require complete, certified copies of
all required insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Contractor sixty (60) calendar days advance
written notice of such change. If such change results in substantial
Flagship Facility Services, Inc. Page C -2
additional cost to Contractor, City and Contractor may renegotiate
Contractor's compensation.
C. Right to Review Subcontracts. Contractor agrees that upon request, all
agreements with subcontractors or others with whom Contractor enters
into contracts with on behalf of City will be submitted to City for review.
Failure of City to request copies of such agreements will not impose any
liability on City, or its employees. Contractor shall require and verify that
all subcontractors maintain insurance meeting all the requirements stated
herein, and Contractor shall ensure that City is an additional insured on
insurance required from subcontractors. For CGL coverage,
subcontractors shall provide coverage with a format at least as broad as
CG 20 38 04 13.
D. Enforcement of Agreement Provisions. Contractor acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Contractor of non - compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features
or limits contained in this Section are not intended as a limitation on
coverage, limits or other requirements, or a waiver of any coverage
normally provided by any insurance. Specific reference to a given
coverage feature is for purposes of clarification only as it pertains to a
given issue and is not intended by any party or insured to be all inclusive,
or to the exclusion of other coverage, or a waiver of any type. If the
Contractor maintains higher limits than the minimums shown above, the
City requires and shall be entitled to coverage for higher limits maintained
by the Contractor. Any available insurance proceeds in excess of the
specified minimum limits of insurance and coverage shall be available to
the City.
F. Self- insured Retentions. Any self- insured retentions must be declared to
and approved by City. City reserves the right to require that self- insured
retentions be eliminated, lowered, or replaced by a deductible. Self -
insurance will not be considered to comply with these requirements unless
approved by City.
G. City Remedies for Non - Compliance If Contractor or any sub -
consultant fails to provide and maintain insurance as required herein, then
City shall have the right but not the obligation, to purchase such
insurance, to terminate this Agreement, or to suspend Contractor's right to
proceed until proper evidence of insurance is provided. Any amounts paid
by City shall, at City's sole option, be deducted from amounts payable to
Contractor or reimbursed by Contractor upon demand.
Flagship Facility Services, Inc. Page C -3
H. Timely Notice of Claims. Contractor shall give City prompt and timely
notice of claims made or suits instituted that arise out of or result from
Contractor's performance under this Contract, and that involve or may
involve coverage under any of the required liability policies. City assumes
no obligation or liability by such notice, but has the right (but not the duty)
to monitor the handling of any such claim or claims if they are likely to
involve City.
I. Contractor's Insurance. Contractor shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of
the Work.
Flagship Facility Services, Inc. Page C -4
CERTIFICATE OF INSURANCE
CHECKLIST
City of Newport Beach
This checklist is comprised of requirements as outlined by the City of Newport Beach. *
Date Received: 10/28/14 Dept. /Contact Received From: Angela
Date Completed: 11/6/14 Sent to: Angela By: Chris
Company /Person required to have certificate: Flagship Facility Services
Type of contract: All Others
I. GENERAL LIABILITY
EFFECTIVE /EXPIRATION DATE: 7/1/14- 7/1115
A.
INSURANCE COMPANY: Zurich American Insurance Company
B.
AM BEST RATING (A -: VII or greater): A +:XV
C.
ADMITTED Company (Must be Califomia Admitted):
Is Company admitted in California?
® Yes ❑ No
D.
LIMITS (Must be $1M or greater): What is limit provided?
1,000,000/2,000,000
E.
ADDITIONAL INSURED ENDORSEMENT — please attach
® Yes ❑ No
F.
PRODUCTS AND COMPLETED OPERATIONS (Must
(What is limits provided ?)
include): Is it included? (completed Operations status does
F.
PRIMARY & NON - CONTRIBUTORY WORDING (For Waste
not apply to Waste Haulers or Recreation)
® Yes ❑ No
G.
ADDITIONAL INSURED FOR PRODUCTS AND
G.
HIRED AND NON -OWNED AUTO ONLY:
COMPLETED OPERATIONS ENDORSEMENT (completed
H.
NOTICE OF CANCELLATION:
Operations status does not apply to Waste Haulers)
® Yes ❑ No
H.
ADDITIONAL INSURED WORDING TO INCLUDE (The City
its officers, officials, employees and volunteers): Is it
included?
® Yes ❑ No
I.
PRIMARY & NON - CONTRIBUTORY WORDING (Must be
included): Is it included?
® Yes ❑ No
J.
CAUTION! (Confirm that loss or liability of the named insured
is not limited solely by their negligence) Does endorsement
include "solely by negligence" wording?
❑ Yes ®No
K.
ELECTED SCMAF COVERAGE (RECREATION ONLY):
® N/A ❑ Yes ❑ No
L.
NOTICE OF CANCELLATION:
❑ NIA ® Yes ❑ No
II. AUTOMOBILE LIABILITY
EFFECTIVE /EXPIRATION DATE: 7/1114- 711/15
A.
INSURANCE COMPANY: Zurich American Insurance Company
B.
AM BEST RATING (A-: VII or greater) A +:XV
C.
ADMITTED COMPANY (Must be California Admitted):
Is Company admitted in California?
® Yes ❑ No
D.
LIMITS - If Employees (Must be $1 M min. BI & PD and $500,000
UM, $2M min for Waste Haulers): What is limits provided?
1,000,000
E
LIMITS Waiver of Auto Insurance / Proof of coverage (if individual)
(What is limits provided ?)
N/A
F.
PRIMARY & NON - CONTRIBUTORY WORDING (For Waste
Haulers only):
M N/A ❑ Yes ❑ No
G.
HIRED AND NON -OWNED AUTO ONLY:
❑ N/A ❑ Yes ® No
H.
NOTICE OF CANCELLATION:
❑ N/A ® Yes ❑ No
III. WORKERS' COMPENSATION
EFFECTIVE /EXPIRATION DATE: 7/1/14- 7/1/15
A.
INSURANCE COMPANY: American Zurich Insurance Company
B.
AM BEST RATING (A-: VII or greater): A +:XV
C.
ADMITTED Company (Must be California Admitted):
® Yes
❑ No
D.
WORKERS' COMPENSATION LIMIT: Statutory
® Yes
❑ No
E.
EMPLOYERS' LIABILITY LIMIT (Must be $1M or greater)
1,000,000
F.
WAIVER OF SUBROGATION (To include): Is it included?
® Yes
❑ No
G.
SIGNED WORKERS' COMPENSATION EXEMPTION FORM:
® N/A ❑ Yes
❑ No
H.
NOTICE OF CANCELLATION:
❑ N/A ® Yes
❑ No
ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED
IV. PROFESSIONAL LIABILITY
V POLLUTION LIABILITY
V BUILDERS RISK
HAVE ALL ABOVE REQUIREMENTS BEEN MET?
IF NO, WHICH ITEMS NEED TO BE COMPLETED?
Approved:
11/6/14
Agent of Alliant Insurance Services Date
Broker of record for the City of Newport Beach
® N/A ❑ Yes ❑ No
® N/A ❑ Yes ❑ No
® N/A ❑ Yes ❑ No
® Yes ❑ No
RISK MANAGEMENT APPROVAL REQUIRED (Non- admitted carrier rated less than _
Self Insured Retention or Deductible greater than $ ) ❑ N/A ❑ Yes ❑ No
Reason for Risk Management approval /exception /waiver:
Approved:
Risk Management Date
* Subject to the terms of the contract.
CERTIFICATE OF LIABILITY INSURANCE 11nrDATE (MMIDD/YYYY)
ggnn A
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the pollCy(!eS) must be endorsed. IT bUlstcwA I IUN 10 "AIVEM, suDleux to
the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the
PRODUCER
INSR
LTR
NAME:
Woodruff- Sawyer & Co.
MD
PHONE Fp/C
50 California Street, Floor 12
POLICY E%P
MMIDDIYYYY
M/C. No. EdiA15-391-2141 x6426 No
E4AIL
San Francisco CA 94111
GENERAL LIABILITY
X COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE OCCUR
ADmEsssstockdale0wsandco.com
3LO829847713
112014
INSURER(S) AFFORDING COVERAGE
NAIC p
$1,000,000
DAMAGE TO RENTED
PREMISES I Ea occunenca
INSURERA:7ur'ch American Insurance Company
165,145
INSURED
FLAGENT -01
INSURER B
Flagship Facility Services, Inc.
GENERALAGGREGATE
:L berty Mutual Insurance Company
23043
1050 N. Fifth Street
PRODUCTS- COMP /OPAGG
$2,000000
San Jose, CA 95112
•
IN$URERD:
BAP829847813
INSURER E
11/2015
Ea accident)
1000000
INSURER F
$
COVERAGES
CERTIFICATE NUMBER: 2009937151
REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
LTR
1rypE OF INSURANCE
IN SR
MD
POLICYNUMBER
POLICY EFF
MMIDDIYYYY
POLICY E%P
MMIDDIYYYY
LIMITS
•
GENERAL LIABILITY
X COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE OCCUR
3LO829847713
112014
/112015
EACH OCCURRENCE
$1,000,000
DAMAGE TO RENTED
PREMISES I Ea occunenca
$1,000,000
MED EXP(Any one person)
$10,000
PERSONAL &ADV INJURY
$1,000.000
GENERALAGGREGATE
$2,000000
GENL AGGREGATE
POLICY
LIMIT APPLIES PER
JECT LOG
PRODUCTS- COMP /OPAGG
$2,000000
$
•
AUTOMOBILE LIABILITY
X ANYALTO
X ALLOWNED X SCHEDULED
AUTOS
X X NON -OWNED
AUTOS
X 5K Comp -Sche IX SK CollSche
BAP829847813
1112014
11/2015
Ea accident)
1000000
BODILY INJURY (Per person)
$
BODILY INJURY (Per accident)
$
PeOPERTY DAMAGE
$
$
C
X
UMBRELLA LIAR
EXCESS LIAB
OCCUR
CLAIM
100005243906
/12014
112015
EACH OCCURRENCE
$25,000,000
rd
AGGREGATE
$25,000,000
DIED I I RETENTION$
$
g
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY
OFFICERIMEM EREXLLUDEIE ECUTNE YIN
(Mandatory In NH)
R yes, describe under
DESCRIPTION OF OPERATIONSbelaw
NIA NIA
NG829803615
71112014
/12015
X I WC STATU- OTH-
E.L. EACH ACCIDENT
$1,000,000
E.L. DISEASE - EA EMPLOYEE
$1,000,000
E.L. DISEASE - POLICY LIMIT
$1,000,000
DESCRIPTION OF OPERATIONS I LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space Is required)
City of Newport Beach and its officers, officials, employees, and agents shall be included as Additional Insured per GL form no. CG 20 10 07
04 & AUTO form no. CA 20 48 02 99. Waiver of Subrogation applicable: GL #U GL 925 B CW (12 -01); Auto # U CA 320 B CW (4 -94); WC
#WC 04 03 06. Insurance is Primary and Non Contributory.
City of Newport Beach
100 Civic Center Drive
Newport Beach CA 92660
ACORD 25 (2010/05)
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
AUTHORIZED REPRESENTATIVE y
n iaRR -9nin
The ACORD name and logo are registered marks of ACORD
All riahts reserved.
POLICY NO, WC829803615
WORKERS' COMPENSATION AND EMPLOYERS' LIABILITY INSURANCE POLICY WC 04 03 06
(Ed. 484)
WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT-
CALIFORNIA
We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not
enforce our right against the person or organization named in the Schedule. (This agreement applies only to the
extent that you perform work under a written contract that requires you to obtain this agreement from us.)
You must maintain payroll records accurately segregating the remuneration of your employees while engaged in
the work described in the Schedule.
The additional premium for this endorsement shall be % of the California workers' compensation pre-
mium otherwise due on such remuneration.
Person or Organization
"ALL PERSONS OR
ORGANIZATIONS."
Schedule
Job Description
"ALL JOBS"
FLAGSHIP ENTERPRISES HOLDING INC., FLAGSHIP FACILITY SERVICES INC.,
FLAGSHIP AIRPORT SERVICES, INC., FLAGSHIP SWEEPING SERVICES INC.
WC 252 (4-84)
WC 04 03 06 (Ed. 4-04)
Page 1 of 1
0
Waiver Of Subrogation (Blanket) Endorsement ZURICH
Policy No.
M Date of Pol,
Up, Date or Pul.
I Elf Dale of End,
Producer
Addl. Preen
Rel. Preen.
43LO829847713
07/012014
07/0112015
$
8
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY,
This endorsement modifies insurance provided under the:
Commercial General Liability Coverage Part
The following is added to the Transfer Of Rights Of Recovery Against Others To Us Condition:
If you are required by a written contract or agreement, which is executed before a loss, In waive your rights of recovery from
others, we agree to waive our rights of recovery. This waiver of rights shall not be construed to be a waiver with respect to any
other operations in which the insured has no contractual interest.
U -GL- 925 -8 CW (12101)
Page I of 1
POLICY NUMBER: BAP829847813
COMMERCIAL AUTO
CA 20 48 02 99
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
DESIGNATED INSURED
This endorsement modifies insurance provided under the following:
BUSINESS AUTO COVERAGE FORM
GARAGE COVERAGE FORM
MOTOR CARRIER COVERAGE FORM
TRUCKERS COVERAGE FORM
With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by
this endorsement.
This endorsement identifies person(s) or organization(s) who are "insureds" under the Who Is An Insured Provision of
the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form.
This endorsement changes the policy effective on the inception date of the policy unless another date is indicated
below.
Endorsement Effective: Countersigned By:
Named Insured:
Authorized Representative
SCHEDULE
Name of Person(s) or Orgenization(s):
SEE CERTIFICATE
(If no entry appears above, information required to complete this endorsement will be shown in the Declarations as
applicable to the endorsement.)
Each person or organization shown in the Schedule is an 'insured" for Liability Coverage, but only to the extent that
person or organization qualifies as an "insured" under the Who Is An Insured Provision contained in Section II of the
Coverage Form,
CA 20480299 Copyright, Insurance Services Office, Inc., 1998 Page 1 of 1 ❑
0
ZURICH
Of Transfer Of Rights Of Recovery Agalnst Others To Us
Policy No.
f£. Date of Pol.,
exp. Date of Pol.
ff.. Dale of End.
genry No.
MI. Pram
eturn Prcm.
BAP829847813
JULY 1, 2014
JULY 1, 2015
This endorsement is issued by the company named in the Declarations. Il changes the policy on the effective date listed above at
the hour stated in the Declarations.
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
Named Insured: FLAGSHIP ENTERPRISES HOLDING INC. FLAGSHIP FACILITY SERVICES INC., FLAGSHIP AIRPORT SERVICES INC., FLAGSHIP SWEEPING SERVICES INC.
Address (including ZIP code): 10.90 NORTH 5TH STREET
SAN JOSE, CA 95112
This endorsement modifies insurance provided under the:
Business Auto Coverage Form
Truckers Coverage Form
Garage Coverage Form
Motor Carrier Coverage Form
SCHEDULE
Name of Person or-Organization: ALL PERSONS AND /OR ORGANIZATIONS THAT REQUIRE A WRITTEN
CONTRACT OR AGREEMENT WITH THE INSURED, EXECUTED PRIOR TO THE ACCIDENT OR LOSS, THAT
WAIVER OF SUBROGATION BE PROVIDED UNDER THIS POLICY FOR WORK PERFORMED BY YOU FOR
THAT PERSON AND /OR ORGANIZATION
We waive any right of recovery we may have against the designated person or organization shown in the schedule because of
payments we make for injury or damage caused by an "accident' or "loss" resulting frorn the ownership, maintenance, or use of
a covered "auto" for which a Waiver of Subrogation is required in conjunction with work performed by you for the designated
person or organization. The waiver applies only to the designated person or organization shown in the schedule.
Countersigned: _ _ Date:
Authorized Representative
U -CA -328 -B C W (4194)
Page 1 of 1
POLICYNUMBER: GLOB29847713
COMMERCIAL GENERAL LIABILITY
CG 20 10 07 04
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED - OWNERS, LESSEES OR
CONTRACTORS - SCHEDULED PERSON OR
ORGANIZATION
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
SCHEDULE
Name Of Additional Insured Persons)
Or Organization(s):
Locations Of Covered O eratlons
WHERE REQUIRED BY WRITTEN CONTRACT
WHERE REQUIRED BY WRITTEN CONTRACT
Information required to complete this Schedule, if not shown above, will be shown in the Declarations.
A. Section II — Who Is An Insured Is amended to B. With respect to the insurance afforded to these
include as an additional insured the person(s) or additional insureds, the following additional exclu-
organization(s) shown in the Schedule, but only sions apply:
with respect to liability for 'bodily injury', "property This insurance does not apply to "bodily injury" or
damage' or "personal and advertising injury" '.property damage" occurring after:
caused, in whole or in part, by:
1. All work, including materials, parts or equip -
1. Your acts or omissions; or
2. The acts or omissions of those acting on your
behalf;
in the performance of your ongoing operations for
the additional insured(s) at the location(s) desig-
nated above.
ment furnished in connection with such work,
on the project (other than service, maintenance
or repairs) to be performed by or on behalf of
the additional Insured(s) at the location of the
covered operations has been completed; or
2. That portion of "your work' out of which the
injury or damage arises has been put to its in-
tended use by any person or organization other
than another contractor or subcontractor en-
gaged in performing operations for a principal
as a part of the same project.
CG 20 10 07 04 0 ISO Properties, Inc., 2004 Page 1 of 1 ❑