Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
C-7065-1 - M/RSA for Repair of Sodium Hypochlorite Tank
i� J MAINTENANCE/REPAIR SERVICES AGREEMENT WITH GATES FIBERGLASS INSTALLERS FOR REPAIR OF SODIUM HYPOCHLORITE TANK THIS MAINTENANCE/REPAIR SERVICES AGREEMENT ("Agreement") is made and entered into as of this 19th day of February, 2016 ("Effective Date'), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"), and Gates Fiberglass Installers, a California corporation ("Contractor'), whose address is 2917 Lakeview Way, Fullerton, California 92835, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Contractor to perform maintenance and/or repair services for City ("Project"). C. Contractor possesses the skill, experience, ability, background, certification and knowledge to provide the maintenance and/or repair services described in this Agreement. D. Contractor has examined the location of all proposed work, carefully reviewed and evaluated the specifications set forth by City for the Project, is familiar with all conditions relevant to the performance of services, and has committed to perform all work required for the compensation specified in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on April 30, 2016, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED 2.1 Contractor shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ("Services' or "Work"). As a material inducement to City entering into this Agreement, Contractor represents and warrants that Contractor is a provider of first class work and Contractor is experienced in performing the Work contemplated herein and, in light of such status and experience, Contractor covenants that it shall follow community professional standards with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances, in performing the Work required hereunder, and that all materials will be of good quality. 2.2 Contractor shall perform all Work required to be performed, and shall provide and furnish all the labor, materials, necessary tools, expendable equipment and all utility and transportation services necessary for the Project. 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Contractor shall perform the Services in accordance with the schedule included in Exhibit A. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Contractor to strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Contractor shall not be responsible for delays due to causes beyond Contractor's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Contractor shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein, not later than two (2) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Contractor's control. 3.4 For all time periods not specifically set forth herein, Contractor shall respond in the most expedient and appropriate manner under the circumstances, by fax, hand -delivery or mail. 4. COMPENSATION TO CONTRACTOR 4.1 City shall pay Contractor for the Services on a time and expense not -to - exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Except as otherwise provided herein, no rate changes shall be made during the term of this Agreement without the prior written approval of City. Contractor's compensation for all Services performed in accordance with this Agreement, including all reimbursable items, shall not exceed Nine Thousand One Hundred Sixty Dollars and 00/100 ($9,160.00), without prior written amendment to the Agreement. 4.2 Contractor shall submit monthly invoices to City describing the Work performed the preceding month. Contractor's bills shall include the name and/or classification of employee who performed the Work, a brief description of the Services performed and/or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Contractor no later than thirty (30) calendar days after approval of the monthly invoice by City staff. Gates Fiberglass Installers Page 2 4.3 City shall reimburse Contractor only for those costs or expenses specifically identified in Exhibit B to this Agreement, or specifically approved in writing in advance by City. 4.4 Contractor shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with Exhibit B. 5. PROJECT MANAGER 5.1 Contractor shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Contractor has designated Casey Parks to be its Project Manager. Contractor shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Contractor, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Contractor warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 6. ADMINISTRATION This Agreement will be administered by the Municipal Operations Department. City's Utilities Manager or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Contractor in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Contractor, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Contractor's Work schedule. 8. TYPE AND INSTALLATION OF MATERIALS/STANDARD OF CARE 8.1 Contractor shall use only the standard materials described in Exhibit A in performing Services under this Agreement. Any deviation from the materials described in Exhibit A shall not be installed or utilized unless approved in advance and in writing by the Project Administrator. 8.2 All of the Services shall be performed by Contractor or under Contractor's supervision. Contractor represents that it possesses the personnel required to perform Gates Fiberglass Installers Page 3 the Services required by this Agreement, and that it will perform all Services in a manner commensurate with community professional standards and with the ordinary degree of skill and care that would be used by other reasonably competent practitioners of the same discipline under similar circumstances. All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Contractor certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws and legally recognized professional standards. 8.3 Contractor represents and warrants to City that it has, shall obtain and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Contractor to practice its profession. Contractor shall maintain a City of Newport Beach business license during the term of this Agreement. 8.4 Contractor shall not be responsible for delay, nor shall Contractor be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Contractor's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. RESPONSIBILITY FOR DAMAGES OR INJURY 9.1 City and all officers, employees and representatives thereof shall not be responsible in any manner for any loss or damage to any of the materials or other things used or employed in performing the Project or for injury to or death of any person as a result of Contractor's performance of the Services required hereunder; or for damage to property from any cause arising from the performance of the Project by Contractor, or its subcontractors, or its workers, or anyone employed by either of them. 9.2 Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects, obstructions or from any cause arising from Contractor's Work on the Project, or the Work of any subcontractor or supplier selected by Contractor. 9.3 To the fullest extent permitted by law, Contractor shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, and employees (collectively, the "Indemnified Parties") from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims'), which may arise from or in any manner relate (directly or indirectly) to any breach of the terms and conditions of this Agreement, any Work performed or Services provided under this Agreement including, without limitation, defects in workmanship or materials or Contractor's presence or activities conducted on the Project (including the negligent and/or willful acts, errors and/or omissions of Contractor, its principals, officers, agents, employees, vendors, Gates Fiberglass Installers Page 4 suppliers, consultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable or any or all of them). 9.4 Notwithstanding the foregoing, nothing herein shall be construed to require Contractor to indemnify the Indemnified Parties from any Claim arising from the sole negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by Contractor. 9.5 Contractor shall perform all Work in a manner to minimize public inconvenience and possible hazard, to restore other work areas to their original condition and former usefulness as soon as possible, and to protect public and private property. Contractor shall be liable for any private or public property damaged during the performance of the Work by Contractor or its agents. 9.6 To the extent authorized by law, as much of the money due Contractor under and by virtue of the Agreement as shall be considered necessary by City may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. 9.7 The rights and obligations set forth in this Section shall survive the termination of this Agreement. 10. INDEPENDENT CONTRACTOR It is understood that City retains Contractor on an independent contractor basis and Contractor is not an agent or employee of City. The manner and means of conducting the Work are under the control of Contractor, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Contractor or its employees. Nothing in this Agreement shall be deemed to constitute approval for Contractor or any of Contractor's employees or agents, to be the agents or employees of City. Contractor shall have the responsibility for and control over the means of performing the Work, provided that Contractor is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Contractor as to the details of the performance of the Work or to exercise a measure of control over Contractor shall mean only that Contractor shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Contractor agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with Contractor on the Project. Gates Fiberglass Installers Page 5 12. CITY POLICY Contractor shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Contractor is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Contractor's indemnification of City, and prior to commencement of Work, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PREVAILING WAGES Pursuant to the applicable provisions of the Labor Code of the State of California, not less than the general prevailing rate of per diem wages including legal holidays and overtime Work for each craft or type of workman needed to execute the Work contemplated under the Agreement shall be paid to all workmen employed on the Work to be done according to the Agreement by the Contractor and any subcontractor. In accordance with the California Labor Code (Sections 1770 et seq.), the Director of Industrial Relations has ascertained the general prevailing rate of per diem wages in the locality in which the Work is to be performed for each craft, classification, or type of workman or mechanic needed to execute the Agreement. A copy of said determination is available by calling the prevailing wage hotline number (415) 703-4774, and requesting one from the Department of Industrial Relations. The Contractor is required to obtain the wage determinations from the Department of Industrial Relations and post at the job site the prevailing rate or per diem wages. It shall be the obligation of the Contractor or any subcontractor under him/her to comply with all State of California labor laws, rules and regulations and the parties agree that the City shall not be liable for any violation thereof. 16. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Contractor, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Contractor is a partnership or joint -venture or syndicate or cotenancy, which shall result in changing the control of Contractor. Control means fifty percent (50%) or more of the voting power or Gates Fiberglass Installers Page 6 twenty-five percent (25%) or more of the assets of the corporation, partnership or joint - venture. L4k 11 :?-,TQ IIL410 The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A. Contractor shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 18. OWNERSHIP OF DOCUMENTS Each and every report, draft, map, record, plan, document and other writing produced (hereinafter "Documents"), prepared or caused to be prepared by Contractor, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Contractor or any other party. Contractor shall, at Contractor's expense, provide such Documents to City upon prior written request. 19. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 20. RECORDS Contractor shall keep records and invoices in connection with the Services to be performed under this Agreement. Contractor shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Contractor under this Agreement. All such records and invoices shall be clearly identifiable. Contractor shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Contractor shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Contractor under this Agreement. 21. WITHHOLDINGS City may withhold payment to Contractor of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to Gates Fiberglass Installers Page 7 constitute a failure to pay according to the terms of this Agreement. Contractor shall not discontinue Work as a result of such withholding. Contractor shall have an immediate right to appeal to the City Manager or his/her designee with respect to such disputed sums. Contractor shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 22. CITY'S RIGHT TO EMPLOY OTHER CONTRACTORS City reserves the right to employ other contractors in connection with the Project. 23. CONFLICTS OF INTEREST 23.1 Contractor or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act"), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 23.2 If subject to the Act, Contractor shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Contractor shall indemnify and hold harmless City for any and all claims for damages resulting from Contractor's violation of this Section. 24. NOTICES 24.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first- class mail, addressed as hereinafter provided. 24.2 All notices, demands, requests or approvals from Contractor to City shall be addressed to City at: Attn: Utilities Manager Municipal Operations Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 24.3 All notices, demands, requests or approvals from City to Contractor shall be addressed to Contractor at: Attn: Steven D. Gates Gates Fiberglass Installers 2917 Lakeview Way Fullerton, California 92835 Gates Fiberglass Installers Page 8 25. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Contractor shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Contractor's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Contractor in writing as unsettled at the time of its final request for payment. Contractor and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Contractor shall be required to file any claim Contractor may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 26. TERMINATION 26.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non -defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 26.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Contractor. In the event of termination under this Section, City shall pay Contractor for Services satisfactorily performed and costs incurred up to the effective date of termination for which Contractor has not been previously paid. On the effective date of termination, Contractor shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 27. LABOR 27.1 Contractor shall conform with all applicable provisions of state and federal law including, but not limited to, applicable provisions of the federal Fair Labor Standards Act ("FLSA") (29 USCA § 201, et seq.). 27.2 Whenever Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Agreement, Contractor shall immediately give written notice to City, and provide all relevant information. 27.3 Contractor represents that all persons working under this Agreement are verified to be U.S. citizens or persons legally authorized to work in the United States. Gates Fiberglass Installers Page 9 27.4 To the fullest extent permitted by law, Contractor shall indemnify, defend, and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers, and employees from loss or damage, including but not limited to attorneys' fees, and other costs of defense by reason of actual or alleged violations of any applicable federal, state and local labor laws or law, rules, and/or regulations. This obligation shall survive the expiration and/or termination of the Agreement. 28. STANDARD PROVISIONS 28.1 Recitals. City and Contractor acknowledge that the above Recitals are true and correct and are hereby incorporated by reference. 28.2 Compliance with all Laws. Contractor shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Contractor shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. 28.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 28.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 28.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 28.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 28.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Contractor and City and approved as to form by the City Attorney. 28.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 28.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to Gates Fiberglass Installers Page 10 this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 28.10 Equal Opportunity Employment. Contractor represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex, sexual orientation, age or any other impermissible basis under law. 28.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 28.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] Gates Fiberglass Installers Page 11 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATTORNEY'S 9,FFICE Date: By: � Aaron (f—Harp' City Attorney ATTEST: 31 /qj Date: J By:- Ayv NLN� Brown City Clerk CITY OF NEWPORT BEACH, a California municipal corporation Date: ffe By' George<urdo Municipal Operations Director - Utilities CONTRACTOR: Gates Fiberglass Installers, a Calif 9 rnia corporation Date: By: Steven D. Gates President Date:4z d � By: C.c az ZZ�cfsd. Linda L. Gates Secretary [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements Gates Fiberglass Installers Page 12 EXHIBIT A SCOPE OF SERVICES • DESCRIPTION OF SERVICES To provide all material, equipment and labor to complete the following work, as detailed in the May 19, 2015 Tank Inspection Report: o Reline with fiberglass the bottom and inside wall of the tank with coverage out the existing manway flange. o Remove the 3" bottom flange bond area and replace a new flange assembly bonded on the tank. ITEMS TO BE PROVIDED BY THE CITY: o The following shall be provided by the City as follows: • Copy of the May 19, 2015 Tank Inspection Report for the Contractor, • Removal of tank chemicals, • Cleaning with neutralization of tank inside surface and working areas, • Field tank hydro testing. • TECHNICAL SPECIFICATIONS The tank is a 10'-0" diameter dome top tank with a straight vertical wall height of 8'-8" and a capacity of 5,500 gallons of Sodium Hypochlorite (NaOCI) solution @12% manufactured in 2004 with Ashland Hetron® 922 Epoxy Vinylester resin with a 100 mil C glass veil. The storage tank appears to weep liquid on the bottom 3" outlet flange of the tank. The internal corrosion barrier on the tank side wall and bottom are showing the age of the tank. The tank will need a complete fiberglass reline of the bottom and inside wall of the tank with coverage out the existing manway flange. • WORK TO BE PERFORMED o Remove, repair and re -line internal surface meeting the following criteria: • Ensure that the internal surface of the tank was cleaned, neutralized and dried before any work is performed. • Prepare the internal surface for a new liner material. Gates Fiberglass Installers Page A-1 • Application of a new 200 mil two (2) ply C -glass surfacing veil with ECR glass. • Tank dry heat post cure. ■ Replacement of the 3" outlet flange assembly o Tank New Internal Liner • The internal surface of the tank will be inspected with the application of a new 200 mil liner to be installed over the bottom and side wall tank repaired areas. The recommended resin for stable 12% sodium hypochlorite shall be a premium grade DERAKANE® 510 (or equal) Epoxy Vinyl Ester resin with a BPO catalyst. o Post Curing • The above tank shall be field post cured with heat. Post curing shall use indirect heat to avoid any heat hotspots. Follow the resin manufacturer's recommendations for post cure temperatures and times. o Field Tank Inspection ■ Inspection of all products fabricated to this proposal upon completion of the field work unless specifically waived in writing by the City. This shall include: 1. Acetone sensitivity test for all internal tank surfaces. ■ 2. Barcol hardness measurements per ASTM D2583 Gates Fiberglass Installers Page A-2 EXHIBIT B SCHEDULE OF BILLING RATES Labor Costs total: $7,000.00 Materials Costs total $2,000.00 Labor and Materials $9,000.00 8% Sales Tax add $ 160.00 Total $9,160.00 Gates Fiberglass Installers Page B-1 EXHIBIT C INSURANCE REQUIREMENTS — MAINTENANCE/REPAIR/JANITORIAL SERVICES 1. Provision of Insurance. Without limiting Contractor's indemnification of City, and prior to commencement of Work, Contractor shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Contractor agrees to provide insurance in accordance with requirements set forth here. If Contractor uses existing coverage to comply and that coverage does not meet these requirements, Contractor agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Contractor shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Contractor shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. B. General Liability Insurance. Contractor shall maintain commercial general liability insurance and, if necessary, umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, products - completed operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Contractor shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Contractor arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented Gates Fiberglass Installers Page C-1 vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Contractor or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Contractor hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, products and completed operations, excess liability, pollution liability, and automobile liability, if required, shall provide or be endorsed to provide that City and its officers, officials, employees, and agents shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self- insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days notice of cancellation (except for nonpayment for which ten (10) calendar days notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: A. Evidence of Insurance. Contractor shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Contractor sixty (60) calendar days advance written notice of such change. If such change results in substantial Gates Fiberglass Installers Page C-2 additional cost to Contractor, City and Contractor may renegotiate Contractor's compensation. C. Right to Review Subcontracts. Contractor agrees that upon request, all agreements with subcontractors or others with whom Contractor enters into contracts with on behalf of City will be submitted to City for review. Failure of City to request copies of such agreements will not impose any liability on City, or its employees. Contractor shall require and verify that all subcontractors maintain insurance meeting all the requirements stated herein, and Contractor shall ensure that City is an additional insured on insurance required from subcontractors. For CGL coverage, subcontractors shall provide coverage with a format at least as broad as CG 20 38 04 13. D. Enforcement of Agreement Provisions. Contractor acknowledges and agrees that any actual or alleged failure on the part of City to inform Contractor of non-compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. E. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Contractor maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. F. Self-insured Retentions. Any self-insured retentions must be declared to and approved by City. City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced by a deductible. Self- insurance will not be considered to comply with these requirements unless approved by City. G. City Remedies for Non -Compliance If Contractor or any sub - consultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Contractor's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Contractor or reimbursed by Contractor upon demand. Gates Fiberglass Installers Page C-3 H. Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractor's performance under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. I. Contractor's Insurance. Contractor shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own judgment may be necessary for its proper protection and prosecution of the Work. Gates Fiberglass Installers Page C-4 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of }ss. On 20 before me, Notary Public, personally appeared who proved to me on the basis of satisfactory evidence to be the person(s) whose names) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signatures(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal Signature (seal) ACKNOWLEDGMENT A notary public or other officer completingthis certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of } ss. On 20 before me, Notary Public, personally appeared proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signatures(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (seal) Gates Fiberglass Installers CERTIFICATE OF INSURANCE CHECKLIST City of Newport Beach This checklist is comprised of requirements as outlined by the City of Newport Beach.'` Date Received: 2/19/16 Dept./Contact Received From: Pat/Rachel) Date Completed: 2/24/16 Sent to: Pat/Rachetl By: Chris/Alicia Company/Person required to have certificate: Gate's Fiberglass Installers Type of contract: All Other L GENERAL LIABILITY EFFECTIVE/EXPIRATION DATE: 10/05/15-10/05/16 A. INSURANCE COMPANY: Kinsale Insurance Company B. AM BEST RATING (A-: VII or greater): A-: VIII C. ADMITTED Company (Must be California Admitted): Is Company admitted in California? ❑ Yes ® No D. LIMITS (Must be $1 M or greater): What is limit provided? 1,000,000/2,000,000 E. ADDITIONAL INSURED ENDORSEMENT—please attach ® Yes ❑ No F. PRODUCTS AND COMPLETED OPERATIONS (Must (What is limits provided?) include): Is it included? (completed Operations status does F. PRIMARY & NON-CONTRIBUTORY WORDING (For Waste not apply to Waste Haulers or Recreation) ® Yes ❑ No G. ADDITIONAL INSURED FOR PRODUCTS AND G. HIRED AND NON -OWNED AUTO ONLY: COMPLETED OPERATIONS ENDORSEMENT (completed H. NOTICE OF CANCELLATION: Operations status does not apply to Waste Haulers) ® Yes ❑ No H. ADDITIONAL INSURED WORDING TO INCLUDE (The City its officers, officials, employees and volunteers): Is it included? ® Yes ❑ No I. PRIMARY & NON-CONTRIBUTORY WORDING (Must be included): Is it included? ® Yes ❑ No J. CAUTION! (Confirm that loss or liability of the named insured is not limited solely by their negligence) Does endorsement include "solely by negligence" wording? ❑ Yes ® No K. ELECTED SCMAF COVERAGE (RECREATION ONLY): ® N/A ❑ Yes ❑ No L. NOTICE OF CANCELLATION: ❑ N/A ® Yes ❑ No II. AUTOMOBILE LIABILITY EFFECTIVE/EXPIRATION DATE: 6130115-6/30/16 A. INSURANCE COMPANY: St Paul Travelers Ins Group B. AM BEST RATING (A-: VII or greater) A++: XV C. ADMITTED COMPANY (Must be California Admitted): Is Company admitted in California? ® Yes ❑ No D. LIMITS - If Employees (Must be $1M min. BI & PD and $500,000 UM, $2M min for Waste Haulers): What is limits provided? 1,000,000 E LIMITS Waiver of Auto Insurance / Proof of coverage (if individual) (What is limits provided?) N/A F. PRIMARY & NON-CONTRIBUTORY WORDING (For Waste Haulers only): ® NIA ❑ Yes ❑ No G. HIRED AND NON -OWNED AUTO ONLY: ❑ N/A ❑ Yes ® No H. NOTICE OF CANCELLATION: ❑ N/A ® Yes 0 No III. WORKERS' COMPENSATION EFFECTIVE/EXPIRATION DATE: 10104/15-10/04/16 A. INSURANCE COMPANY: State Compensation Ins. Fund B. AM BEST RATING (A-: VII or greater): N/A C. ADMITTED Company (Must be California Admitted): ® Yes ❑ No D. WORKERS' COMPENSATION LIMIT: Statutory ® Yes ❑ No E. EMPLOYERS' LIABILITY LIMIT (Must be $1 M or greater) 1,000,000 F. WAIVER OF SUBROGATION (To include): Is it included? ® Yes ❑ No G. SIGNED WORKERS' COMPENSATION EXEMPTION FORM: ® N/A ❑ Yes ❑ No H. NOTICE OF CANCELLATION: ❑ N/A ® Yes ❑ No ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED W, PROFESSIONAL LIABILITY V POLLUTION LIABILITY V BUILDERS RISK HAVE ALL ABOVE REQUIREMENTS BEEN MET? IF NO, WHICH ITEMS NEED TO BE COMPLETED? Approved: Agent of Alliant Insurance Services Broker of record for the City of Newport Beach 2/24/16 Date ® N/A ❑ Yes ❑ No ® NIA ❑ Yes ❑ No ® N/A ❑ Yes ❑ No ® Yes ❑ No RISK MANAGEMENT APPROVAL REQUIRED (Non -admitted carrier rated less than _; Self Insured Retention or Deductible greater than $ ) ❑ N/A ❑ Yes ❑ No Reason for Risk Management approval/exception/waiver: Risk Management approval needed due to GL carrier being Non -Admitted Approved by Sheri on 2/22/16 Approved: Risk Management * Subject to the terms of the contract. Date GATES -1 OP ID: SF A� Ra CERTIFICATE OF LIABILITY INSURANCE ATE (MMIDONYYY) 001126/201 TYPE OF INSURANCE 6 01/26/26 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and concilfions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER NAME: Bob Mattheson Solomon d Solomon Ins Brokers N PHCNc Ell :949-583-0300 CACX No): 949-951-9342 LIc#OC3O562 24411 Ridge Route Or Ste 135 EMAIL ADDRESS: Laguna Hills, CA 92653 INSURERS) AFFORDING COVERAGE NAIC0 Bob Mattheson INSURERA:KinsaleInsurance Company__ AGGREGATE LIMIT APPLIES PER: POLICY ❑ jECT LOC OTHER. GENERAL AGGREGATE $ 2,000,00 INSURED Gate's Fiberglass Installers INSURERS:St Paul Travelers Ins Group 19070 Steve Gates 2917 Lakeview Way INsuRERc:StateCompensationIns. Fund 35076 BA361OM754-15 06130/2015 Fullerton, CA 92835 INSURER 0: BODILY INJURY (Perperson) $ INSURER E PROPERTYI)AMAGE $ Peracciden[ INSURER F UMBRELLA LIAB EXCESS LIAR COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAYHAVE BEEN REDUCED BY PAID CLAIMS. I LTRR TYPE OF INSURANCE SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE POLICY NUMBER EFF MMID POLICYYYY) POLICY EXP (MMIDp1YYYYI LIMITS A X COMMERCIAL GENERAL LIABILITY CLAIMSMADE X❑ OCCUR OwnerlCont Prot X 0100023699-1 10/05/2015 10105!2016 EACH OCCURRENCE $ 1,000,00 X GEN'L X -DAMAGI -- PREMISES Es occurrencel $ 100,00 MED EXP(Any one person) $ excluded PERSONAL &ADV INJURY $ 1,000,000 AGGREGATE LIMIT APPLIES PER: POLICY ❑ jECT LOC OTHER. GENERAL AGGREGATE $ 2,000,00 PRODUCTS-COMPIOP AGS $ 2,000,00 $ B AUTOMOBILE LIABILITY X ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS X HIRED AUTOS X ION-CWNED AUTOS BA361OM754-15 06130/2015 06/30/2016 (CO MBINEDSINGLE LIMIT $ 1,000,00 Ea acddem BODILY INJURY (Perperson) $ BODILY INJURY [Per accitlenn $ PROPERTYI)AMAGE $ Peracciden[ UMBRELLA LIAB EXCESS LIAR OCCUR CLAIMS -MADE EACH OCCURR ENCE $ AGGREGATE $ DED RETENTION$ $ C WORKERS COMPENSATION ANDEMPLOYERS'LIABILI-Y ANY PROPRIETDRPARTNERrE CUTIVE YIN OFFICERIMEMRER EXCLUDED? (Mandatory In NN) If yee describe under DESCRIPTION OF OPERATIONS belcw NfA 1749736.15 10/04/2015 10/04/2016 X H- STATUTE ER EL EACH ACCIDEN $ 1,000,00 E. L. DISEASE -EA EMPLOYEE $ 1,000,00 E. L. DISEASE -POLICY LIMIT $ 1,000,00 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHCLES (ACORD 101, Additional Remarks Schedule, maybe attached If more space is required) Certificate holder is hereby named as additional insured per blanket dditioml insured form CG20100704 and CAS50030110 on file with the coTapany CERTIFICATE HOLDER CANCELLATION CITYNPB SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Newport Beach ACCORDANCE WITH THE POLICY PROVISIONS. 949 W 16th Street AUTHORIZED REPRESENTATIVE Newport Beach, CA 92663 ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD ENDORSEMENT AGREEMENT WAIVER OF SUBROGATION REP D1 BLANKET BASIS 1749736-15 RENEWAL SP 0-64-59-35 PAGE 1 HOME OFFICE SAN FRANCISCO EFFECTIVE OCTOBER 4, 2015 AT 12.01 A.M. ALL EFFECTIVE DATES ARE AND EXPIRING OCTOBER 4, 2016 AT 12.01 A.M. AT 12:01 AM PACIFIC STANDARD TIME OR THE TIME INDICATED AT PACIFIC STANDARD TIME GATES FIBERGLASS INSTALLERS 2917 LAKEVIEW WAY FULLERTON, CA 92835 WE HAVE THE RIGHT TO RECOVER OUR PAYMENTS FROM ANYONE LIABLE FOR AN INJURY COVERED BY THIS POLICY. WE WILL NOT ENFORCE OUR RIGHT AGAINST THE PERSON OR ORGANIZATION NAMED IN THE SCHEDULE. THIS AGREEMENT APPLIES ONLY TO THE EXTENT THAT YOU PERFORM WORK UNDER A WRITTEN CONTRACT THAT REQUIRES YOU TO OBTAIN THIS AGREEMENT FROM US. THE ADDITIONAL PREMIUM FOR THIS ENDORSEMENT SHALL BE 2_00% OF THE TOTAL POLICY PREMIUM. SCHEDULE PERSON OR ORGANIZATION ANY PERSON OR ORGANIZATION FOR WHOM THE NAMED INSURED HAS AGREED BY WRITTEN CONTRACT TO FURNISH THIS WAIVER JOB DESCRIPTION BLANKET WAIVER OF SUBROGATION NOTHING IN THIS ENDORSEMENT CONTAINED SHALL BE HELD TO VARY, ALTER, WAIVE OR EXTEND ANY OF THE TERMS, CONDITIONS, AGREEMENTS, OR LIMITATIONS OF THIS POLICY OTHER THAN AS STATED. NOTHING ELSEWHERE IN THIS POLICY SHALL BE HELD TO VARY, ALTER, WAIVE OR LIMIT THE TERMS, CONDITIONS, AGREEMENTS OR LIMITATIONS OF THIS ENDORSEMENT, COUNTERSIGNED AND %ISSUED AATSAN NFRANCISCO: SEPTEMBER 29,x/22015 J,{/ AUTHORIZED REPRESEN'2 TPlfIVE PRESIDENT AND CEO SCIF FORM 10217 (REV.7-2014) 2572 OLD DP 217 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY ENDORSEMENT Attached To and Forming Part of Policy Effective Dote of Endorsement Named insured 0100023699-1 20/05/201512:01AM at the Named Insured Gates Fiberglass Installers Inc address shown on the Declaratlons Additional Premium: Return Premium: $0 $0 This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE ENVIRONMENTAL CONTRACTING AND PROFESSIONAL SERVICES LIABILITY COVERAGE The insurance provided to Additional Insureds shall be primary and non-contributory with respect to any other valid and collectible insurance available to the Additional Insured, provided that the written contract specifically requires that this insurance apply on a primary and noncontributory basis. ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED. CASS003 0110 Page 1 of 1 THIS ENDORSEMENT CHANGES THE POLICY, PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS SCHEDULED PERSON OR ORGANIZATION Attached To and Forming Port aJPo/iry E/fective Date of Endorsement Named Insured 0100023699-1 l0/05/201512;02AM at the Named Insured Gates Fiberglass Installers Inc address shown on the Declarations Additional Premium: Return Premium $0 1 so This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Additional Insured Persons) or Organization(s): Lacation(s) of Covered Operations Blanket, as required by written contract. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section 11— who Is An Insured is amended to include as an additional insured the person(s) or organizations) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above. B. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1. All work, including materials, parts or equipment fumished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED, CG 20 10 07 04 ® ISO Properties, Inc., 2004 Page 1 of 1 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS Attached To and Forming Part of Policy Effective Date of Endorsement Named Insured 0100023699-1 10/05/2015 12:01AM at the Named Insured Gates Fiberglass Installers Inc address shown on the Declarations AdditronO Premium: Return Premium.' $0 or persons. "New residential construction" does not include $D This endorsement mocilfies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Additional Insured Person{s or Organization(s) Location and Description of Completed Operations Blanket, as required by written contract. EXCLUDES ALL NEW RESIDENTIAL CONSTRUCTION "Your work" does not include "new residential construction", which means any building or structure not previously occupied, and designed or intended for occupancy in whole or in part as a residence by any person or persons. "New residential construction" does not include apartments or apartment buildings or assisted living facilities. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Section II —Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location desig- nated and described in the schedule of this endorse- ment performed for that additional insured and In- cluded in the "products -completed operations hazard ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED, CG 20 37 07 04 0 ISO Properties, Inc., 2004 Page 1 of 1